Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
15 GARCIA JUAREZ CONST INC. RESPONSE TO CLAIM 05-06-08
GARCIA JUAREZ CONSTRUCTION, INC. P.O. BOX 309 — BREA, CA 92822-0309 Phone: (951) 657-3535 Fax: (951) 657-3955 April 17, 2008 City of Tustin 300 Centennial Way Tustin, CA 92780-3715 Attention: Mr. Tim D. Serlet Director of Public Works sent via fax and courier Reference: Letter from Cox, Castle & Nicholsom LLP — Protesting the Award of the Sycamore Avenue Storm Drain Project (CII' No. 5033) Dear Mr. Serlet, Per your correspondence dated April 15, 2008, Garcia Juarez Construction, Inc. (GJC) has the following response. The Center for Contract Compliance (CCC) is an organization that works directly with (and is at the same address as) the Laborers Union with the purpose of harassing non- union contractors. The CCC does not have an interest in "contractor compliance" or "maintaining a level playing field". Their only agenda is to discredit non-union contractors. Despite their constant attempts to discredit this firm (a non-union Contractor), GJC has successfully completed public works projects in excess of $26 million over the past three years (see GJC references) and currently has $4 million of upcoming contracted work. It is the contention of this firm (and the agencies that this firm has worked for) that GJC is a responsible contractor capable of completing this project in a safe and timely manner. 1) City of San Diego Mr. Jim Jackson was employed as an officer of Southern California Underground Contractors, Inc. (SCU) from March of 1994 to December 2004. In June of 2000, SCU was debarred for a three year term over unfounded minor issues. SCU disagreed with the City's unfounded inaccurate allegations and the lack of due process. SCU subsequently filed a lawsuit. The City retaliated with permanent debarment. The case was heard by the Superior Court (SCU prevailed) and the Appellate Court (City prevailed). City of Brea Because the debarment was not due to a violation of law or safety regulation, the City of Brea bid form was answered accurately. See enclosure "A". Ri GARCIA JUAREZ CONSTRUCTION, INC. P.O. BOX 309 — BREA, CA 92822-0309 Page 2 of 3 April 17, 2008 City of Tustin 2) Apprenticeship Requirements The only complaints filed are from the Laborer's Union. Despite their continuous harassment, the Division of Apprenticeship Standards "have reviewed the complaints and found no evidence to warrant an investigation". See enclosure `B". 3) and 4) City of Riverside Upon completion of 90% of the available work (on Spring Garden), the City of Riverside terminated the Contract to avoid additional costs in excess of $600,000 for a redesigned reach of work (on Palmyrita). Subsequently, GJC filed a lawsuit against the City of Riverside. See enclosure "C". The numerous allegations noted are neither accurate nor factual. The City of Riverside is posturing itself to defend a lawsuit. Despite Riverside's inaccurate accusations, GJC was never cited by any regulatory agency (Osha, Labor Board, Apprenticeship Board, etc...). Additionally, the integrity of GJC's work has never been in question. All material was placed and accepted in accordance with the Contract Documents. 5) City of Compton The City of Compton awarded the Contract and then could not obtain a necessary permit from the Los Angeles County Department of Public Works. The City of Compton has agreed to pay GJC $95,000 and has deemed the Contract terminated for convenience. See enclosure "D". Conclusion The CCC's (Laborers Union) accusations are inaccurate and without merit. The opinions of the CCC should not be considered due to their alternative agenda to discredit non- union contractors. GJC agrees that the taxpayers are best served when public contractors are awarded to responsible bidders. GJC respectfully requests that the City of Tustin contact the listed 19 references to confirm that GJC exemplifies honesty and integrity through the completion of all its contracts. See enclosure `B". GARCIA JUAREZ CONSTRUCTION, INC. P.O. BOX 309 — BREA, CA 92822-0309 Page 3 of 3 April 17, 2008 City of Tustin Should the City elect to discuss any of the matters noted above in greater detail, please call to schedule a conference at your earliest convenience. GJC would like to take this opportunity to thank the City of Tustin for considering our bid proposal. Thank you for your time. President JJ:vlg Enclosures cc: Mr. T. Lutz, City Mr. E. Loke, City Council Members April 15, 2008 Mr. Jim Jackson, President Garcia Juarez Construction, Inc. P.O. Box 309 Brea, CA 92822-0309 ; Re: Letter from Cox, Castle & Nicholson LLP Protesting the Award of the Sycamore Avenue Storm Drain Project (CIP No. 5033) Dear Mr. Jackson: The City of Tustin Mayor and Council Members received the attached letter and enclosure package on Monday, April 14, 2008, from Cox, Castle & Nicholson LLP, a firm that represents the Center for Contract Compliance (the "CCC"). The CCC is protesting the Award of the Sycamore Avenue Storm Drain Project to Garcia Juarez Construction, Inc. The letter, with enclosures, has been forwarded to our City Attorney for review. If you care to respond, we request that you provide your written response to the City addressing all of the allegations and evidence set forth by the CCC no later than 5:00 P.M., on Monday, April 21, 2008. Please direct any such response to me at City Hall. In the meantime, if you have any questions, please do not hesitate to contact me or Terry Lutz of my staff at (714) 573-3150. Sincerely, Tim D. Serlet Director of Public Works/City Engineer Attachment: Cox, Castle & Nicholson LLP Letter dated April 10, 2008 with enclosures C: Dana Kasdan (w/o attachments) Terry Lutz (w/o/ attachments) Eric Loke (w/o attachments) Doug Holland (w/o attachments) Joe Forbath (w/o attachments) A PROFESSIONAL LAW CORPORATION CONSTRUCTION LAWYERS RICHARD B. ANDRADEt � if��'C.-+� 11 e?h'tiiF L. •_f I� ,e tiif 7t Y: Yi.:'�.i)� ... "I)"8. �' 1 F.>>'•. t7 '4f nA'8'G 7�l ::1V{?,=iA vEt':eCA r0,UY' OP 'N", WA °c •� Our client: To Whom It May Concern: MISS!ON RIDGE -- 27 101 f�L.F Ftia REAL. SUI r�._ 120 MISSION VIF_IO. CA 92691 TELEPHONE t949) 553-1951 F.ACS(MI+..F (949)155:3-0655 April 18, 2008 Garcia Juarez Construction, Inc. (Enclosure A) RONAL.c) G. HOLHEP SC1071 KRO",: ,JENNIFER t.... GoROO.,� KIMSERLY .d. WiNW Or COUNSEL AZZAM D. SAAR' " This office represents the low bidder, Garcia Juarez Construction, Inc. ("Garcia'). and submits this letter in response to the Laborers Union formal bid protest. Garcia disputes the accuracy of the Laborers Union's allegations in its formal bid protest. The Laborers Union incorrectly asserts that Southern California Underground Contractors, Inc. ("SoCal'') and Jim Jackson were debarred by the City of San Diego for a violation of a law or safety practice -- this is not so. Garcia and Mr. Jackson disputed the City of San Diego`s allegations and defended the action vigorously. More importantly, the action by the City of San Diego did not involve a finding of a criminal violation of any lawn or safety regulation. Moreover, there was no criminal conviction nor any civil penalty imposed for any such violations. Black's Law dictionary defines "violation" as a ``breach of a right or duty of the law." in the City of San Diego case, no such finding was made in that regard. The Disqualification Questionnaire at issue states: "Has the bidder. any officer of the bidder, or any employee of the bidder who has proprietary interest in the bidder,. even been disqualified, removed or otherwise prevented from bidding on or completing a federal, state or local government project because of a violation of lain or a safety regulation." March 4, 2008 Pattie No. 2 Following my ad% ice on ansxvering this questionnaire. Mr. Jackson responded in the negative..( Mr. Jackson's response Nyas truthful and responsive to the questionnaire as posed. This issue has been raised by the Laborers Union in the past. without success. The Cite of San Diego case is a matter of public record. and despite being raised on prior numerous projects, no public agency has eyes disqualified Garcia fir answering this question in the negative. More importantly, the events leading to the debarment in the Cite of' San Diego were 8 years ago and involved a completely separate entity than Garcia. Since then. Mr. .Jackson has performed numerous public works projects without complaint or incident. Garcia encourages you Lo contact its refferences directly. Neither you nor the taxpayers would be better served by rejecting Garcia's bid and having to pay more money to construct the project "ith the second lowest bidder. Should you require additional inf-ormation. Garcia requests that you hold a hearing on this issue and permit Garcia and Mr. ,Jackson to present evidence refuting the hid protest. Should you have any questions or concerns. don't hesitate to contact this office. Thank you for you cooperation and courtesy in the matter. Sincerely. ANDRADE & A,4 SOCIATES f, R CI-IAR[7 B. ANDRADE. ESC.. Attorne% s for Garcia .Juarez Construction. Inc. RBA: Id (I DA I AGarCia Auamz'_dt i lir , yuc.uonn irrr i ti tis dkk,. Public Contract Code section 10162, the authority cited for requiring the Disqualification Quest] onnaire. is a statute that allotivs a state agency to ask if you have ever been debarred. This does not apply to a local agency and a reciprocal statute or section is not found in the Local Agency Contracting section of the Public Contract Code. Oil its face, this statute does not permit you to reject Garcia's bid even if' Mr. Jackson's response to the. Disqualification Questionnaire is deemed to be inaccurate. y (f i �l�ctliii(t' STATE OF CALIFORNIA (Enclosure B) Arnold Schwarzenegger, Governor DEPARTMENT OF INDUSTRIAL RELATIONS E j` www.dir.ca.gov DIVISION OF APPRENTICESHIP STANDARDS 455 Golden Gate Avenue, 10th Floor San Francisco, CA 94102 ADDRESS REPLY TO: 703-4920 C Div. of Apprenticeship Standards Tel: an ( )P. O. Box 420603 Fax: (415) 703-5477 San Francisco, CA 94142-0603 June 13, 2006 Jim Jackson, President Garcia Juarez Construction, Inc. PO Box 309 Brea, CA 92822-0309 RE: Wood Road Irrigation Pipeline DAS Complaint # 2006-0099 Calle Las Bolas Storm Drain Improvements DAS Complaint # 2006-0105 Dear Mr. Jackson, The Division of Apprenticeship Standards (DAS) has received complaints against your company alleging violations of LC § 1777.5 for the works you performed at Wood Road Irrigation Pipeline and Calle Las Bolas Storm Drain Improvements. We have reviewed the complaints and find that there is no evidence to warrant an investigation of a knowing violation. Please find enclosed copies of Excerpts from California Labor Code, Apprentices on Public Works Summary of Requirements, Public Contract Award Notification form, Request for Dispatch of Apprentices form and a Training Fund Contribution form. You can find further information at our website: www.dir.ca.gov/DAS/Public WorksForms.htm. This letter and attached forms constitute legal notification of the requirements of LC §1777.5. Any future investigations of alleged violations on public works projects will include the possibility of the imposition of penalties. If you have any questions please call me at 415-355-5472. cerely, Pacia Parker Apprenticeship Consultant Enclosures Cc: Daniel Brennan, Center for Contract Compliance Pierre Weakley, Center for Contract Compliance Tony Burgett, Western Municipal Water District City of San Clemente File GARCIA JUAREZ CONSTRUCTION, INC. P.O. BOX 309 — BREA, CA 92822-0309 Phone: (562) 984-7340 Fax: (562) 984-7341 April 4, 2006 Division of Apprenticeship Standards Department of Industrial Relations PO Box 420603 San Francisco, CA 94142 sent via Certified Mail Reference: Complaint of Alleged Violations of Labor Code Section 1777.5 Dear Sir or Madam, Per the attached complaint, Garcia Juarez Construction, Inc. (GJC) has complied with all Apprentice Committee requirements for this two week project (see enclosures). Please respond should additional information be required. In the event you should have any questions, please do not hesitate to call at your earliest convenience. JJ:vlg Enclosures This form) should be sent to the Apprenticeship Committee of the craft or trade in the area of the site of the public work. If you have any questions as to the address of the appropriate, Apprenticeship Committee, contact the nearest office of the Division of Apprenticeship Standards (DAS). Consult your telephone directory under California, State of, industrial Relations, for the DAS office In your area. Do not send this form to the Civision of ADarenticeshio Standards. J /z- 9-0--5 PUBLIC WORKS CONTRACT AWARD INFORMATION Check One Of The Boxes Below Please Note: Your election of options below is not to be deemed a request for the immediate dispatch of apprentices. Contractors must make a separate request for actual dispatch. Box t U We will request dispatch of apprentice(s) for this job in accordance with Section 230.1 (A), California Code of Regulations, We voluntarily choose to comply with the applicable Apprenticeship Committee Standards for the duration of this job only, with regard to training apprentices and to the payment of training contributions. Box 2 We will request dispatch of apprentice(t) for this job in accordance with Section 230.1 (A), California Code of Regulations, but do not agree to be bound by the applicable Apprenticeship Committee Standards in training the apprentices; Instead, we agree to employ and train apprentice(s) in accordance with the California Apprenticeship Council regulations, including Section 230.1 of the California Code of Regulations, governing employment of apprentices on public work projects. Box 3 o We are already approved to train apprentices by the applicable Apprenticeship Committee and we will employ and train under the Standards. We will request dispatch of apprentices for this job in accordance with Section 230.1 (A), California Code of Regulations. Box 4 L=._ Wewill not request the dispatch of apprentice(s) since apprentices are not required on this job under the provisions of Califomia Labor Code Section, b use Typed Ndme -- Jackson Title President Date 9 S State of CaliforniaDepartment of Industrial Relations DIVISION OF .APPRENTICESHIP STANDARDS DAS 140 (REV. 2/94) COHTRACTOR'S STATE LICENSE N0. NAME OF CONTRACTOR Garcia Juarez Construction, Inc. 848401 CONTRACTOR'S MAILING ADDRESS — NVMDER A STREET, CITY, ZIP CODE AREA COOL A TELEPHONE No. P.O. Box 309 (714) 672-9009 Brea, CA 92822 NAME 9 LOCATION OF PUBLIC WOAKS PROJECT DATE Of COIETA G1 A AAO 05 R� �rrl1C`/l�v11 J QuCeir� �� DATE OF E PECT ON AM L START OT PROJECT fvvo�f R� C� van )Qi'v�rsl /� /9 O.5 NAME 5 ADDRESS OF PUBLIC AGENCY AWARDING CONTRACT ESTIMATED NU BF/RJOTJOUR NEY MEN HOURS Gvec,+Wy\ /`7LpIP-c /'�G APPRENTICES 'OCCUPATION OF APPRENTICE NUMBER TO BE EMPLOYED APPROXIMATE DATES To aE EMPLOYED Or l 05 Check One Of The Boxes Below Please Note: Your election of options below is not to be deemed a request for the immediate dispatch of apprentices. Contractors must make a separate request for actual dispatch. Box t U We will request dispatch of apprentice(s) for this job in accordance with Section 230.1 (A), California Code of Regulations, We voluntarily choose to comply with the applicable Apprenticeship Committee Standards for the duration of this job only, with regard to training apprentices and to the payment of training contributions. Box 2 We will request dispatch of apprentice(t) for this job in accordance with Section 230.1 (A), California Code of Regulations, but do not agree to be bound by the applicable Apprenticeship Committee Standards in training the apprentices; Instead, we agree to employ and train apprentice(s) in accordance with the California Apprenticeship Council regulations, including Section 230.1 of the California Code of Regulations, governing employment of apprentices on public work projects. Box 3 o We are already approved to train apprentices by the applicable Apprenticeship Committee and we will employ and train under the Standards. We will request dispatch of apprentices for this job in accordance with Section 230.1 (A), California Code of Regulations. Box 4 L=._ Wewill not request the dispatch of apprentice(s) since apprentices are not required on this job under the provisions of Califomia Labor Code Section, b use Typed Ndme -- Jackson Title President Date 9 S State of CaliforniaDepartment of Industrial Relations DIVISION OF .APPRENTICESHIP STANDARDS DAS 140 (REV. 2/94) 1'�-9,0-5 REQUEST FOR DISPATCH OF AN APPRENTICE Do not send this form to DAS You may use this form to request dispatch of an apprentice from the Apprenticeship Committee in the craft or trade in the area of the public work. Cao to: http://www.dir.ca.gov/das/PublieWorksPornis.htn for information about programs in your area and trade. You may also consult your local Division of Apprenticeship Standards (DAS) office whose telephone number may be found in your local directory under California, State of, Industrial Relations, Division of Apprenticeship Standards, Date: To Applicable Apprenticeship Committee: Laborers So. Cal. it. Ap. Cetn. Address: 1385 Sierra Madre, Azusa, Telephone: Contractor Requesting Dispatch: Fax: Garcia Juarez Construction, Inc. Address: P.O. Box 309 - Brea, CA 92822 Telephone: ( 714) 672-9009 Fax: ( 714) 6724099 Person making request: Jim Jackson Number of Apprentices) Needed 1 Craft or Trade Laborer Date Apprentice(s) to Report: 12 / 9 DS (48 hours notice required) Name of Person to Report to: Jim Jackson Address to Report to: 6_,)ocd .�v ve-n i2w i Qj'v�r S�Ci� Time to Report: 7.00 AM You may use this form, or make a verbal or written request, to ask for the dispatch of an apprentice. Please take note of California Code of Regulations, Title 8, § 230.1 (a) which says in part: if in response to a written request an Apprenticeship Committee does not dispatch any apprentice to a contractor who has agreed to employ and train apprentices in accordance with either the Apprenticeship Committee's Standards Or these regulations within 72 hours of such request (excluding Saturdays, Sundays and holidays) the contractor shall not be considered in violation of this section as a result of failure to employ apprentices ... DA8142 (Rev. 9-03) 0-' !U Postage $ 0 Certified Fee C3 C3 Return Receipt Fee $1.85 (Endorsement Required) 0 Restricted DeliveryFee ' rO (Endorsement ReI' IJI Required) r-9 Total Postage & Fees �4 • °v C3 Sent To freer, dpr. tfo.; or PO Boz No. T(/•.• Olty, State, ZlP+4 IT ANGIFA fL Postage O Certified Fee O Return Receipt Fee (Endorsement Required) O fLJ Restricted Delivery Fee co (Endorsement Required) rq Total Postage & Fees U-) ent To 171— 1 —. _ t.. . SECTION ON DELIVERY' iverageProvided) Agent + O El❑ Addressee orinted Name) C. Date of Delivery 5 0750 rrn ` ,/) .J ess different from Rem 17 11 Yes gf, �^vl slivery address below: ❑ No 04/05/2006 ill ❑ Express Mail Return Receipt for Merchandise I C.O.D. very? (Extra Fee) ❑ Yes 7660 Domestic Return Receipt 102595.02-M-1540 n X 1 T `"'u DN ON r. ❑ Agent ❑ Addressee Prtnled Name) C. Date of Delivery 4�y� 7 ares§ different from Rem 17 LJ Yes delivery address below: ❑ No lail ❑ Express Mail I MReturn Receipt for Merchandise ail C.O.D. uu o is s-- Gam_ ❑ Yes 102595-02-M-1540 March 28, 2006 CENTER FOR CONTRACT COMPLIANCE Division of Apprenticeship Standards Department of Industrial Relations P.O. Box 420603 San Francisco, CA 94142 RE: Complaint of Violations of Labor Code Section 1777.5 Dear Sir or Madam: Enclosed is a formal complaint against Garcia Juarez Construction, a contractor on the project Wood Road Irrigation Project. The violation(s) that are listed on the attached Public Works Complaint started on or about December 24, 2005 and ended on or about January 7, 2006. The information has been verified by the applicable JATC and/or California Apprenticeship Council. This complaint is made pursuant to California Code of Regulations Title 8, Chapter 2, Part 1, Article 10, and Section 231(A). THE CENTER FOR CONTRACT COMPLIANCE IS WILLING TO BE PRESENT AND TESTIFY AT ANY HEARING CONDUCTED BY THE ADMINISTRATOR OF APPRENTICESHIP PROGRAM CONCERNING THIS COMPLAINT I DECLARE UNDER PENALTY OF PERJURY, THAT THE FOREGOING IS TRUE AND CORRECT TO THE BEST OF MY KNOWLEDGE. Sincerely, Daniel Brennan Investigator C-7 7;l -i cc: Garcia Juarez Construction with Proof of Service attached (Certified Mail 7004 2510 0000 5561 8978) Western Municipal Water District Attachments: DAS 210/Public Works Complaint Proof of Service of the Complaint on the Respondent. CERTIFIED MAIL RETURN RECEIPT: 7004 2510 0000 5561 8961 CASE: 05838881 CCC S/362 (02/05) 1168 E. La Cadena Dr., Suite 202, • Riverside, CA 92501-1417 • (951) 686-3328 • FAX (951) 686-8470 _.._....w... 4AA%jAP¢ III rUUU;NU I:U Jh{rjZUf1[lF P.O. Box 42003 • San Fr-an-visuo, CA 04142 801)) 1 J�lI �YLJv% Please type or print clearly. If all applicable items and information are not completed, the Complaint may not be acceptable. Please send the completed forms to the Division of Apprenticeship Standards at the above address. COMPLAINANT INFORMATION YOUR FU L NAME 1 0,0 YOUR ADORES NUMBER & STREET, CITY, STATE, ZIP C DE 1 AV\ E-MAIL ADDRESS PUBLIC WORK, COMPLAINT (California Labor Cod Sections 1777.5 and 177 Moto Q YOUR T LEPH Mv —3Ls� AGAINST (RESPONDENT) FULL NAME LICENSEN ;2"TY, I� vC' (1 , ADD SS%- NUMBER STREET, CISTATE, ZIP CODE r' 3 — v v TELEPHONE NO, AMOUNT QF PRIME CONTRACT AZO S l'� CONTRACT AWARD DATE OR OATS WORK STARTED Respondent Is: sGeneratfPrfine Contractor Sub -Contractor IF RESPONDENT IS A SUB -CONTRACTOR; COMPLETE THE FOLLOWING: GENERAL CONTRACTOR'S FULL NAME LICENSE NO. ADDRESS -NUMBER & STREET, CITY, STATE, ZIP CODE TELEPHONE NO. PUBLIC AGENCY AWARDING CONTRACT NAM OOFPUBL AGENCY -DISI h� U ADD ESS —:NUMBER & STRE ITY, STATE, P ODE "' RU 'P() NAM ITLE OF CONTAA PERSON (IF KNOWN) 0�173 LEPHONE N0. PUBLIC WORK JOB SITE PROJECT NAME CONTRACT # ADDRESS OR GEO RAPPA LOCATION O PUBJIq WORKJOBISITE Ockfc,c,� II TY rl oAs 210 (REv.osmi) 'p' 1/tiQ PUBLIC WORKS COMPLAINT Southern Cal. 1fomia .Laborers Training School & apprenticeship Program February 11, 2005 Dan Brennan Center for Contract Compliance 1168 E. La Cadena Dr. #202 Riverside, CA. 92501 Re: Apprenticeship requirements for Garcia Juarez Construction — Wood Road Irrigation Pipeline project Dear Mr. Brennan: I am writing this letter in response to your inquiry regarding the apprenticeship requirements. for the above-mentioned contractor/project Did the contractor file a D.A.S. 140? YES F7 NO 0 Did the contractor request dispatch of an apprentice? YES [ NO FX Did the contractor pay training contribution to the JAC? YES 0 NO F7 Should you have any further questions, please call me at 626-610-1700. Sincerely, z Mary Vizcaino Apprenticeship Representative Laborers Training School & Apprenticeship 1385 West Sierra Madre Avenue, Azusa Ca. 91702 • Phone (626) 610-1700 9 Fax (626) 633-0204 GARCIA JUAREZ CONSTRUCTION, INC. _ P.O. BOX 309 — BREA, CA 92822-0309 Phone: (562) 984-7340 Fax: (562) 984-7341 April 25, 2006 Division of Apprenticeship Standards Department of Industrial Relations PO Box 420603 San Francisco, CA 94142 sent via Certified Mail Reference: Complaint of Alleged Violations of Labor Code Section 1777.5 Dear Sir or Madam, Per the attached complaint, Garcia Juarez Construction, Inc. (GJC) has complied with all Apprentice Committee requirements for this project (see enclosures). Please respond should additional information be required. In the event you should have any questions, please do not hesitate to call at your earliest convenience. JJ:vlg Enclosures This form should be sent to the Apprenticeship Committee of the craft or trade in the area of the site of the public work. If you have any questions as to the address of the appropriate, Apprenticeship Committee, cortact the nearest otfke of the Division of Apprenticeship Standards (DAS), Consult your telephone directory under California, State of, 'Industrial Relations, for`the DAS office in your area. Do not send this form to the Division of Apprenticeship Standards. PUBLIC WORKS CONTRACT AWARD INFORMATION NAME Or CONTRACTOR - CONTRAGTOR'3 STATE LICE13C N0. Garcia Juarez Construction, Inc. 848401 CONTRACTOR'5 MAILING ADDRESS — NU110ER 0 STREET, CITY, ZIP'CODE AREA CODE 0 TELEPHONE N0, P.O. Box 309 (714) 672-9009 .Brea, CA 92822 NAME A LOCATION OF FVYLIC WORKS IRa1ECT r s �o l ,St-�-r-�-� OAT[ Or CONTRACT AWARD y- r (?, C)--5, OATT. Or EXIECTEO OR ACTUAL START Or /ROJECT NAME 3 AODRE33 Of FVOLIC ACENCT AWARDING CONTRACT ESTIMATED HUMBER Or JOURNEYMEN HOuR3 54^ Chert if G C> APPRENTICES APPRENTICE HVNNER TO 01C EMPLOYED APPROXIMATES DATES TQ Ve EMPLOYCO //OCCUPATIONOr ajoo� I^+ l, C ,7 Check One Of The Boxes Below Please Note: Your election of options below is not to be deemed a request for the immediate dispatch of apprentices. Contractors must make a separate request for actual dispatch, Bax t We will request dispatch of apprentice(s) for this job in accordance with Section 230.1 (A), California Code of Regulations. We voluntarily choose to comply with the applicable Apprenticeship Committee Standards for the duration of this job only, with regard to training apprentices and to the payment of training contributions. Box 2 1XI We will request dispatch of apprentice(s) for this job in accordance with Secllon 230:.1 (A), California Code of Regulations, but do not agree to be bound by the applicable Apprenticeship Committee Standards in training the apprentices; Instead, we agree to employ and train apprentice(s) in accordance with the California Apprenticeship Council regulations, including Section 230.1 of the California Code of Regulations, governing employment of apprentices on public work projects. Box 3 We are already approved to train apprentices by the applicable Apprenticeship Committee and we will employ and train under the Standards,. We will request dispatch of apprentices for this job in accordance with Section 230.1 (A), California Code of Regulations, Box a C We will not request the dispatch of apprentice(s) since apprentices are not required on this job under the nrnvielnnc ( I oknr r'-4. O.,J.4;— 1'777 C Typed Narne Jim Jackson Title president Date 5 O� State 0f California — Department of Industrial Relatlon3 ons 140 (REV. ZJpq) DIVISION OF APPRENTICESHIP STANDARDS REQUEST FOR DISPATCH OF AN APPRENTICE Do not send this form to DAS You may use this form to request dispatch of an apprentice from the Apprenticeship Committee in the craft or trade in the area of the public work. Go to: http://www.dir.ca,Kov/da:§/PublicWorksFornis.htm for information about programs in your area and trade. You may also consult your local Division of Apprenticeship Standards (DAS) office whose telephone number may be found in your local directory under California, State of, Industrial Relations, Division of Apprenticeship Standards, Date: ,(r%A.�-� 0 2005 To Applicable Apprenticeship Committee: 1- a�OrGi'S ,So CAI Address: Telephone: Fax: -- Contractor Requesting Dispatch: Address: Garcia Juarez Construction, Inc. P.O. Box 309 - Brea, CA 92822 Telephone: ( 714) 672-9009 Fax: ( 714) 672-8099 Person making request: Jim Jackson Number of Apprentice(s) Needed Craft or Trade 4,,,,'J0d Date Apprentice(s) to Report: 9 0 (48 hours notice required) Name of Person to Report to. e sd� Address to Report to: S4 '-, r- be� e k Time to Report: 'i¢!l You may use this form, or make a verbal or written request, to ask for the dispatch of an apprentice, Please take note of California Code of Regulations, Title 8, § 230.1 (a) which says in part: if in response to a written request an Apprenticeship Committee does not dispatch any apprentice to a contractor who has agreed to employ and train apprentices in accordance with either the Apprenticeship Committee's Standards or these regulations within 72 hours of such request (excluding Saturdays, Sundays and holidays) the contractor shall not be considered in violation of this section as a result of failure to employ apprentices ... DA8142 (Rev. 9.03) ■ Compiete items 1, 2, and 3: Also -complete item 4, If. Restricted Delivery Is desired. I! Print your name and address on the reverse so that we can. refum the card to you. ■ Attach this card to the back of the mailpied6, or on the front if space permits. 1: Article Addressed to: A. Signature 4:A, r.: .:0 At 8.1 Received'by (P►infetl Name) "CkDiiite of Is iielivery�dilresd dMerertt from Item 1? Oyes If YES, enter delivery address below: 0 No. 3. Service Type Issue PVI: $4.65 Total: $15.01 Paid by: Visa $15.01 (y p ' (C�' C ��• ! ' Qe�g�, E3 Certified Mali o Exp" all ❑ Registered b Retum Recelpt for Merchandise Approval #: 006455 AR (l9 s� /' t J 9. ❑ Intsured Mail ❑ C:0 D. 4: Restricted Delivery? Pft Fee) 1 ;Yes BREA , California 928229998 24 Article Number 7004 2 510 0003 3905 3570 0569390464-0091 05/06/2005 (800)275-8777 05:27:33 PS Forrti 3811, February 2004 —�-` Domeetkc%Wfn Receipt 109595-02-1-159 Sales Receipt — - Product Sale Unit Final Description sty Price Price A\ U.S. Postal Selivicei,.1 WHITTIER CA 90601 $0.60 a CERTIHED MAIL,, RECEIPT First -Class r_ Provided) Return Receipt (Green Card) $1.75 m (Domestic Mail OMY; No 11isurance Coverage Certified $2.30 Label Serial #: 70042510000339053594 to a- - t C A U S' E Issue PVI: ___=___= $4.65 a' rn Postage $ YORBA LINDA CA 92885 $1.06 m22-9 $2.30 99B First -Class o Certified Fee Postmr�ear� Issue PVI: - -- - - - - -$1 06 O (Endorsement Required) $1.75 LOS ANGELES CA 90071 $0.60 r-9 Restricted Delivery Fee (Endorsement Required) $0100 CID First-C}ass Return Receipt (Green Card) $1.75 fu Total Postage & Fees $ 54.G5 0. 06/2005 Certified $2.30 Label Serial #: 700425101000339053563o -------- o enr o b¢ '� r-�. Tf l'... � �......... Issue PVI: $4.65 . i Street, pt.1Vo.; or PO Box No.l g s/ .............. AZUSA CA 91702 $0,60 ..... ciry sl8ie, ziP+a First -Class Return Receipt (Green Card) $1.75 Certified $2.30 Label Serial #: 70042510000339053570 Issue PVI: $4.65 Total: $15.01 Paid by: Visa $15.01 Account # XXXXXXXXXXXX4595 Exp. 12/07 Approval #: 006455 Transaction #: 769 23 903500148 Bill#: 1000901602200 Clerk: 02 — All sales final on stamps and postage. — Refunds for guaranteed services only. Thank you for your business. Customer Copy April 6, 2006 29 CENTER FOR CONTRACT COMPLIANCE Division of Apprenticeship Standards Department of Industrial Relations P.O. Box 420603 San Francisco, CA 94142 RE: Complaint of Violations of Labor Code Section 1777.5 Dear Sir or Madam: Enclosed is a formal complaint against Garcia Juarez Construction, a contractor on the Calle Las Bolas Storm Drain Improvements project. The violation(s) that are listed on the attached Public Works Complaint started on or about May 14, 2005 and ended on or about August 6, 2005. The information has been verified by the applicable JATC and/or California Apprenticeship Council. This complaint is made pursuant to California Code of Regulations Title 8, Chapter 2, Part 1, Article 10, and Section 231(A). THE CENTER FOR CONTRACT COMPLIANCE IS WILLING TO BE PRESENT AND TESTIFY AT ANY HEARING CONDUCTED BY THE ADMINISTRATOR OF APPRENTICESHIP PROGRAM CONCERNING THIS COMPLAINT I DECLARE UNDER PENALTY OF PERJURY, THAT THE FOREGOING IS TRUE AND CORRECT TO THE BEST OF MY KNOWLEDGE. Sincerely, Pierre Weakley Investigator cc: Garcia Juarez Construction with Proof of Service attached (certified mail 7004 2510 0000 5561 8992) City of San Clemente Attachments: DAS 210/Public Works Complaint Proof of Service of the Complaint on the Respondent. CERTIFIED MAIL RETURN RECEIPT: 7004 2510 0000 55618985 CASE: 02723872 CCC S/362 (02/05) 1168 E. La Cadena Dr., Suite 202, • Riverside, CA 92501-1417 • (951) 686-3328 • FAX (951) 686-8470 Southern California Laborers Tralniiig School & Apprenticeship Program March 27, 2006 Pierre Weakley Center for Contract Compliance 1168 E. La Cadena Dr. #202 Riverside, CA. 92501 Re: Apprenticeship requirements for Garcia Juarez Construction, Inc. — Calle Las Bolas Storm Drain Improvements project Dear Mr. Weakley, I am writing this letter in response to your inquiry regarding the apprenticeship requirements for the above-mentioned contractor/project. Did the contractor file a D.A.S. 140? Did the contractor request dispatch of an apprentice? Did the contractor pay training contribution to the JAC? Should you have any further questions, please call me at 626-610-1700. Sincerely, YES ❑X NO ❑ YES ❑ NO ❑X YES ❑ NO ❑ 1385 West Sierra Madre Avenue, Azusa Ca. 91702 • Phone (626) 610-1700 9 Fax (626) 633-0204 GARCIA JUAREZ CONSTRUCTION, INC. P.O. BOX 309 — BREA, CA 92822-0309 Phone: (951) 657-3535 Fax: (951) 657-3955 March 25, 2008 Division of Apprenticeship Standards Department of Industrial Relations P.O. Box 420603 San Francisco, CA 94142 sent via certified mail Reference: Complaint of Alleged Violations of Labor Code Section 1777.5 Dear Sir or Madam, Per the attached complaint, Garcia Juarez Construction, Inc. has complied with all Apprentice Committee requirements for this project (see enclosures). Please respond should additional information be required. In the event you should have any questions, please do not hesitate to call at your earliest convenience. JJ:vlg Enclosures PUBLIC. WORKS CONTRACT AWARD INFORMATION Contract award information must be sent to your Apprenticeship Committee if you are approved to train, If you are not approved to train, you must send the information (which may be this form) to ALL applicable Apprenticeship Committees in your craft or trade in the area of the site of the public work. Go to: http://www.dir.ca.gov/das/PubiicWorksForms,htm for information about programs in your area and trade. You may also consult your local Division of Apprenticeship Standards (DAS) office whose telephone number may be found In your local directory under California, State of, Industrial Relations, Division of Apprenticeship Standards. Do not send this form to the Division of Apprenticeship Standards. NAME OF YOUR COMPANY CONTRACTOR'S S ATE LICENSE NO Garcia Juarez Construction Inc. 848401 MAILING ADDRESS- NUMBER d STREET, CITY, ZIP CODE AREA CODE b TELEPHONE NO. P0,Box 309 Brea, CA 92822 (714) 672-9009 NAME Q ADDRESS OF PUBLIC WORKS PROJECT DATE YOUR CONTRACT EXECUTED �/ — / C./ �7� jI G✓ r'C� Sk rt i i 0.l y Se t aJ e -i' / DATE OF EXPECTEDOR ACTUAL START OF PROJECT T^ rcy �e r► �.^.%S 6 it p 7 rp NAME& ADDRESS OF PUBLIC AGENCY AWARDING CONTRACT ESTIMATED NUMBEKQF JOURNEYMEN HOURS OCCUPATION OF APPRENTICE ,/�� -2V O S /7'Y�G�L� t i"� & I V 4) �4A Ail e r 2ro 5 THIS FORM IS BIFING SENT T0: NAME d ADDRESS OF APPRENTICESHIP PROGRAM(S)) Labor r - ESTIMATED NUMBER OF APPRENTICE HOURS 5 d APPROXIMATE DATES TO BE EMPLOYED Labor' rs Southern California Joint Appre tfceship Costuftittee 1385 Sierra Madre Azusa CA 91702 This is not a request for dispatch of apprentices. Contractor must make a separate request for actual dispatch, in accordance with Section 230.1(a) California Code of Regulations Check One Of The Boxes Below 1, W� are already approved to train apprentices by the A0Iprenticeship Committee. We will employ and train under their Standards. Enter name of the Committee 2, a W� will comply with the standards of Apprenticeship Committee for the duration of this job only. Enter name of the Committee 3, []�] W will employ and train apprentices in accordance with the California ApprInticeship Council regulations, in luding § 230,1 (c) which requires that apprentices em on public projects can only be assigned to pe orm work of the craft or trade to which the appre 'ce is rebistered and that the apprentices must at all times work with or under the direct supervision ofj}QurPiBy Ian/m Signature ---1 / Date i��,/0 —17 Typed Name Title President State of California - Department of Industrial Relations DIVISION DAS 140 (REV. 1/04) j OF APPRENTICESHIP STANDARDS a REQUEST FOR DISPATCH OF AN APPRENTICE Do not send this form to DAS You may use this form to request dispatch of an apprentice from the Apprenticeship Committee in the craft or trade in the area of the public work, Cao to: http://www.dir.ca.gov/das/PublicWorksFortis.htm for information about programs in your area and trade, You may also consult your local Division of Apprenticeship Standards (DAS) office whose telephone number may be found in your local directory under California, State of, Industrial Relations) Division of Apprenticeship Standards, Date: T��tc �j Zoo 7 To Applicable Apprenticeship Committee: Laborers So. Cal. Jt. Ap. Com. Address; 1385 Sierra Madre, Azusa, Telephone. Fax: Contractor Requesting Dispatch; Garcia Juarez Construction, Inc. Address: P.O. Box 309 - Brea, CA 92822 Telephone; ('114) 672-9009 Fax: ( 714) 672-8099 Person making request; Jim Jackson Number of Apprentice(s) Needed 1 Craft or Trade Laborer Date Apprentice(s) to Report:� 7 (48 hours notice required) Name of Person to Report to: Jim Jackson Address to Report to; /-- 'A ., P' ^ Time to Report; 7:00 AM You may use this form, or make a verbal or written request, to ask for the dispatch of an apprentice. Please take note of California Code of Regulations, Title 8, § 230.1 (a) which says in part: if in response to a written request an Apprenticeship Committee does not dispatch any apprentice to a contractor who has agreed to employ and train apprentices in accordance with either the Apprenticeship Committee's Standards or these regulations within 72. hours of such request (excluding Saturdays, Sundays and holidays) the contractor shall not be considered in violation of this section as a result of failure to employ apprentices DA8142 (Rev, 9-03) ■ Complete items 1, 2, and 3. Also complete Item 4 if Restricted Delivery is desirad. ■ Print your name and address on the reverse so that we can return the card to you. ■ Attach this card to the back of the mailpiece, or on the front if space permits. 1. Article Addressed to: j C A. Si atur i' � / ''; %) ❑Agent X ?/�� ❑ Addressee B. Received by ( Printed Name) C. Date of Delivery Lr r' D. Is delivery address different from item 1 ❑ Yes If YES, enter delivery address below: ❑ No 3 � 3 3. Service Type / 13 Certified Mail C3 Express Mail - G 7 11t) z Registered ❑ Return Receipt for Merchandise ❑ Insured Mall ❑ C.O.D. 4. Restricted Delivery? (Extra Fee) ❑ Yes 2. Article Number ?006 0100 0002 2717 5996 (Transfer from sere)-- . PS Form. 3811, February 2004--- Domestic Return Receipt 102595-02-M-1540 ■ Complete items 1, 2, and 3. Also complete item 4 if Restricted Delivery is desired. ■ Print your name and address on the reverse so that we can return the card to you. ■ Attach this card to the back of the mailpiece, or on the front if space permits. 1..` l Article Addressed toto: aa-l-A,7i'-)F A. Signature $0.41 Ir ❑ Agent X 3 ❑ Addressee S. Received,byf n ed Name) C. to of Delivery h����` nZi�l� 6607 D. Is delivery address different from Rem 1? ❑ Yes If YES, enter delivery address below: ❑ No 3. Service Type Certified Fee ❑ Certified Mail ❑ Express Mali Return Receipt Fee ❑ Registered ❑ Return Receipt for Merchandise ❑ Insured Mail ❑ C.O.D. 0 4. Restricted Delivery? (Extra Fee) ❑ Yes 2, Article Number 7006 0100 0002 2717 6009 (Transfer from service label) PS Form 3811, February 2004 Domestic Return Receipt 102595-02-M-1540 -n $0.41 Ir $2.65 E . u1 tti r—1 p qR'"'2 C`- Here fU Postage $ r1.1 p Certified Fee O CO Return Receipt Fee 0 (Endorsement Required) (Endorsement Required) 0 Restricted Delivery Fee Q (Endorsement Required) r� Provided) Total Postage & Fees nt oA lber tJ ,S'o .4 i! as -- to freeillpE...... 1fA.... ............................... or PO Box No.b,a 1'0QJA I. ....... clryYiw4-•------•-•------•--- --...._-----••--•--•--------------PS F-01111 3800—hole 20()2 Set! Reverse for Instruction" $0.41 1 0042 02 Postmark Here Ii6/135/2007 $2.65 $2.15 $13. 0IJ $5.21 nt oA lber tJ ,S'o .4 i! as -- to freeillpE...... 1fA.... ............................... or PO Box No.b,a 1'0QJA I. ....... clryYiw4-•------•-•------•--- --...._-----••--•--•--------------PS F-01111 3800—hole 20()2 Set! Reverse for Instruction" b U.S. Postal Service:., ru Certified Fee $2.6c � 02 CERTIFIED MAIL:,., RECEIPT 0 Return Receipt Fee Here (Endorsement Required) $0.00 O Restricted Delivery Fee 0 (Endorsement Required) r -i CDTotal Postage & Fees (Domestic Mail Only, No Insurance $5.21 Coverage Provided) For delivery information visit our website at www.usps.com 11 b ru Certified Fee $2.6c � 02 Postmark $2.15 0 Return Receipt Fee Here (Endorsement Required) $0.00 O Restricted Delivery Fee 0 (Endorsement Required) r -i CDTotal Postage & Fees 116/115/21111] $5.21 —a Sent CJ -c�a lir ©a y� rti .�, ,,�.L.4 A- r so --..----•-• ......................... f� 3`treef, Apt. No.; or PO Box No. ;! q A .� ! !e /L !. AC 1 ..................... pity, siat'e,'ziP+4 _ � O (d O PS Form 3800, June 2002 See Reverst! for Instructions CENTER FOR CONTRACT COMPLIANCE Riverside Office - 1168 E. La Cadena Dr. #202 - Riverside, CA 92507 TEL.951-686-3328 - FAX.951686-8470 zp 28 C �y March 14, 2008 Division of Apprenticeship Standards Department of Industrial Relations P.O. Box 420603 San Francisco, CA 94142 RE: Complaint of Violations of Labor Code Section 1777.5 Dear Sir or Madam: 9 tri, Enclosed is a formal complaint against Garcia Juarez Construction, a contractor on the Citywide Sanitary Sewer Improvements — Group 1 (591-412-1728-7895) project. The violation(s) that are listed on the attached Public Works Complaint started on or about April 30, 2007 and ended on or about September 8, 2007. The information has been verified by the applicable JATC and/or California Apprenticeship Council. This complaint is made pursuant to California Code of Regulations Title 8, Chapter 2, Part 1, Article 10, and Section 231(A). THE CENTER FOR CONTRACT COMPLIANCE IS WILLING TO BE PRESENT AND TESTIFY AT ANY HEARING CONDUCTED BY THE ADMINISTRATOR OF APPRENTICESHIP PROGRAM CONCERNING THIS COMPLAINT I DECLARE UNDER PENALTY OF PERJURY, THAT THE FOREGOING IS TRUE AND CORRECT TO THE BEST OF MY KNOWLEDGE. Sincerely, Patrick Clifton Investigator PC/ia cc: Garcia Juarez Construction with Proof of Service attached (certified mail 70022410000406048433) City of Anaheim Attachments: DAS 210/Public Works Complaint Proof of Service of the Complaint on the Respondent. CERTIFIED MAIL RETURN RECEIPT. -7002 2410 0004 0604 8426 CASE: 07647987 CCC S/362 (02/05) -THE LABORERS SCHOOL LABORERS TRAINING d RETRAINING TRUST OF. SOUTHERN CALIFORNIA l 1i Bea Southern Cali tornia Laborers Training School & Apprenticeship Program February 11, 2005 Patrick Clifton Center for Contract Compliance 1168 E. La Cadens Drive, Suite 202 Riverside, CA. 92501 Re: Apprenticeship requirements for Garcia Juarez Construction — Citywide Sanitary Sewer Improvements project. Dear Mr. Clifton: I am writing this letter in response to your inquiry regarding the apprenticeship requirements for the above-mentioned contractor/project. Did the contractor file a D.A.S. 140? YES NOX Did the contractor request dispatch of an apprentice? YES 0 NO FX Should you have any further questions, please call me at 626-610-1700. Sincerely, Mary Vizcaino Apprenticeship Representative Laborers Training School & Apprenticeship GARCIA JUAREZ CONSTRUCTION, INC. P.O. BOX 309 — BREA, CA 92822-0309 Phone: (951) 657-3535 Fax: (951) 657-3955 April 17, 2008 Division of Apprenticeship Standards Department of Industrial Relations P.O. Box 420603 San Francisco, CA 94142 sent via certified mail Reference: Complaint of Alleged Violations of Labor Code Section 1777.5 Dear Sir or Madam, Per the attached complaint, Garcia Juarez Construction, Inc. has complied with all Apprentice Committee requirements for this project (see enclosures). Both the DAS140 form and the dispatch request form were forwarded via certified mail prior to project commencement. Please respond should additional information be required. In the event you should have any questions, please do not hesitate to call at your earliest convenience. JJ:vlg Enclosures Fcs ddimy inforcl bl -O Ln co Cefted Fee C3 C Return Rsoelpt Fee (EndorBement Required) p Q ReeMoted Dsl' Fee (End,1Yement Required) F-9 ❑ lbtel pentane,e Pees Q A� 0 0Q Cq V vret�,n �n ,e\ e- e.^ r r 3'hridiipflYo:...............Q........ ......... OrP0Box Ab. 51-( P � 9� 41 F Pb�p. $ so C3 2 oO (EndQr 0tRd0mReet drw �r�on) �5 / C� ru cc flp°i"Y•a $0.00 ��U .� r_9 $2.79 07/03/2006 Ln aPGbat lYa ----- Its M a d'rt.----............ --^-- i'i.Lv s q CA - 9170 a.. ni 0 BTXB-V to I6�! P OFLT LONG BEACH, C41ifornta 908079999 0544950005-0094 07/03/2006 (562)428-4134 04:39:52 PN 'Sales `Rcefpt`n'' Product Sale Unit Final Description Qty Price Price AZUSA CA 91702 $0.39 First -Class 1.00 oz. Certified $2.40 Label #: 70051820000444067475 Issue PVI; iwawwwia $2.79 WHITTIER CA 90601 $0.39 First -Class 1.00 oz. Certified $2.40 Label #: 70060100000588896806 fwwiwwii Issue PVI; $2.79 Total; $5.58 Paid by; Cash $20.00 Change Due; -$14.42 8111#; 1000600972300 Clerk; 25 — All sales final on stamps and postage. Refunds for guaranteed services only. Thank you for your business. Customer Copy PUBLIC. WORKS CONTRACT AWARD INFORMATION. Contract award Informauon must be sent to your Apprenticeship Committee if you are approved to train. If you are not approved to train, you must send the Information (which may be this form) to ALL applicable Apprenticeship Committees in your craft or trade in the area of the site of the puNo work, Go to; http.//www,dIr.oa,gov/des/PublioWorksForms,htm for information about programs in your area and trade. You may also consult your local Division of Apprenticeship Standards (DAS) office whose telephone number may be found In your local directory under California, State of, Industrial Relations, Division of Apprenticeship Standards. hi f m to the Division of Apprenticeship Standards. wo not send t s or CON CTOR'S STATEtICENSE NO NAME OF YOVR CO PA gygyo► EA CODE& TELEPHONE NO. MAILING ADDRE kt91ER F , C1TY,''7aP CODE g22 / 672 - �9 , F3. C'9 ' rP TE YOUR CONTRACT D NAME, -WMO PROJECT DATE OF EXP iEtl OR A UA4 9 ARi'OF PROJECT onp,/I NAME d ADDRESS OF PUSUC AGENCY AWARDING CONTRACT ESTIMAJED NUMBER OF OURNEYMEN HOURS 0c90 �S ,�' f OCCUPATION OF ARP ENTIC 3 Co N. �� 0 �� � hvr HIS:FORM.IS EIN NT Ot NAME. 'AD KESS OF APPRENTICESHIP PROGRAMS ESTIMATED NUMe$R OF APPRENTICE HOURS SGO - l �,.b�,f- �if 5 ,���`t'�► �(`� Co. It 1�0 M r'4 �o rtPT-f APPROXIMAT DATEsTO:SEEMPLOYED ,q �-r'c �s l�'Cvr�,ti►, � tt e se— r q s v6 -:;P.9 4 7 ( 8 S 5t.JaX � � �e gI70 This is not a request for dispatch or apprentices. Contractors must make a separate request for actual dispatch, In accordance with Section 230,1(e) California Code of Regulations Check One Of The Boxes Below 1, F7 We are already approved to train apprentices by the Apprenticeship Committee. We will employ and train under their Standards, Enter name of the Committee 2. E We will comply with the standards of Apprenticeship Committee for the duration of this job only, Enter name of the Committee 3, � We will employ and train apprentices in accordance with the California Apprenticeship Council regulations, including § 230.1 (c) which requires that apprentices employed on public projects can only be assigned to perform work of the craft or trade to which th re ce is registered and that the apprentices must at all times work with or under the direct supervision Jou yma /men, Signature \,_Z/ / % ' Date 7Z 3Z0 Typed Name L. -I Title v Knp s ► c. ieovt— State of Callfornia • Department of Industrial Relations DIVISION OAS I40 (REV. 1/04) OF APPRENTICESHIP STANDARDS REQUEST FOR DISPATCH OF Aff APPRZNTICE Do not send this form to DAS You may use this form to request dispatch of an apprentice from the Apprenticeship Committee in the craft or trade in the area of the public work. Cao for htlR:/4www.dir,ca.gov/das/PublieWorksF-orras,htin for information about programs in your area and trade. You may also consult your local Division of Apprenticeship Standards (DAS) office whose telephone number may be found in your local directory under California, State of, Industrial Relations, Division of Apprenticeship Standards, Date: To Applicable Apprenticeship Committee: Laborers So. Cal. it. Ap. Cam. Address: 1385 Sierra Madre, Azusa, Telephone; Fax: Contractor Requesting Dispatch: Garcia Juarez Construction, Inc. Address: P.O. Box 309 — Brea, CA 92822 Telephone: ( 714) 672-9009 Fax: ( 714) 672--0099 Person making request: Jim Jackson Number of Apprentice(s) Needed 1 Craft or Trade Laborer Date Apprentice(s) to Report: C//5/06__ (48 hours notice required) Name of Person to Report to: Jim Jackson Address to Report to: Omni%% 96-P4 �� Time to Report: 7:00 AM You mity use this form, or make a verbal or written request, to ask for the dispatch of an apprentice. Please take now of California Code of Regulations, Title 8, § ,230.1 (a) which says in part: if in response to a written request an Apprenticeship Committee does not dispatch any apprentice to a contractor who has agreed to employ and train apprentices In accordance with either the Apprenticeship Commtttee's Standards or these regulations within 72 hours of such request (excludingSaturdays, Sundays and holidays) the contractor shall not be considered in violation of this section as a result offailure to employ apprentices ... DA8142 (Rev. 9.03) April 8, 2008 CENTER FOR CONTRACT COMPLIANCE Riverside Office • 1168 E. La Cadena Dr. #202 • Riverside, CA 92501 TEL.951-686-3328 • FAX 951-686-8470 . 104W 28 Division of Apprenticeship Standards Department of Industrial Relations P.O. Box 420603 San Francisco, CA 94142 RE: Complaint of Violations of Labor Code Section 1777.5 Dear Sir or Madam: Enclosed is a formal complaint against Garcia Juarez Construction, a contractor on the O'Neill Regional Sewer Conversion project. The violation(s) that are listed on the attached Public Works Complaint started on or about October 23, 2007 and ended on or about January 5, 2008. The information has been verified by the applicable JATC and/or California Apprenticeship Council. This complaint is made pursuantto California Code of Regulations Title 8, Chapter 2, Part 1, Article 1.0, and Section 231(A). THE CENTER FOR CONTRACT COMPLIANCE IS WILLING TO BE PRESENT AND TESTIFY AT ANY HEARING CONDUCTED BY THE ADMINISTRATOR OF APPRENTICESHIP PROGRAM CONCERNING THIS COMPLAINT I DECLARE UNDER PENALTY OF PERJURY, THAT THE FOREGOING IS TRUE AND CORRECT TO THE BEST OF MY KNOWLEDGE. Sincerely, Pierre Weakley Investigator PW/im cc: Garcia Juarez Construction with Proof of Service attached City of Diamond Bar Attachments: DAS 210/Public Works Complaint Proof of Service of the Complaint on the Respondent. CERTIFIED MAIL RETURN RECEIPT: 7007 0220 0000 8105 7287 CASE: 05896231 CCC S/362 (02/05) (Z. Iii►isurrr of +tA3��free;hip �ntiardl: Caff tmiA ftartwilt of Ilttittc5fr'ca1 Rcxatipas P.O. BDh --240603 -ban Fmhla-600, CA 94142-06Va Please type or print clearly. If all applicable items and information are not completed, the Complaint may not be acceptable. Please send the completed forms to the Division of Apprenticeship Standards at the above address. For DAS use only Complaint a PUBLIC WORKS COMPLAINT (California Labor Code Sections 1777.5 and 1777.7) COMPLAINANT INFORMATION YOUR FULL NAME �¢ p C0 �FA C CD AA, 6 1 Til A ) t. _< YOUR ADDRESS - NUMBER S STREET, MY. STATE, ZIP CODE 11ve, E-MML ADDRESS 9si-6�6�33a8 AGAINST (RESPONDENT) FULL NAME G o R c I A J UA P-,, -Z CON s�� � ���o,J '�ENa S` � Vr ADWMB NLWBER; STREET Ctrl' STATE, ZIP CODE AMOUNTaF PRWECONTRACT AWARD 6 - - 3 o �[ 0 00NTRACT AWARD DATE OR DATE WORK STARTED Reapondanl liG GenewPdMe Contractor SUDCorpracor IF RESPONDENT IS A SUB-CONTRACTOR,—COMPLETE THE I=OLLOWING: GENERM. CONTRACTOR'S FULL NAME UCENSE No. ADDRES&NUYBER 6 STREET, C171:3TAT'E, ZIP CODE TELEPHONE NO. PUBLIC AGENCY AWARDING CONTRACT NAME OF PUBUC AGENCY FAVI.� �' L.LT�t3! Tri • CIVIL Cy--rrs,,S P 2A � oom 1 (2 NAME & TME OF CONTACT PERSON OF KNOWN" Ns AAI J6001\)AAD C I (t, --T= oP PUBLIC WORT{ JOB SITE ^""•`�� v^ vzvw+Mru� u1 ^1 r'AN VV PUBUG WORK JOB SITE OAs210(REV.WM) SIA 1-701 TEIEPl10NE i tJM i n115�T2� b� . t PROTECT NAME J (V a l t- d'5 �iG ) 0 A//vL L �` V)14 Q-6 r 4" I C/ CONTRACT��# / 8 ( PUBLIC WORKS COMPLAINT - u�uuJJC1Lt�4 LABORERS SCHOOL Southern Callfbimia Laborers Training School & Apprenticeship Program February 6, 2008 Pierre Weakley Centex for Contract Compliance 1168 E. La Cadena Drive, Suite 202 Riverside, CA- 92501 Re: Apprenticeship requirements for Garcia Juarez - O'Neil Park Sewer Conversion projecj Dear Mr. Weakley, PAGE 02/02 I am. Writing this letter in response to your inquiry regarding the apprenticeship requirements for the above-mentioned contractor/project. r Did the contractor file a D.A.S. 140? XES L� J NO ❑ Did the contractor request dispatch of an apprentice? Should you have any furtber questions, please call me at 626-610-1700. Sincerely, zfMawo Appreatic=Wp Representative Laborers Training School & Apprenticeship YFs ❑ NO Q 1385 West Siem Madre Avenue,, Azusa Ca. 91702 - Phone (626) 6I0-1700 - Fax (67-6) 633-0204 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 (Enclosure C) RICHARD B. ANDRADE, ESQ., CSB N0.075702 ANDRADE & ASSOCIATES A PROFESSIONAL LAW CORPORATION 27101 Puerta Real, Suite 120 Mission Viejo, CA 92691 Telephone: 949-553-1951 Facsimile: 949-553-0655 Attorney for Claimant Garcia Juarez Construction, Inc. CLAIM AGAINST PUBLIC ENTITY GARCIA JUAREZ CONSTRUCTION, INC Claimant, V. GOVERNMENT CODE CLAIM CITY OF RIVERSIDE Respondent. TO THE CLERK, CITY OF RIVERSIDE: Claimant GARCIA JUAREZ CONSTRUCTION, INC. ("GJ") hereby presents its claim pursuant to California Government Code § 910 against the CITY OF RIVERSIDE (hereinafter "CITY") and makes the following statements in support of its claim: 1. Name and address of the Claimant is as follows: Garcia Juarez Construction, Inc., P.O. Box 309, Brea, CA 92822. 2. The address to which Claimant desires response to this claim to be sent is as follows: Richard B. Andrade, Andrade & Associates, 27101 Puerta Real, Suite 120, Mission Viejo, CA 92691, Telephone Number: (949) 553-1951; Facsimile Number: (949) 553-0655. 3. GJ was the successful bidder on the project known as the SEWER PIPELINE CAPACITY IMPROVEMENT AND PALMYRITA AVENUE IMPROVEMENT (the "PROJECT") and in or about September 5, 2007, entered into a written agreement with the GOVERNMENT CODE CLAIM nm AT A\r, A Rrl A II I AD 1:7'Idl1- 'TVA 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 CITY for the construction of the PROJECT. 4. On October 1, 2007 GJ commenced work on the Project and as of March 2008 was at near completion of the Spring Garden- Columbia reach of the Project. GJ was prevented from performing work on the Palmyrita reach due to utility hindrances requiring the redesign of the reach. As a result, GJ was on delay from October 1, 2007 to January 28, 2008, On January 30, 2008, the CITY issued a Stop Work Order to GJ due to GJ's refusal to provide daily certified payroll records. On February 4, 2008, CITY amended its Stop Work Order to allow construction to recommence but advised GJ daily payroll records must be provided at the end of each work day. As a result thereof, GJ has been unable to return to work and the Project has been shut down. 5. The contract between the parties does not obligate the contractor to provide daily certified payroll records. The contract only requires weekly certified payroll records to be produced by the contractor. At all times since commencement of the Project, GJ has complied with the contractual requirement in regards to weekly certified payroll records. 6. During construction of the Spring Garden -Columbia reach of the Project, GJ encountered conditions different than those represented in the contract documents and as a result was delayed in the performance of its work and incurred additional expenses. 6. The redesign of the Palmyrita reach as well as the incorrectly issued Stop Work Order by the City have resulted in delays to the project and entitles GJ to additional contract days of performance as well as additional compensation. 7. On February 22, 2008, the CITY directed GJ to re -commence work on the Project within five (5) working days. On February 27, 2008, GJ complied with the CITY's direction and re -mobilized on the Project. 8. On February 27, 2008, Counsel for the CITY demanded a revised construction schedule showing completion of the Project by March 17, 2008. On February 27, 2008, GJ advised the CITY that the Project could not be completed by March 17, 2008 due to the differing site conditions on the Project as well as owner caused delays. GOVERNMENT CODE CLAIM GIDATA\Garcia Iuare7 24033\City of River6rle\P1dna\C:nveroment r>., r1�im_n1_1 zn4 .4, 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 9. On March 4, 2008, the CITY unilaterally terminated the contract with GJ and has required GJ's surety to complete performance of the Project. 10. The termination of the contract by the CITY was improper and was a breach of the contract between the parties. 11. As a result of the improper termination by the CITY, GJ has suffered damages including $300,000.00 of earned and unpaid work under the contract; $250,000.00 of extra work performed and unpaid for under the contract; $350,000.00 of lost profits; costs incurred by GJ's surety in an amount in excess of $500,000.00; and impairment to GJ's bonding line and resulting loss of business/profit in excess of $3,000,000.00. 12. The name of the individuals causing claimant's damages are Ms. Siobhan Foster, Public Works Director, Mr. Sean Gill, Contracts Administer, and Mr. Daniel Simmons, Resident Engineer for the City. 13. The claim as of this date is in an amount in excess of $10,000.00, and will place this action within the jurisdiction of the Superior Court, Dated: March 17, 2008 al ANDRADE & ACSSOCIATES RICHAUJ! ANDRADE I -- Attorneys Attorneys for Claimant GARCIA JUAREZ CONSTRUCTION, INC. GOVERNMENT CODE GADATA\Garcia Juarez 24033\City of RiversideTIdne\Government Code C1aim-03-17-OR rine 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 PROOF OF SERVICE STATE OF CALIFORNIA, COUNTY OF ORANGE I am employed in the County of Orange, State of California. I am over the age of 18 years and not party to this action. My business address is 27101 Puerta Real, Suite 120, Mission Viejo, CA 92691. On March 18, 2008, I served the following document(s): GOVERNMENT CODE CLAIM on the interested parties in this action as follows and by the method listed below: Jim Jackson Garcia Juarez Construction, Inc. P.O. Box 309 Brea, CA 92822 David Hughes Attorney for The Guarantee America USA dlhughes()boothmitchel.com Jan Swaney The Swaney Corporation tsc@ix.netcom.com Company of North City of Riverside 3900 Main Street Riverside, CA 92522 Siobhan Foster City of Riverside sfoster e riversideca.gov Sean Gill City of Riverside sgi l K4iversideca.g_ov Theodore L. Senet Attorney for City of Riverside tsenet(ag Ig t.com XX (Service by Mail) I caused such envelope, with postage thereon, fully prepaid, to be placed for deposit at 27101 Puerta Real, Suite 120, Mission Viejo, CA 92691, in the United States Postal Service. I am familiar with the regular mail collection and processing practices of Andrade & Associates that the mail would be deposited with the United States Postal Service that same day in the ordinary course of business, and that the envelope was sealed and deposited for collection and mailing on the above date following ordinary business practices. (Service by overnight delivery) I caused such envelope to be placed for deposit at 27101 Puerta Real, Suite 120, Mission Viejo, CA 92691. I am familiar with the overnight delivery collection and processing practices of Andrade & Associates that the mail would be deposited with an overnight delivery service that same day in the ordinary course of business, and that the envelope was sealed and deposited for collection and mailing on the above date following ordinary business practices. — (Personal Service) I caused such envelope to be delivered by hand to the addressee(s). — (Via Facsimile) By faxing copies to the person(s) and fax numbers listed above named. X (Via E -Mail) By sending copies to the person(s) indicated at the e-mail address listed above. X (STATE) I declare under penalty of perjury, under the laws of the State of California and the United States of America, that the foregoing is true and correct. GOVERNMENT CODE CLAIM (i•\hATA\r' r io I-- 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 (FEDERAL) I declare that I am employed in the office of a member of the bar of this Court at whose direction the service was made. I declare under penalty of perjury under the laws of the correct. Executed March 18, 2008 at Mission Viejo, Ca GOVERNMENT CODE CLAIM ina (Enclosure D) SETTLEMENT AGREEMENT AND RELEASE This Settlement Agreement and Release ("Agreement") is entered into as of the Effective Date ('Effective Date" is defined below at paragraph 21), by and between GARCIA JUAREZ CONSTRUCTION, INC. ("Garcia") and CITY OF COMPTON, ("Compton"); all of which shall sometimes collectively be referred to as 'Parties" and individually as "Party". RECITALS WHEREAS, on January 3, 2007, Garcia commenced an action in the Superior Court of the State of California, County of Los Angeles, entitled Garcia Juarez Construction, Inc. v. City of Compton, and designated Case Number TCO20649 (the "Action"), arising out of an alleged breach of contract. WHEREAS, Garcia's claim was that that Compton wrongfully terminated the contract. WHEREAS, on February 13, 2007, Compton filed an answer denying Garcia's allegations in the complaint and filed a Cross -Complaint for breach of contract (the "Cross -Action") against Garcia. WHEREAS, Compton claims that Garcia breached the contract and therefore Compton's termination of the contract was justified. WHEREAS, the Parties each dispute the contentions and allegations of the other Party. NOW, THEREFORE, the Parties desire to settle certain of their disputes on the following terms and conditions. Settlement Agreement Page 1 of 7 AGREEMENT Wherefore, in consideration of the promises, the mutual obligation and undertaking set forth hereinunder, and other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged by the Parties, the Parties agree to settle their disputes, as follows: 1. Within thirty (30) days of execution of this Agreement by either party, Compton shall pay Garcia Ninety -Five Thousand and .00/100 dollars ($95,000.00). Said payment shall be made payable to Andrade & Associates in Trust for Garcia and mailed directly to Andrade & Associates, 27101 Puerta Real, Suite 120, Mission Viejo, CA 92691-8518. 2. Immediately upon execution of this Agreement, Compton shall cause the termination of the contract between the parties to be changed from "for cause" to a "for convenience" termination. Upon any inquiry from, including but not limited to, another public agency, union, contractor, individual, private entity, etc., Compton shall ONLY disclose that the contract with Garcia was terminated "for convenience" and nothing more. 3. Garcia, and its related companies, agree not to do any future business with Compton. The contract between Compton and Onsite Krushing Co., a copy of which is attached hereto as Exhibit "A", is hereby mutually terminated by and between Compton and Garcia's related company Onsite Krushing Co. 4. When all terms and conditions required under this Agreement have been completed and/or performed, Garcia and Compton shall cause the within Action and the Cross -Action to be dismissed in their entirety with prejudice. 5. This Agreement affects a compromise and settlement of disputed and contested claims, and nothing contained in this agreement is intended to or shall be Settlement Agreement Page 2 of 7 construed as an admission or acknowledgment of the validity of any allegation, claim, assertion, defense, demand or any other matter claimed or asserted by Garcia or Compton. 6. Except as otherwise expressly stated in this Agreement, and subject to performance of their respective obligations under this Agreement, the Parties hereby release and forever discharge each other, and their agents, servants, employees, representatives, assigns, heirs, successors in interest, predecessors in interest, administrators, adjusters, attorneys, accountants, insurers and bond companies, from any and all claims, demands, causes of action, obligations, damages and liabilities of any nature whatsoever between the Parties hereto. 7. The Parties hereto acknowledge that upon execution of this Agreement by all Parties, this Agreement shall be effective as a full and final accord and satisfaction, waiver, relinquishment and settlement of, and as a bar to, the claims, demands, damages, debts, accountings, reckonings, liabilities, obligations, costs, expenses, liens, actions, and causes of action, heretofore referred to and released, which any Party hereto has, may have in the future, or has had against any other Party hereto. Each of the Parties hereto acknowledges that it is aware that it or its attorney may hereafter discover facts different from or in addition to the facts which it or its attorney now knows or believes to be true with respect to the claims which are being released by this Agreement, but that in signing this Agreement, each Party hereto intends thereby to fully, finally, absolutely and forever settle the claims waived by the Parties herein, and that in furtherance of such intention, the mutual releases herein given shall be and remain in effect as full and complete releases notwithstanding the discovery of any such difference or additional facts concerning the claims referred to above. Settlement Agreement Page 3 of 7 8. Each of the Parties hereto acknowledge that it has been informed by its attorneys and advisors or, and that it is familiar with, Section 1542 of the Civil Code of the State of California, which provides as follows: "A GENERAL RELEASE DOES NOT EXTEND TO CLAIMS WHICH THE CREDITOR DOES NOT KNOW OR SUSPECT TO EXIST IN HIS FAVOR AT THE TIME OF EXECUTING THE RELEASE, WHICH IF KNOWN BY HIM MUST HAVE MATERIALLY AFFECTED HIS SETTLEMENT WITH THE DEBTOR." Each of the Parties hereto does hereby waive and relinquish all rights and benefits he has or may have under Section 1542 of the Civil Code of the State of California to the full extent that it may lawfully waive all such rights and benefits pertaining to the subject matters of this Agreement. 9. The Parties to this Agreement agree that they will execute any and all further and additional documents and take all further and additional steps which may be necessary or convenient to consummate this Agreement and accomplish the purposes thereof. 10. This Agreement contains the entire agreement of the Parties, and no representations, warranties, inducements or promises not included herein by express provision or contained in a document or instrument identified herein and executed contemporaneously herewith shall be binding on any Party hereto. 11. This Agreement may be executed and delivered in counter parts, each of which shall constitute an original and all of which together shall constitute one in the same agreement. 12. This Agreement is made pursuant to, and shall be governed by and construed in accordance with the laws of the State of California. Settlement Agreement Page 4 of 7 13. Each party to this Agreement represents and warrants to each of the other parties that he, she, or it, and the person signing this Agreement on his, her, or its behalf, has the capacity and authority to execute this Agreement. 14. Each party to bear its own costs and attorneys' fees to date. 15. In the event it is necessary to initiate litigation to enforce the terms/conditions of this agreement, the prevailing party shall be entitled to recover reasonable attorney's fees and costs of litigation. 16. Specific Performance And Defense To Future Actions. The obligations and covenants set forth in this Agreement may be specifically enforced by any Party. This Agreement may be pled as a full and complete defense to any and all claims and causes of action being released. Further: a. Pursuant to Evidence Code Sections 1123(a) and (b), this Agreement is enforceable, binding and admissible in a court of law. b. Pursuant to Code of Civil Procedure Section 664.6, the court shall retain jurisdiction over the Parties to enforce this Agreement until performance in full of the terms of the settlement. 17. Negotiation and Advice of Counsel. Each Party acknowledges that it has had a full opportunity both to negotiate the terms of this Agreement and to obtain legal advice from an attorney of its choosing regarding this Agreement and the advisability of entering into this Agreement. Each Parry represents that it has either knowingly decided to execute this Agreement based on advice of counsel or has knowingly decided to waive its right to counsel and execute this Agreement without such advice. Settlement Agreement Page 5 of 7 18. Preparation of the Agreement. This Agreement shall be deemed to have been prepared jointly by the Parties, and the usual rule that the provisions of a document are to be construed against the drafter shall not apply. 19. Voluntary Agreement. The Parties have executed this Agreement freely and voluntarily, and with full knowledge of its significance and without inducements, promises or representations made by the other Parry or Parties, except as set forth in this Agreement. 20. Waiver. No provision hereof may be waived unless in writing signed by the Party to be charged with the waiver. Waiver of any one provision herein shall not be deemed to be a waiver of any other provision herein. 21. Effective Date of Agreement. This Agreement shall be effective as of the date of execution of this Agreement by all of the Parties hereto ("Effective Date") and shall be effective as to any Party when signed by such Party hereto. 22. Read and Understand. The Parties have read and fully understand the terms, conditions, and provisions of this Agreement. THE UNDERSIGNED PARTIES HEREBY AGREE that their agreement hereto is evidenced by their signatures on the dates set forth below: CITY OF COMPTON Dated: By: KAMBIZ SHOGHI, General Manager GARCIA JUAREZ CONSTRUCTION, INC. Dated: By: JIM JACKSON, President Settlement Agreement Page 6 of 7 APPROVED AS TO FORM: Dated: Dated: CITY OF COMPTON M. EDWARD CHAVEZ, Esq. Attorney for CITY OF COMPTON ANDRADE & ASSOCIATES, APLC By: RICHARD B. ANDRADE, Esq. Attorney for Garcia Juarez Construction, Inc. Settlement Agreement Page 7 of 7 (Enclosure E) Rev 4/15/08 GARCIA IUAREZ CONS?"RUCTION INC. Contract References City of Anaheim, $2,270,000 (In Progress) "Anaheim Hills Road Transmission Main" Mr. Manny Briones (949) 466-6701 Mr. John Lamar (714) 863-8020 City of Ontario, $1,340,000 (In Progress) "Recycled Water Pipeline Project" Mr. Franz Guardia (909) 395-2689 County of Orange, $6,153,000 "O'Neill Park Sewer Conversion" Mr. Rick Allen (714) 448-8552 City of Anaheim, $1,0200,000 "Lincoln Avenue Sewer" Mr, Jay Kalan (714) 369-2081 Mr. Sean Razmy (714) 765-5059 Los Angeles County Dept. of Public Works, $180,000 "CMP Replacement Project" Mr. Jose Ontiveros (909) 319-8627 City of Rosemead, $750,000 "Street, Storm Drain, and Street Lighting" Mr. Tom Harbour (417) 770-2898 City of Fullerton, $2,000,000 "Lemon — Rosslynn Sewer" Mr. Eliseo Bravo (714) 932-7506 Mr. Murdock Miralaie (714) 595-6720 City of Rancho Palos Verdes, $400,000 "Forrestal Swale Drainage Improvements" Ms. Bindu Vaish (310) 544-5254 Mr. Jim Pugh (805) 602-0891 City of Huntington Beach, $4,640,0000 "OC -9 Water Transmission Main" Mr. Dave Verone (714) 375-8471 Mr. Mike Hitt (714) 292-2140 Rev 4/15/08 Los Angeles County Dept. of Public Works, $450,000 "Ditman Avenue Storm Drain" Mr. Johnny Oghoorian (626) 712-4820 Western Municipal Water District, $480,000 "Wood Road Irrigation Pipeline" Mr. Greg Alexander (951) 712-6566 Golden Rain Foundation, $140,000 "Perimeter Wall Project, Section G&H" Mr. Carlos Martinez (562) 431-6586 (#371) City of San Clemente, $1,040,000 "Calle Las Bolas Storm Drain" Mr. Gary Voborsky (949) 279-9730 Los Angeles County Dept. of Public Works, $500,000 "112"' Street Replacement" Mr. Joe Baker (562) 405-5715 City of Huntington Beach, $230,000 "Residential Storm Drain" Mr. Jeff Gibbons (714) 401-5008 City of Palos Verdes Estates, $80,000 "Beach Club Access Retaining Wall" Mr. Jim Pugh (805) 602-0891 Los Angeles County Dept. of Public Works, $2,150,000 "Kenneth Hahn Storm Drain" Mr. Mark Buschard (626) 458-3104 County of Orange, $190,000 "Federal Storm Channel" Mr. Rick Allen (714) 448-8552 Los Angeles County Dept. of Public Works, $180,000 "Private Drain 996 (Victoria St.)" Mr. Rene Bracamontes (310) 487-9254 CITYOFIZgf`ICHO PALOS VERDES PUBLIC WORKS DEPARTMENT March 14, 2007 Jim Jackson Garcia Juarez Construction, Inc. P.O. Box 309 Brea, CA 92822-0309 RE: Forrestal Swale Improvement Project. Dear Mr. Jackson: Forrestal swale improvement project was completed satisfactorily, and the City council has accepted the project as completed on February 20, 2007. On behalf of the Public Works Department of Rancho Palos Verdes I would like to thank you and offer our appreciation for the excellent job on this Project. Your company completed the project on schedule, within authorized amount, in a professional manner. It has been our pleasure to work with you and your employees, those in the field and in your office. We find to be very competent, professional and responsive. I hope you will continue to work on our City's projects and provide services as you have provided on this project. Please feel free to use the City of Rancho Palos Verdes as a reference. I can be reached at 310/544-5252 or via e-mail at binduv(aD-rpv.com. Sincerely, Bindu Vaish Project Manager xc: Jim Bell, Director of Public Works 30940 HAWTHORNE BLVD. / RANCHO PALOS VERDES, CA 90275-5391 PI IRI Ir WnpieQ /dim inn-G9G9 i nnDT GAY MiM Fnn.GoOo Garcia Juarez Construction, Inc. From: Jacobs, Yvonne [JACOBSY@valassis.com] Sent: Monday, June 12, 2006 3:10 PM To: garciajuarez@verizon.net Subject: Newland Street Construction Hello Todd, Just a quick note to saythaw for the GREAT job your company has done in the construction process for Newland Street. Being a resident who lives on Newland (between Talbert & Slater) — I have seen your workers for several months now. They go in — do their job — post signs and place cones for easy maneuvering — and get out — after a good cleaning up! It has been a smooth process from where I sit. I just thought you should know that I for one appreciate your work process. Keep up the nice job! O Yvonne Jacobs 8471 EI Arroyo Drive Huntington Beach, CA 92647 Tel 714.918.5208 Fax 714.979.4194 Office Hours: 8:00am to 4:30pm PST This message may include proprietary or protected information. If you are not the intended recipient, please notify me, delete this message, and do not further communicate the information contained herein without my express written consent. No virus found in this incoming message. Checked by AVG Free Edition. Version: 7.1.394 / Virus Database: 268.8.3/361 - Release Date: 6/11/2006 January 3, 2006 File: EF27694 Jim Jackson Garcia Juarez Construction Inc. P.O. Box 309 Brea, CA 92822-0309 Dear Mr. Jackson: I would like to thank you for a job well done on the construction of the emergency repairs to Federal Storm Channel. The work was performed in a quick and professional manner and your company was easy to deal with when changes had to be made. I look forward to working with you again on future projects. Sincerely, a cKinn y, Resident E eer RDMD/Construction Division CONSTRUCTION DIVISION MAILING ADDRESS: TELEPHONE: 1152 E. FRUIT STREET P.O. BOX 4048 (714) 567-7800 SANTA ANA, CALIFORNIA SANTA ANA, CA 92702-4048 FAX # 567-7813 Bryan Speegle, Director $,t�I =' 0 300 N. Flower Street Santa Ana, CA COUNTY OF ORANGE P.O. Box 4048 U t'y Santa Ana, CA 92702-4048 RESOURCES & DEVELOPMENT MANAGEMENT DEPARTMENT C>� �LIFpg Telephone: (714) 834-2300 Fax: (714) 834-5188 January 3, 2006 File: EF27694 Jim Jackson Garcia Juarez Construction Inc. P.O. Box 309 Brea, CA 92822-0309 Dear Mr. Jackson: I would like to thank you for a job well done on the construction of the emergency repairs to Federal Storm Channel. The work was performed in a quick and professional manner and your company was easy to deal with when changes had to be made. I look forward to working with you again on future projects. Sincerely, a cKinn y, Resident E eer RDMD/Construction Division CONSTRUCTION DIVISION MAILING ADDRESS: TELEPHONE: 1152 E. FRUIT STREET P.O. BOX 4048 (714) 567-7800 SANTA ANA, CALIFORNIA SANTA ANA, CA 92702-4048 FAX # 567-7813 PHONE (310) 639-9800 FAX (310) 639-2454 E-mail: harborbiz@aol.com December 6, 2005 Cts URNSPORTERS. INC. jransCargo, Inc. Garcia Juarez Construction, Inc. P.O. Box 309 Brea, CA 92822 Attention: Mr. Jim Jackson Reference: Victoria Street Closure Dear Mr. Jackson, P.O. Box 20398 Long Beach, California 90801 It is my understanding that the street was closed due to the construction of a storm drain for the Los Angeles Department of Public Works. On behalf of CP Transporters, Inc., we would like to thank your firm for your cooperation and prompt completion of the street closure_. , As you may be aware, our company requires continual road access. Any closure, even if only near by, can create a hardship for us. Throughout the duration of the project, your crews worked in close proximity to our business and were able to mitigate the potential for such hardships. We were really impressed with the neatness and completion of this project ahead of the posted scheduled time. Sincerely, inares eneral Manger TDAAIQI nAn AKIn MQDATnL! nCCIP`C. 7rIRA C \lin+nrin C+r + Dnnnhn Ilnminni�n� r`nlifnrnin 0 4ERP4 CITY OF 1�(4akc;(4 w V INCORPORATED 1839 c9L1 F000, November 17, 2005 Jim Jackson Garcia Juarez Construction, Inc. P.O. Box 309 Brea, CA 92822-0309 RE: Structural Engineer's Final Observation Report Malaga Cove Beach Access Road Retaining Wall Project Dear Mr. Jackson: I have enclosed Melvyn Green and Associates' final observation report for this project. It is satisfactory, and the City Council will accept the project at its December 13 meeting. On behalf of the Public Works Department I would like to thank you and offer our appreciation for Garcia Juarez Construction's fine job on the Malaga Cove Beach Access Road Retaining Wall Project. Your field crews completed the project as a team effort in a timely, professional manner, without punch list requirements and without resident complaints. It has been a pleasure interacting with your employees, those in the field and in your offices, who we feel are entirely professional, responsive, and very capable. Please be sure to let them know. Garcia Juarez will be on our contact list for future City concrete work, and I hope that you continue to bid on our projects. We look forward to working with your company again. Please feel free to use the City of Palos Verdes Estates as a reference. I can be reached at (310) 378-0383. Sincerely, Floriza Rivera Public Works Department Cc: Allan Rigg, Director of Public Works PW 502-05 MELVYN GREEN AND ASSOCIATES INC. Re: Completion of Beach Retaining Wall Dear Mr. Rigg: This letter will serve as our final observation report for the project noted above. Our previous field observation report noted that the wall work was essentially in conformance with the construction documents prepared by our office. We have reviewed the twenty-eight day concrete strength tests. Our findings are that the concrete has met the design strength requirements. Our recommendation is that you accept the project. Yours truly, �G- Me vyn Green Structural Engineer 21311 Hawthorne Boulevard STE 220 Torrance California 90503 IT 310. 792. 9252 FAX 310. 792. 8092 www.mgreenassoc.com November 13, 2005 Structural Engineering Architectural Mr. Alan Rigg Preservation Director of Public Works . City of Palos Verdes Estates Materials 340 Palos Verdes Drive West Conservation Palos Verdes Estates, CA 90274 Re: Completion of Beach Retaining Wall Dear Mr. Rigg: This letter will serve as our final observation report for the project noted above. Our previous field observation report noted that the wall work was essentially in conformance with the construction documents prepared by our office. We have reviewed the twenty-eight day concrete strength tests. Our findings are that the concrete has met the design strength requirements. Our recommendation is that you accept the project. Yours truly, �G- Me vyn Green Structural Engineer 21311 Hawthorne Boulevard STE 220 Torrance California 90503 IT 310. 792. 9252 FAX 310. 792. 8092 www.mgreenassoc.com Y �J11111� PALOS VERDES y A T H L E j\ September 26, 2005 City of PVE Mr, Allan Rigg Public Works Director 340 Palos Verdes Drive West Palos Verdes Estates, Ca. 90274 Dear Allan, On behalf of the Palos Verdes Beach Club I want to express our appreciation to you and the City for the fine work that is being done on the emergency service road. I am well aware that additional work has been done that will ensure the integrity of the slope to the outside of the Club's property. The workmanship has been top quality and the company hired to do the work has been very easy to work with during our hours of operation. Again, I want to thank the City for their cooperation in helping maintain this PVE "Jewel" by the Sea. est regards, anie Williamson Manager P.O. BOX 158 • PALOS VERDES ESTATES • CA •' 90274 � � � � � B RR g I �COXCASTLE NICHOLSON 0- T 1 April 10, 2008 VIA OVERNITE EXPRESS Jerry Amante, Mayor City of Tustin 300 Centennial Way Tustin, CA 92780 Lou Bone, Councilmember City of Tustin 300 Centennial Way Tustin, CA 92780 Jim Palmer, Councilmember City of Tustin 300 Centennial Way Tustin, CA 92780 Cox, Castle & Nicholson LLP 2049 Century Park East, 28d' Floor Los Angeles, California 90067-3284 P 310.277.4222 F 310.277.7889 Dwayne P. McKenzie 310.284.2279 dmckenzie@coxcastic.com 1 File No. 18316 Doug Davert, Mayor Pro Tem City of Tustin 300 Centennial Way Tustin, CA 92780 Tony Kawashima, Councilmember City of Tustin 300 Centennial Way Tustin, CA 92780 Re: Protest of Award of the Sycamore Ave. Storm Drain Project to Garcia Juarez Construction Dear Mayor Amante and Council Members: Our firm represents the Center for Contract Compliance (the "CCC" or "Center"), a joint labor-management committee established pursuant to the Labor Management Cooperation Act of 1978. The CCC is concerned with maintaining a level playing field for contractors and workers on public works and therefore seeks to further compliance with the Prevailing Wage Law, California Labor Code Sections 1720, et seq. The Center routinely monitors bids, awards, and construction activities, and also reviews payroll records, inspectors' logs, and interviews workers to ascertain compliance with the Prevailing Wage Law. The Center works closely with awarding agencies, enforcement agencies, contractors, and other interested parties to achieve these goals. The Center is informed that Garcia Juarez Construction ("GJC") is the apparent low bidder on the Sycamore Ave. Storm Drain project ("Project"). The Center believes that GJC and its principals have a substantial history of non-compliance with public bidding and public works laws and has demonstrated repeated poor performance on public works construction for other public agencies, resulting in termination of GJC contracts, disbarment and litigation. www.coxcastle.com Los Angeles ( Orange County I San Francisco Mayor Amante and Council Members April 10, 2008 Page 2 Accordingly, the Center asks that the City of Tustin ("City") reject the bid of GJC and declare GJC a non -responsible bidder. In the alternative, the Center would strongly urge that the City re- bid the Project and conduct further investigation into the practices of GJC. To aid the City in its determination, the Center offers the following information regarding GJC: 1. Debarment of GJC Principals by the City of San Diego and Subsequent Attempts by GJC Principals to Circumvent the Debarment. The Center is informed that the president of GJC is Mr. James "Jim" Jackson. The Center has reviewed the past conduct of Mr. Jackson as an officer of Southern California Underground and found that the City of San Diego has permanently debarred the company and its officers, including Mr. Jackson and Mr. George Frost, under the San Diego Municipal Code, Section 22.801, from performing any public works projects for the City of San Diego. The City of San Diego found the company and its officers engaged in corrupt practices while administering public works contracts in the City. Enclosed as Exhibit 1 are copies of the City of San Diego's Manager's Report, dated May 20, 2004, and copies of the relevant portions of the city minutes approving the permanent debarment of Southern California Underground and Mr. Jackson. Also enclosed as Exhibit 2 for your review is a copy of the decision in Southern California Underground Contractors, Inc. v. City of San Diego, 108 Cal.App.4th 533 (2003), which on the third page discusses the debarment of Southern California Underground for "a pattern of willful acts of corruption and deception, unethical and unacceptable business practices, and inadequate contract performance on numerous public works contracts with [the City of San Diego]." The City of San Diego also took action against J.G. Pipeline, a company established and operated by Mr. Frost and Mr. Jackson only days after the initial debarment of Southern California Underground to circumvent the debarment and permit them to continue to bid and perform pipeline work in San Diego. J.G. Pipeline was set up under the name of Mr. Frost's sister-in-law and was essentially a continuation of the operations of Southern California Underground. After a lengthy and extensive analysis of the continued operation of Southern California Underground as J.G. Pipeline, the Manager's Report to the City of San Diego, dated June 7, 2001, concluded that "The totality of the information... indicates a willful effort on the part of SoCal/J.G. to circumvent the permanent disbarment mandated by the City Council. Such corrupt practices violate in letter and spirit the principles of "responsible" bidding and are prohibited by law." A following Manager's Report further concluded, "SoCal and J.G. have committed and continue their corrupt practices. Swift and permanent debarment of J.G. is necessary to protect the health and safety of the citizenry, the full and open competition, namely the integrity of our bidding system, granting contract awards only to responsible contractors." (Copies of these Manager's Reports are enclosed as Exhibit 3.) The same individuals responsible for the "corrupt practices" of Southern California Underground and J.G. Pipeline now continue to operate under the banner of GJC. As Mayor Amante and Council Members April 10, 2008 Page 3 GJC, they have failed to disclose, in effect concealing, to awarding agencies the debarments by the City of San Diego. The Center has also obtained bid documents submitted by GJC and signed by Mr. Jackson on a number of public works projects. A bid dated February 2, 2005, was submitted to the City of Brea. The Disqualification Questionnaire form asked, "if any officer of the bidder or any employee of the bidder who has proprietary interest in the bids has ever been disqualified, removed or otherwise prevented from bidding on or completing a federal, state, or local government project because of a violation of law or safety regulations." Despite the action by the City of San Diego, Mr. Jackson provided a "NO" response. (Enclosed as Exhibit 4 is a copy of this document.) The Center also received bid documents submitted to the City of Yorba Linda. The documents asked the contractor to list all other dba's prior and current. GJC's response was "NONE." Also on page 5, GJC was required to list their references. However, the references listed were not those of Garcia Juarez Construction but, instead, were references of Southern California Underground. Copies of these documents are also enclosed as Exhibit 4. 2. Potential GJC Violations Of Apprenticeship Requirements On Public Works. The Division of Apprenticeship Standards has notified GJC of complaints of apprenticeship violations on two public works jobs: Wood Road Irrigation Pipeline Agency Western Municipal Water District in Riverside and the Calle Bolas Storm Drain Improvements Agency in the City of San Clemente. In addition, the Southern California Laborers Training School has indicated that GJC did not request dispatch of apprentices on the O'Neill Regional Park Sewer Conversion project for the Orange County Board of the Supervisors, the total contract for which is estimated at $6,243,690. Similarly on the City of Anaheim's Citywide Sanitary Sewer Improvement project, GJC did not request a dispatch of apprentices and did not submit DAS-140 forms to the Southern California Labors Training School and Apprenticeship Program. (Documents reflecting all of the foregoing are enclosed as Exhibit 5.) Finally, the Center is informed that laborers on the City of Anaheim project were paid Group 1 labor rates instead of the proper Group 4 laborers rate for pipe layers, a potential violation of the Prevailing Wage Law (Cal. Lab. Code §§ 1720, et seq.). 3. GJC Performance Issues On The Sewer Pipeline Capacity Improvements Project For The City Of Riverside The Center has reviewed the Inspector's logs for the Sewer Pipeline Capacity Improvements Project for the City of Riverside, including certified payroll records provided by GJC. The Center is informed this project is currently ongoing although GJC's performance has Mayor Amante and Council Members April 10, 2008 Page 4 been terminated (please see below). These documents (copies of which are enclosed as Exhibit 6) reflect numerous GJC performance issues and potential public works law violations. a. On January 30, 2008, Riverside Inspector Anthony Allen had contact with Garcia Juarez foreman Ruben Mendoza. Mr. Mendoza told the inspector that they would not be working on the laterals that needed to be replaced according to the City standards. Mr. Mendoza also informed the Inspector they would not be providing any more lists of laborers on the site. The Inspector informed GJC that if the names were not provided, the superintendent would be required to provide a list of names each day. The Inspector thereafter spoke to Mr. Jackson by phone, and after a heated debate, the Inspector issued correction notices, including a notice requiring proof of proper disposal of asbestos pipe. While the Inspector was completing these documents, George Frost arrived at the site.I The Inspector reported that Mr. Frost "began an attack both verbally and physically on the Inspector." The Inspector warned Mr. Frost that if he touched him again, he would forcefully restrain him. Mr. Frost was told to move away and when he refused, the Inspector called 911. Mr. Frost left the site before the police arrived. GJC then threatened to leave the worksite in an unsafe condition until they were informed that if they did not finish certain guardrail safety work, city forces would be used at GJC's expense. b. GJC has an extensive history of change orders on the Sewer Pipeline Capacity Improvements Project. As the July 16, 2 Manager's Report (Exhibit 3, at p. 9) states, a contractor which routinely underbids on public works, like J.G.Pipeline had, either "loses money, uses shoddy materials, or seeks numerous change orders with exorbitant change order pricing." The following are GJC change orders on the Sewer Pipeline Capacity Improvements Project and the status reported to the Center: • NOPC- 1 Amount: $1,142.92 for Cal Trans permit fee. Denied. • NOPC-2 Amount: $8,000 for the reason the crew prolonged work due to utilities not anticipated. Denied. • NOPC-3 Amount: No amount shown. Denied. • NOPC-4 Amount: $3,000 because the "Crew incurred 4 hrs of extra work due to conditions beyond the control of the contractor." Denied. • NOPC- 5 Amount: $4,000 for proposed trench line that is outside of the original scope of work. Denied. • NOPC-6 Amount: $2,000 per day for trench line that is caving in. Denied. Although the current role of Mr. Frost on behalf of GJC is unknown, the Inspector's Logs clearly indicate Mr. Frost acted in a representative capacity for GJC. Mayor Amante and Council Members April 10, 2008 Page 5 • NOPC-8 Amount: $10,000 for night work. Denied. • NOPC-9 Amount: $6,000 for water line work. Denied. • NOPC-10 Amount $6.000 for excavation around AT&T Boxes. Denied. • NOPC-11 Amount $6,000 for excavation around AT&T Boxes. Denied. • NOPC-12 Amount $4,000 for excavation around AT&T Boxes. Denied. • NOPC-13 Amount $5,000 to preserve and protect conduit. Denied. • NOPC-16 Amount $8,000 for reimbursement of temporary asphalt. Denied. • NOPC-17 Amount: No amount shown for unknown conduit. • NOPC-18 Amount: No amount shown for project delay. • NOPC-19 Amount $3,000 per day for work stoppage related to events of January 30, 2008 (detailed above). Denied. C. The City of Riverside Daily Construction Log Reports and the certified payroll records submitted by GJC indicate that GJC routinely under -reports workers on its certified payroll records. The experience of the Center is that contractors who seek to avoid prevailing wage obligations often do so by failing to report workers on their certified payroll records and paying unreported workers less than the required rate of prevailing wages. On the Sewer Pipeline Capacity Improvements Project, GJC has underreported 88 man -days. Enclosed as Exhibit 7 is a spreadsheet summarizing GJC's under -reporting as represented by GJC's certified payroll records and the daily reports on the project. d. In addition to under -reporting of workers, the City of Riverside inspector noted in his Daily Construction Log Reports the following performance issues with GJC: • 10-10-07: GJC claiming extra work for potholing. • 10-16-07: Noted conflict with Jim Jackson regarding permission to conduct street grinding. GJC indicated it would grind street regardless of Inspector instructions. 10-26-07: GJC was not backfilling and compacting a trench according to contract specifications, in that they are not completing the compaction operation by the end of each work day. Forms were not completed when concrete arrived and therefore part was roughly hand troweled. Possible over mixing may have occurred. Despite being forewarned to be out of the roadway by 3:30 p.m., GJC only completed work clearing equipment out of the roadway by 4:10 p.m. GJC Mayor Amante and Council Members April 10, 2008 Page 6 closed E. La Cadena Ave. with heavy equipment in contradiction of the traffic control plan. 10-29-07: Logs indicates names of GJC personnel are questionable. The contractor was still not backfilling and compacting the trench according to contract specifications. Manhole rings are not according to City specifications and is unauthorized work. GJC instructed to support and protect in place the existing transverse sewer line as this was not being done during excavation. • 11-19-07 toll -20-07: City Engineer did not accept 24" pipe join being more than 1" outside of manhole. GJC broke a waterline. City Emergency Services was contacted, and work was halted. • 11-20-07 to 11-21-07: GJC was issued a correction notice for failure to produce a welder's certification. • 11-25-07 to 11-26-07: GJC issued a correction notice for failing to produce a flagger's certification. GJC thereafter provided incomplete certification. • 12-2-07 to 12-03-07: GJC was issued a correction notice to furnish an approved traffic control plan. • 12-3-07 to 12-4-07: Jim Jackson attempted to have inspector sign for apparent extra work done without approval by the city. • 12-4-07 to 12-5-07: GJC was notified that the excavation for a manhole exceeded the standard limits and that a solution was to be obtained before 3:00 a.m. or the excavation would be required to be backfilled and compacted for traffic safety by 5:00 a.m. GJC instead used steel plating. GJC was notified that GJC would be responsible for public safety, and 24-hour monitoring was required. • 12-11-07 to 12-12-07: GJC failed to provide engineering drawings to show that the plates spanning the excavation was structurally sound and safe and was, therefore, issued a correction notice to immediately make the site safe. 12-12-07 to 12-13-07: GJC was issued a correction notice for trenching shoring and truck bed covering of the excavated materials loaded. • 12-16-07 to 12-17-08: GJC was issued a correction notice to use correctly equipped flagmen when crossing a roadway open to the public. GJC was also issued a correction notice to correctly repair a lateral sewer line broken during excavation operation and to follow the correct spill procedure in order to prevent contamination. Mayor Amante and Council Members April 10, 2008 Page 7 1-8-08: GJC was given various correction notices for: (1) failing to obtain approval for materials used for lateral connections, (2) needing to obtain approvals for materials integrated on Roadway work (3) improper work hours, and (4) using Band Seals (Rubber Couplers) for lateral connections despite being instructed in previous correspondence not to use such materials. • 1-9-08 to 1-10-08: GJC was given various correction notices for non -conforming catch basins and not submitting impact reports. 4. Termination Of The Sewer Pipeline Capacity Improvements Project For The City Of Riverside Recently, on March 4, 2008, the City of Riverside terminated performance of the Riverside Project by GJC for many of the above performance issues, citing GJC's: • Abandonment of the work for one month without just cause, • Failure to re -mobilize and re -man the project, • Material failures in performance, and • Project delays jeopardizing other City of Riverside projects. Enclosed as Exhibit 8 are copies of the City of Riverside's proposed Resolution terminating GJC's performance and the March 4, 2008, Riverside City Counsel Memorandum regarding the authorization to terminate GJC's performance of the Riverside Project. The latter further details the many performance failures of GJC, including: • GJC's repeated efforts to use improper or unacceptable materials on the Riverside Project, • Erroneous requests for additional materials for time and materials work, • Failure to perform work with the agency's representatives as required under the contract, • Failure to provide reasonable and justifiable costs for sewer redesign issues, • Failure to provide correct Certified Payroll records, • Failure to provide worker information to allow confirmation of Certified Payroll record accuracy, and Mayor Amante and Council Members April 10, 2008 Page 8 • GJC's request to add a subcontractor despite GJC's statement before the City Council that no subcontractors would be utilized on the project. Also enclosed for your review is a Memorandum from the Riverside City Attorney concerning closed session consideration of litigation between the City of Riverside and GJC. 5. City of Compton Litigation Against GJC. The City of Compton has filed a cross-complaint against GJC for breach of contract and breach of the implied covenant of good faith and fair dealing arising out of alleged non-performance by GJC. (Enclosed as Exhibit 9 is a copy of the cross-complaint.) The cross-complaint alleges that in a September 21, 2006 pre -construction meeting on the Construction of Tucker Street Water Distribution Pipeline and Well Discharge Main project, Jim Jackson of GJC was informed by the City of Compton that Willdan Company would be the Project Manager. All contractually required material submittals would be made to Willdan for review. Material submittals and schedules submitted by GJC did not meet the contract requirements, were incomplete, untimely, or proposed the use of non -complying materials. The cross-complaint further alleges that GJC was contacted by Willdan for critical plans necessary for the safe and efficient execution of the work. GJC critical plan submissions either went uncorrected or were not submitted in an acceptable form until weeks after such documents are normally prepared and submitted. On October 20,2006, Willdan sent a Notice of Cure Deficiency letter to GJC. The cross-complaint states that GJC had been trying to obtain permission to substitute some of the materials set out in the specifications. When Willdan repeatedly denied GJC's demand for substitution, GJC sought to contact associates at another of Willdan's offices and to the City onsite personnel to try to obtain permission to make specification changes. On November 20, 2006, the City of Compton sent a letter to GJC entitled "Notification of Potential Termination for Default: City of Compton Tucker Street Water Distribution Pipeline and Well Discharge Main: Show Cause." Willdan never received a response letter from GJC. On December 6, 2006, the City sent GJC a notice of termination of contract. Conclusion The Center believes that the above evidence clearly depicts GJC's current and ongoing non-compliance and open disregard for public works laws and GJC's performance obligations under its public works contracts. It illustrates that GJC has continued to engage in the same practices which lead to the debarment of its predecessors Southern California Underground and J.G. Pipeline (discussed in the Center's February 27 protest), companies Mayor Amante and Council Members April 10, 2008 Page 9 operated by the same persons representing GJC, i.e., Jim Jackson and George Frost. As recently as this month, GJC's practices and poor performance have lead to termination of their contract with the City of Riverside. These same practices are the subject of actual and potential litigation with awarding bodies. In addition, in response to protests of the Center, the City of Fullerton determined this month to re -bid a project on which GJC was the apparent low bidder. The Center believes that the practices of GJC as evidenced by the documents submitted with this letter are clearly those of a contractor who flouts its contractual obligations and the obligations imposed by law without regard for the costs and damages incurred by the public agencies with which it contracts. Because the City of Tustin and its taxpayers are best served when public contracts are given to responsible bidders, the Center asks that the City reject the bid submitted by Garcia Juarez Construction. If the City would like any further information or assistance, please do not hesitate to contact me at the above number. Very T Yours, Dwayne P. cKenzie DPM/ag Enclosures 18316\1339022vl 1Db Died CHOIN _. SVO 'X09-ol E! l8ti'ti9Z9-'� - THE CITY or SAN [DIEGO MANAGER'S REPORT UMIS:OI 50 -H -RA PDAIROeg DJC' D: May 20, 2004 REPORT NO. 04-104 A: Honorable Mayor and City Council . Docket of May 24, 2004 SReinstatement of Resolution R-294947 permanently debarring SOutliern California Underground Contractors Mc., George Rogers Frost, and Jim Craig Jackson, (collectively referred to as SOCAL). City Manager Report No. 01-068 (Revised). fn,,nd ould the City Council permanently debarring Southern California nd Contractor's Inc., George Rogero Froct, and Jim Craig Jackaon, ,Iy TP.FerrPd t() ARSnC AI.)? Recommendation:The City Council should permanentlydebar alifornia 'U'nderground Contractor's Inc., George Rogers Frost, and Jim son, (collectively referred to as SOCALmmendations: None. act. None. On May 2 200I, Council passed Resolution R-294947 permanently debarring Southern _ California nderground Contractor's Inc., George Rogers Frost, and Jim Craig .iankson, [collective referred to as SOCAL), pursuant to San Diego Municipal Code sections 22:0801 et eq., for "corrupt practices involving the administration or award of City contracts." A copy of the Resolution and Findings adopted by Council ate attached.) Council he d approximately an hour and a half of oral presentation over two Council meetings had in excess of, 400 pages of documents to review for the deba$ment haaiiilg. T "currupt ptacticcs" noted in the Council 1~indings included taking water from City hydrants without using operable water motels so that billiLg for the water could not b accomplished, hyo instances of falsification of traffic control permits, numerous asions of working in the public right -of --way without traffic control plana or inappropri a traffic control, false claims for inflatpA labor rates and inflated equipment L0 30bd 1)00 ELI81,bU9Z9 19:TT 5002/0£/E0 0 Boo and OH31N..' ,.',1Sd3 'X03-ol EIIBkkk9l9= -�. 0,19:01 90-0E-teN pen�e�ay rates on t ests for additional compensation, misrepresentations o('work completed, and three inses of false worker's compensation claims made to the City's Owner 1NtuauccPlugtzrlrt.Cuuntril also passed an alternative resolution that if a court ovred the pormancnt debarment, a thrco year dcbaiujrut pur�;Uaul to SDMC Section 203(x) would go: into effect. SOCAL ed a. lawsuit (SDSC No. 76R749) challenging its debarment by alleging its due process ri hts had been violated and that Council did not have alrtlinrity to permanently debar un the applicable Municipal Code provisions. On October 9,2001, the superior court rule that SOCAL had not been denied due process of law, however, the court also ruled that until had exceeded its authority under the Municipal Code in permanently debarring OCAL and ordered that the alternative three year debarment be imposed, effective ay 29, 2001. Both the City and SOCAL appealed- On ppealed On May 6 2003, tho Appellate Court ruled in tho City's favor, agreeing that SOCAL's due prose rights had not been violated, and reversing the Superior Court by ruling that Council d have authority under the Municipal Code to permanently debar SOCAL. The Appellate urt specified "The.matter ie rernandtA to tbn trial court with directi ons that the City uracil may reinstate its resolution permanently debarring SOCAL." (A copy Of the Ap 'late Court ruling.is attacbed.) SOCAL petitioned the California Supreme Court for view, which was denied on -August 20, 2003. On August 28, 2003, the Appellate urf certified that its opinion was final and remanded the matter to the superior c On September•. 19, 2003, the Superior Court amended its previous judgment* d ruled in the City's favor. The court specified "Respondent, City of San Diego, ma reinstate its resolution and petitioner is'permanently debarred." For SOC to be permanently debarred, itis necessary for Council to reinstate Recoluti 294947. At pre4ent SOCAL is debarred under the thrcc year debarment, which end May 2.9, 2004. The City uracil not permanently debar SOCAL. This is not recommended as it would allow SOTL to continue bidding on City contracts and would contradict earlier City -actions. submi lied, Frank Bel k Jr., David Zoumaras Richard Mandcs lire ctor Assistant. Deputy Director Deputy Engineerin and Capital Projects Pty City Manager BRLOC oumaras The attach ents are available for review in the Office of the City Clerk_ 80 3Jtid ow £LI8VVP9Z9 TS:ii 500Z/0£/£0 Minutes of the Council of the City of San Diego for the Regular Meeting of Monday, May 24, 2004 - Page 48 Based on its evaluation. of the proposal, the Working Group submitted a series of detailed reports and a proposed clean-up and abatement order to the Regional Board in advance of a public workshop held by Regional.Board staff on May 3, 2004. At the workshop; the Working Group presented its materials and urged the adoption of an expedited clean-up order. The Regional Board soon will be considering a new order for remediation of the site. This action will allow for a resolution.of the City Council authorizing a'letter to the RWQCB from the Mayor and Council requesting that the matter of a new order be heard by the Regional Board as soon as possible, but no later than August, 2004, and urging the adoption of anew clean-up and abatement order requiring clean=up on an expedited bases. -The City is requesting that the remediation be expedited given that 15 years has transpired since the initial release. was identified and the release continues to adversely impact significant public resources. FISCAL IMPACT: None with this action. Mendes/Heap/SMC FILE LOCATION: MEET (61) COUNCIL ACTION: (Time duration: 2:16 p.m. - 2:17 p.m.) CONSENT MOTION BY MADAFFER TO ADOPT. Second by Zucchet. Passed by the following vote: Peters -yea, Zucchet-yea, Atkins -yea, Lewis -yea, Maienschein-yea, Frye -yea, Madaffer-yea, Inzunza-yea, Mayor Murphy -yea. * ITEM -5402: Debarment .of Southern California Underground Contractors, Inc. (See City Manager Report CMR -04-104.) CITY MANAGER'S RECOMMENDATION: Adopt the following. resolution: (R-2004-1213) ADOPTED AS RESOLUTION R-299276 Reinstating Resolution R-294947 in its entirety, including all exhibits, and . adopting the "Findings. egarding the Permanent Debarment of Southern Minutes of the Council of the City of San Diego for the Regular Meeting of Monday, May 24, 2004 Page 49 California Underground Contractors, Inc., its divisions and organizational elements,.its Affiliates, Jim Craig Jackson and George Rogers Frost,, (SoCal), pursuant to San Diego Municipal Code Section 22.080 1, et seq., and based upon all evidence and testimony. FILE LOCATION', MEET COUNCIL ACTION: (Time duration: 2:16 p.m. -2:17 p.m.) .CONSENT MOTION BY MADAFFER TO ADOPT. Second by Zucchet..Passed by the* following vote: Peters -yea, Zucchet-yea, Atkins -yea, Lewis -yea, Maienschein-yea, Frye -yea, Madaffer-yea, hizunza-yea, Mayor Murphy -yea. * ITEM -5403: Excusing Councilmember Zucchet from the Natural Resources and Culture Committee Meeting on May 12, 2004. COUNCILMEMBERZUCCHET'S RECOMMENDATION: Adopt the following- resolution: (R-2004-1265) ADOPTED AS RESOLUTION -R-299277 Excusing Councilmember Michael Zucchet from attending theregularly scheduled May 12, 2004, NaturalResources and Culture Committee meeting. FILE LOCATION: AGENDA COUNCIL ACTION: (Time duration: 2:1.6 p.m. - 2:17 p.m.) CONSENT MOTION BY MADAFFER TO ADOPT. Second by Zucchet. Passed by the following vote: Peters=yea, Zucchet-yea, Atkins -yea, Lewis -yea, Maienschein-yea, Frye -yea, Madaffer-yea, Inzunza-yea, Mayor Murphy -yea. 108 Cal. App. 4th 533; 133 Cala Rptr. 2d 527; 2003 Cal. ApF. LEXIS 667; 2003 Cal. -Daily Op. Service 3848; 2003 Daily Journal DAR 4919 .SOUTHERN CALIFORNIA UNDERGROUND CONTRACTORS, INC., Plaintiff and Appellant, V. CITY OF SAN .DIEGO, Defendant and Appellant. No. D039275. COURT OF APPEAL OF CALIFORNIA, FOURTH APPELLATE DISTRICT, DIVISION ONE .108 Cal. App, 4th 533; 133 Cal. Rptr. 2d 527; 2003 Cal. A p. 2003 Cal. Daily Op.. Service 3848; 2003 Daily Journal pDARLEXIS 4919 667; May 6, 2003, Decided May 6, 2003, Filed SUBSEQUENT HISTORY: As Corrected May 6, 2003. Counsel Corrected May 21, 2003. Rehearing denied by -Southern California Underground Contractors, Inc. v. City of San Diego, 2003 Cala App. LEXIS 777 (Cal. App. 9th Dist., May 20, 2003) Time for Granting or Denying Review Extended Southern California \, Underground Contractors Inc. v. Cit (Cal., July y of San Diego, 2003 Cal. LEXIS 5221 23, 200,3.). Review denied by Southern California Underground Contractors, Inc. V. City of San Diego, 2003 Cal. LEXIS 6188 (Cal., Aug. 20, 2003) PRIOR HISTORY: Superior Court of San Diego County, No. GIC768749, E. Mac Amos; Judge. COUNSEL: Andrade & Associates, Richard B. Andrade, Frank A. Satalino, W. Grey Zimmerman and Natalia Desiderio for Plaintiff End Appellant. Casey Gwinn, City Attorney, Anita M. Noone, Assistant City Attorney, and Sim Von Kalinowski,. Deputy City Attorney, for Defendant and Appellant. JUDGES: (Opinion by Aaron, J., with Benke, Acting J., concurring:) P. J., and McDonald, OPINIONBY: AARON OPINION: AARON, J. I. INTRODUCTION These appeals follow an administrative ruling by the City of San Diego (City) to permanently debar Southern California Underground Contractors, Inc. (SoCal), from contracting with City. The debarment was based on findings of the San Diego City Council (City Council) that SoCal engaged in corrupt practices while administering public works contracts it had entered into with City. The trial court granted SoCal's petition for writ of administrative mandamus (Code Civ. Proc.; 1094.5), concluding that the decision to permanently debar SoCal constituted an abuse of discretion and an act in excess of City's authority because SoCal had not engaged in an Otherwise, involving the "administration" of y practices, corrupt or ts but rather had engaged in such practices onlylin thetracts with City, "Perfothe contracts. Accordingly, the court ordered City to adoptrmatsce of proposed alternative resolution to debar SoCal for a _.. per ._years.. The court rejected_SoCal's claim that -the debarment d of three denied SoCal its rights to procedural due process and to a fair hearing before an impartial tribunal. g In its appeal; SoCal does not challenge the sufficiency of the evidence supporting the findings upon which. the debarment was based. Rather, SoCal contends it was not given a full and fair opportunity to defend itself.. Specifically, SoCal maintains it was denied the right to confront and cross-examine adverse witnesses and the right to present live testimony before an impartial tribunal. City also appeals, contending the court erred in finding that SoCal had not engaged in corrupt practices involving the "administration" of contracts and that its order for permanent debarment was thus proper. we conclude that the debarment proceeding afforded SoCal due process and a fair hearing before an impartial tribunal, and affirm the judgment in this respect. However, we further conclude that SoCal's corrupt practices involved the "adnuriistrafion" -of City contracts so as to warrant permanent debarment. Accordingly, we reverse theJ insofar as it imposes on SoCal a three-year debarment ratherthaneat permanent one. II. FACTUAL AND PROCEDURAL BACKGROUND nl - - - - - - - - - - - - --Footnotes - - - - - - - - - - _ nl In order to thoroughly and fairly state the factual and procedural background, pursuant. to Evidence Code section 459, we grant the following requests for judicial notice: A. SoCal's request for judicial notice filed June 21, 2002, of the original complaint entitled Southern California Underground GIC759273) Contractors, In c. v. City of San Diego (Super. Ct. San Diego County No. B. SoCal's request for judicial notice, filed September 19, 2002, of: (i) Complaint entitled Southern Cali Inc V. City of fornia Underground Contractors,m San Diego (Super. Ct. San Diego County, No. GIC750233); (ii) March 14, 2001, order granting petitioner's motion f reinstatement inm Southern California or, City of San DiUnderground Contractors, Inc. v. egom (Super Ct. San Diego County, No. 750233); (iii) Administrative Record Index for June 2000 Permanent Debarment ofm Southern_California Underground Contractors, Inc.; (iy) City of San Diego City Charter, article VII; (v) City. of San Diego, resolution No. R -L89709, adopted February 2, 1998; (vi) San Diego City Council's meeting minutes from 1979 through 2000.. C. City's request for judicial notice filed October 10, 2002, of: _(i) San Diego 2001_Superior_Court case -No: --750233 ruling- filed March 23, ; 9 (ii) San Diego Superior Court case No. 754273, City's answer to plaintiff's unverified complaint, filed October 10, 2000. - - - - - - _ - - - End Footnotes- - - - - - - - - - - - - - SoCal is a contractor that specializes in public underground construction projects. In June 2000, while working on 11 projects City, SoCal was debarred n2 for engaging in "corrupt practices for involving the administration or award of a contract with the City _ (San Diego Mun. Code, n3 § 22.0803(b).) The. debarment was based on City Council's findings, made after a hearing, that SoCal had engaged in a pattern of willful acts of corruption and deception, unethical and unacceptable business practices, and.inadequate contract performance on numerous public works contracts with City. In the three weeks before the debarment hearing, City provided SoCal with a written factual basis and supporting evidence for the proposed debarment, and made available for review and copying all project files for the contracts upon which the proposed debarment was based. At the request of SoCal, made available for depositioCity also n six of its inspectors to testify as to the allegations supporting the debarment. _ - - - - - - - - - - - - - Footnotes - - - - - - - - - - - - - - - D2 'Debarment' means action taken by the City Council to exclude a contractor from contracting with the City for a reasonable, specified period." (San Diego Mun. Code, § 22.0802.) n3 All code references are to the San Diego Municipal Code unless otherwise specified. End Footnotes - After the City.Council rendered its decision to permanently debar SoCal, SoCal filed a petitionfor writ of administrative. mandamus, challenging the debarment. While the writ was pending, SoCal-filed a multimillion -dollar lawsuit against City in which it alleged that the debarment was illegal. In issuing the writ, the court remanded the debarment matter to the City Council for a rehearing, based upon its finding that SoCal had not been afforded adequate time to prepare a defense, and thus had been denied due process. The court . another hearing be set no ordered that court's ruling. sooner than 45 days from the date of the City scheduled the .second debarment hearing for May 22, 2001, 60 days after the court's ruling. On April 9, 2001, City served SoCal with manager's report No. 01=168, in which the factual basis for the proposed debarment was set forth, together with supporting documents. The proposed debarment was based on the same charges that were raised in the June 2000 proceeding: (1) falsifying traffic (2) working in .the public right-of-way control permits; appropriatwithout traffic control plans -or e traffic control, on numerous occasions; (3) taking water from city fire hydrants without having water meters, and using meters that .were either. -inoperable - or -had -been reported -missing water could not be billed (4 ) misrepresenting that work ha the use of ad been completed, and attempting to. cover up the misrepresentation; (S) s-ubmitting numerous false claims for extra work, at significantly inflated labor rates; (6) submitting false claims for inflated rates on equipment (by physically altering equipment model numbers); and (7) submitting false workers' compensation claims from City's owner - controlled insurance program. Before the second hearing, SoCal took 13 additional depositions of City employees. City inforined SoCal it could dispute the proposed debarment through a combination of submitting written materials to the City -Council and making an oral presentation to the City Council. SoCal was given the right to submit unlimited written materials, including legal briefs, to declarations-and deposition transcripts .'City advised SoCal that in order to ensure a full and fair opportunity to be heard before the City Council, SoCal should present its complete positiorL in writing in advance of the hearing, together with all supporting documentation. SoCal was further informed that testimony will be accorded subject to the regularfineetingportunruleslty andfor discretion of the Cit materials cony Council. If SoCal wishes to have written sidered, please ensure delivery to the City Clerk in order for the City Council members to review it prior to the debarment bearing." City twice reminded SoCal that SoCal had the right to submit unlimited written materials. With regard to the right witnesses, City pointed out that SoCal hto cross-examine ad been afforded the opportunity to cross-examine witnesses during their depositions, and that SoCal could present this testimony at the City Council hearing through written statements, declarations and deposition transcripts. SoCal, through its counsel,- submitted nearly 400 pages of written materials to the city clerk at 4:13 p.m, on the day prior to the .scheduled debarment hearing. At the May 22, 2001 hearin SoCal was allowed 90 mating. Ao g, counsel for continued for one week to allow time efor Sthe lmembers ofs case. htheeCityg was Council to review SoCal's written submissio to, and did, submitns. SoCal was also permitted .a supplemental brief and additional deposition transcripts after the hearing. At.the continued hearing on May 29, 2001, SoCal's attorney made another 40 -minute oral presentation. Following the hearings, the City Council adopted a resolution permanently debarring SoCal. The City Council made an alternative motion to debar SoCal for three years in the event a court were to overturn the permanent debarment. SoCal filed its administrative mandamus petition in the superior court challenging the procedural aspects of the debarment and claiming that City had acted beyond its statutory authority, SoCal. The .court rejected SoCa.l's due process argument, Piny debarring SoCal had been afforded ample o g finding that evidence and cross -e_ opportunity to conduct.discovery, present cross-examine adverse witnesses. prior to the debarment hearing. The court further found that SoCal had not met its burden of showing it had been denied due process on the grounds that certain members of the City Council failed to consider SoCal 's evidence, or that the City Council was biased because SoCal h against -city. ad filed a lawsuit However, the -court gran-ted-SoCal s- etition-for writ of mandate on the ground that the decision to permanently debar SoCal under section 22.0803(b) for corrupt practices involving the "admi.nistration" of a contract constituted an abuse of discretion and an act in excess of City's authority. In -distinguishing between the terms "administration" of a contract and "performance" of a contract as used in section 22.0803(a) and (b); the court found SoCal had not engaged in any practices, corrupt or otherwise, involving.the administration of contracts. Rather, the court found, SoCal had provided unsatisfactory "performance" under the contracts. The court concluded that SoCal's unsatisfactory performance, together with its demonstrated lack of business integrity,- warranted a three-year debarment under section 22.0803(a). Accordingly, the. court ordered City to vacate its decision permanently debarring SoCal, and to adopt a resolution debarring SoCal for a period of three years. III. SOCAL'S APPEAL Discussion 1. The Debarment Proceeding Before the City CO vncil Satisfied the Requirements of Due Process a. SoCal Was Not Entitled to a Fv11 Evidentiary Hea Council ring Before the City (la) SoCal contends the debarment proceeding before. the City Council was fundamentally unfair and -resulted in a denial of due process because SoCal was not allowed to present live rebuttal testimony or to cross-examine adverse witne.sses:.SoCal asserts that being afforded only the opportunity to provide written submissions and to make a limited oral presentation does not satisfy the requirements of due process. (2a) The ultimate determination whether an administrative proceeding was fundamentally fair is a question of law to be decided on appeal. Rosenblit v. Superior Court"(1991) 231 Cal. App. 3d 1434,. 14-43 [282 Cal. Rptr. 819).) Thus, we independently evaluate SoCal's claims that it was denied a fair hearing."( Id. at p. 1444; -Ran Diego County Deputy Sheriffs Assn. v. San Diego County Civil Service Com. (1998) 68 Ca1:App.9th 1084, 1086 [80 Cal. Rptr. 2d 7,12).) (lb) Debarment excludes an individual or entity from doing business with the government as a result of wrongful .conduct or violations of a public contract or program. ( Golden Day Schools, Inc. v. State Dept. of Education (2000) 83 Cal.App.4th 695, 703 199. Cal. Rptr. 2d 917).) Although. debarment can have a severe economic impact on contractors, it "is not intended as punishment. It is, instead,a necessary means to enable the contracting governmental agency to deal with irresponsible bidders and contractors, and to administer its duties with efficiency." ( Id. at P. 704, citing, Gonzalez v. Freeman (D.C. Cir. 1964).334 F.2d 570, ,,77.) However, because debarment implicates a liberty interest, a contractor"has a due process right to a fair hearing when a government entity seeks to debar it from contract Deligibility. ( Golden Schools, Inc. v. StateDept. den Day of Education, supra, B3 CGol 711; Stacy & Wi tbeck, Inc. v. City and County of San Fra* ncipcoth at p. 36 Cal. App. 4th 107 4,. 1086, fn. 6 [ 4 4 Cal. Rptr. 2d 472 (1495) ugh a government contractor cannot be debarred without procedurallsafeguards, -there is'no r _ constitutional entifleinent to the full panoply udicial trial procedures such as cross-examination. ck j City and County of San Francisco, supra, 36 Cal.App.4th=at p Ind v p. 1087.)- (3) Due process is the opportunity to be heard at a meaningful time and in a meaningful manner. ( Mathews v. Eldridge (1976) 424 U.S. 319, 333 [47 L. Ed. 2d 18, 96 S. Ct. 893J.) Unlike some legal rules, due process 'is not a technical conception with a fired content unrelated to time, place and circumstance.' [Citation.]" ( Id. at p.-334.[96 S. Ct. at P. 902]:) Rather, it " 'is flexible and calls for such procedural protections as the particular situation demands.' [Citation.]" (Ibid.) Determining whether a particular administrative procedure is constitutionally sufficient requires analysis of the gover private interests involved: nmental and (1) the private interest that will be affected by the official action; (2) the risk of -an erroneous deprivation of such interest through .the procedures used and any, probable value of additional or substitute procedural safeguards; and (3) the government's interest, including the function involved and the fiscal and administrative burdens that the additional or substitute Procedural requirement would entail. ( Id. at 9031.) p. 335 [96 S. Ct. at p. (4) SoCal.cites Goldberg v. Kelly (1970) 397 U.S. 254, 269 [25 L. Ed. 2d 287, 9o. S. Ct. 1011J to support its -position that due process requires that it be afforded the opportunity to confront and cross- examine adverse witnesses at the debarment hearing before the City Council. In Goldberg, New York City welfare recipients challenged the adequacy,of procedures .for notice and hearing in connection with the termination of their public assistance payments. While acknowledging that some governmental benefits may be administratively terminated without affording the recipients a pretermination evidentiary hearing, the Supreme. Court held that due process required such a Public assistance payments to welfhearing when are recipients may be discontinued. Id. at p. 264 [90 S. Ct. at pp. 10187101-9 at this conclusion, the court stated. ]') Significantly, in arriving context --a factor not present in thethis contractor, case ]of the he cblacklistedial factor1government is that termination of aid pending resolution of a controversy over eligibility may deprive an eligible recipient of the very means by which to live while he waits. Since he lacks independent resources, his situation becomes immediately desperate. His need to concentrate upon finding the means for daily. subsistence, in turn, adversely affects his ability to seek redress from the welfare bureaucracy." (Ibid., italics added. at the particular characteristics of a welfareourt recipient, pr las applied to due process required "timely and adequate notice detailip'ngnthe reasons for a proposed termination, and an effective opportunity to defend by confronting -any adverse witnesses and by presenting his own arguments and evidence orally." ( Id. at pp. 267-268 190 S. Ct. at p. 1020].) Noting that New York City's procedures did not per recipients to present evidence orally or to comit welfare nfront and cross-examine witnesses, the court in Goldberg explained the context of its holding; "The opportunity to be heard must be tailored to the capacities and circumstances of those who are to be heard. It is not enough that a welfare recipient may present his position to the decision maker in writing or second-hand through his caseworker. Written submissions are an unrealistic option for most recipients, who lack the educational - atta-inment necessary to --write effectively -fin- who cannot o twin Professional assistance." ( Goldberg v. Ke11y,.svpra, 397 U.S. at 268-269 190 S. Ct. at p. 1021], italics added.er, pp- submissions do not provide the "flexibility of oral or written "permit the recipient to mold his ar maker a P gument to the issues the decision ppears to regard as important." ( Id. at P. 269 [90 S. Ct. at p. 1021).) Thus, a welfare recipient "must be allowed to state his Position orally. Informal procedures will suffice; in this context due process does -not require a particular order of proof or mode of offering evidence. [Citation.)" (Ibid.) Additionally, due process requires that welfare recipients be affordedetheurt held, opportunity to confront and cross-examine adverse witnesses. ( Id. at pp. 269-270 190 S. Ct_ at pp. 1021-10.22).) (lc) Here, as noted in Goldberg, the administrative procedure did not deprive SoCal of "the very means by which to live . followed Goldberg v. Kelly, supra, 397 U.S. at P. 264 190 S. Ct.-at SoCal is a sophisticated business entity and had the profesp. 1018) ) nAl assistance of counsel. Socal was given "timely and adequate notice ..detailing the reasons for a proposed [debarment)." ( Goldberg. supra, 397 U.S. at pp 267-268 190 S. Ct. at 9 Kelly, afforded an effective o P• 1020].) SoCal was pportunity to confront adverse witnesses at depositions. And unlike the welfare recipients in Goldberg, SoCal was able, through its counsel, to effectively present its. position in writing, and present arguments and evidence orally before the decis maker. (-Id. at pp. 268-269 [90 S. Ct, at pp. 1020-1021).) The ion procedure followed here was tailored to SoCal's "capacities and circumstances," and thus provided sufficient due process safeguards. Goldberg v. Kelly, supra, 397 U.S. at p 269 190 S. Ct. at p. 1021).) In Mathews v. Eldridge, supra, 424 U.S. 319, the Supreme Court addressed the issue whether due process required n hearing in the context of an administrative termination ofdisabilityrbenefits- ( Id, at pp. 345-346 196 S. Ct. at pp. 907-908).) The court distinguished Goldberg, where "welfare assistance. is given to persons on the very margin of subsistence," noting that eligibility for disability benefits is not based on financial need. ( Id. at S. Ct. at P. 905),) Accordingly, " h 3 n [96 9 i', there is less reason .here than in Goldberg to depart from the ordinary principle, established by our decisions, that something less than an evidentiary hearing is sufficient prior to adverse administ S. Ct. at p• 907].) rative action." ( Id. at;p 393 [96 In considering the fairness and reliability of the existing administrative procedures for disability recipients, the Mathews court observed that the potential value of an evidentiary hearing was substantially less than in the welfare context. The court noted that written submissions provide the disability recipient with an effective means of communicating his case to the decision maker. The state agency identifies with particularity the information relevant to the entitlement decision, and information critical to that decision is ordinarily derived from medical sources. These sources are likely to be able to communicate more effectively through written documents than are .welfare recipients or lay witnesses. ( Mathews v. Eldridge, supra, 929 U.S. at p. 395 [96 S. Ct. at pp. 907-908].) In addition, before benefits are terminated, the disability recipient is afforded full access to the information relied on by the' tate agency. The recipient - is given reasons for the tentative assessM-CFat and an'o submit additional arguments and evidence. PPorfuriity to Ct. at pp. 907-908] - ) The court f ( Id. at pp. 395-346 [96 S. found that .this procedure enables recipient to 'mold' his "the argument to respond to the precise issues which P. 908).) the decision maker regards as crucial." ( Id. at p. 346 [96 S. Ct. at (5)Moreover, the Mathews court noted, requiring an evidentiary hearing in all cases before terminating disability benefits would entail fiscal and administrative burdens out of proportion to any countervailing benefits. Further, the court observed that "[t]he judicial model of an evidentiary hearing is neither a required, nor even the most effective, method of decisionmaking in all circumstances." ( Mathews v. Eldridge, Supra, 429 U.S. at p. 348 [96 S. Ct. at p. 909).) All that is necessary to comport with due process "is that the procedures be tailored, in light of the decision.to be made, to 'the capacities and circumstances of those who are to be heard,' [citation) to insure that they are given.a meaningful opportunity to present their case.— (-'Id. at 196 S. Ct. at -p. 9093. ) p. 349 (ld) Here, the administrative proceeding in which SoCal participated comported fully with the requirements of due process, as articulated by the court in Mathews. The manager's report identified with Particularity the information relevant to the proposed debarment and summarized City's evidence against SoCal. City provided supporting documents upon which it would rely, and allowed SoCal to review City's complete files pertaining to the subject contracts, prior to the debarment hearing, n4 SoCal was given the opportunity to conduct discovery, and.was permitted to present unl witness statements in the form of declaratice, ons, and the testimonyimited documentary .evidenen adverse witnesses it had cross of -_examined. Through its written arguments, both factual and -legal, SoCal was able to respond, to the specific charges underlying the proposed debarment. ( Mathews v. Eldridge, supra, 424 U.S; at p. 346 [96 S.. Ct. at p. 908].) In addition to providing written submissions, SoCal was afforded -the opportunity to make two oral presentations, to "mold [its) argument" to the issues City regarded as important. ( Goldberg v. Kelly, supra, 397 U.S. at p. 269 190 S. Ct. at p. 1021).) In sum, SoCal had a meaningful opportunity to be heard and thus received due process- --- - - - - - - Footnotes - - - - - - - - - - - - - - - n4 SoCal does not challenge the sufficiency of the notice it received, the specificity of the charges against it, or the access to information it was granted. --- - - - - End Footnotes. - . - - - - - - _ - - SoCal cites Golden Day. Schools, Inc. v. State Dept. of Education, supra, 83_Cal.App.4th at page 706, for the proposition that due process required that it have been allowed to present live testimony and to cross-examine adverse witnesses at the hearing before.the City Council. In Golden Day, the court held that a child care -contractor with the state, debarred from applying for further contracts, for three years, had a due process liberty interest _jentitling it to a hearing regarding -the -Just to .. _ pp.08_ procedures afforded in that case consisted of review ofOthe The contractor's written submissions and an oral presentation during which the contractor or its representative had the opportunity to argue or explain any material submitted in its response. The review panel could set reasonable limits on the scope of the presentation. ( Id. at p. 700.) In addressing the contractor's claim that the hearing was unfair because the contractor was not permitted to cross-examine adverse witnesses, the court in Golden Day noted that the contractor had not sought, to cross-examine anyone. However, the .court held that the contractor should have been allowed the opportunity to cross-examine staff persons who had participated in the determination that led to the debarment recommendation. The court ultimately remanded the matter for a new hearing before a panel member who had not participated in the initial decision. (Golden _Day Schools, Education, supInc.' v. .State Dept. of ra, 83 Cal. App: 4th -at p. 7jl.)_ Here, unlike in Golden Day, SoCal did have the opportunity to cross- examine City employees who. participated in the investigation leading to its debarment. SoCal took the depositions of adverse witnesses and was able to present their deposition testimony to the City Council, and to highlight in its written briefs and oral presentation any inconsistencies, faulty memory or bias on the part of these witnesses. Nothing in Golden Day or other. case law requires that cross-examination occur at the hearing before the City Council rather than at a deposition. (2b) " 'In the vast bulk of .circumstances, the procedures chosen. by the legislature or by the agency are likely to be based on application of a Mathews -type cost -benefit test by .an institution Positioned better than a court to identify and quantify social costs and benefits. A court should give serious consideration to second- guessing a legislative or agency choice of procedures only when it has indications that the agency or legislature chose its. -procedures in bad faith or without considering the implications of its choice of Procedures' [p) 'In assessing what process is due . substantial weight must be given to the good -faith judgments of .the [agency).' .[Citation.)" ( Mohilef v. Janovici (1996) 52 Cal. App. 4th 267, 288-289 [58 Cal. Rptr. 2d 721).) (le) SoCal offers no evidence to support the conclusion that the City Council chose .the procedures followed at the debarment hearings in bad faith, or that it failed to consider the implications of its choices. In the absence of such evidence, the court must give great deference to City Council's choice of procedures. b. SoCal Was Not Entitled to Receive Due. Process Protections Set Forth in the Code. of Federal Regulations or Government Code Section 11425.10 Citing the Code of Federal Regulations, SoCal asserts that City's debarment proceeding did. not required by federal law. Howecomply with minimum due process standards ver, the Code of Federal Regulations applies to administrative agencies of the federal government, not to municipalities or local agencies. (See 44 U.S.C., § 1510.) Similarly, the provisions of the Government Code cited by SoCal apply to: "state boa-rds;-eerwi-ssions! and -officers, " and not to local entities. (Gov.. Code, §§ 11410.30, 11500, subd. (a)..) Even if Government Code section 11425.10 applied, here; SoCal did receive "notice and an opportunity to be heard, including the opportunity to present and rebut evidence.,, C- SOC:al Was Afforded the Opportunity to Effectively Debarment Hearing Participate in the SoCal asserts City did not follow its own "specific uniform procedures" under the San Diego Municipal Code, such as providing "an opportunity w to participate in the administrative hearing However, as we previously discussed, SoCal was afforded §the o4pPortunortun to, and did, fully participate in the administrative hearing. ity SO Cal compares the procedure for debarment with the procedure for bid protest hearings, which allows for presentation of live testimony and cross-examination of witnesses, and argues.that it should have been afforded the opportunity to present live .testimony and cross- examination. The procedures for administrative enforcement hearings such as bid protests require the appointment of a hearing officer. (§ 12.0401 et seq.) In contrast, debarment is determined by the City Council, which' determines the procedures to be followed. 22-0803(b).) The court will not (§§ 22.0101, second-guess City's choice of procedures to carry out its various functions,. as long as those Procedures comport with the requirements of due process. In assessing what process is due,. we accord substantial weight to City's good -faith judgments. ( hlohilef v.. Janovici, supra, 51 Ca1.App.4th at P. 289,) 2. This Court Presumes the City Council Considered All Evidence Offered by SoCal SoCal contends that allowing written submission of briefs was an unsatisfactory method of resolving City's debarment decision because there was no guarantee the members of the City Council. would review these. materials. However, City is entitled to the benefit eof the presumption. that its official duty has been rgularly performed. (Evid. 138 Code,' § 669; Gentry v. City of Murrieta (1995) 36 Cal.App.4th 1359, 5 [43 Cal. Rptr. 2d 170).) Following the presentations -at the original hearing on May 22, 2001, the debarment hearing was continued for one week specifically to allow. the City Council additional time to thoroughly review the documents submitted, including exhibits. We presume City considered all of SoCal's evidence, as it was required. to do,.in arriving at its debarment decision.. Comments by certain City Council members cited by SoCal are taken entirelyout of conte: not support SoCal's speculative argument t and do ons were not read, or that only a cursory review tofhthe rmaterialitten smwas lmade. Further, it is not within the province of the court to inquire into what evidence was or was not examined or relied on by a council member in reaching his or her decision. ( City of Fairfield v. Superior Court (1975) 14 Cal. 3d 768, 777 [122 Cal. Rptr. 543, 537 P.2d 375].) 3. SoCal Received a Hearing Before an Unbiased Tribunal SoCal contends it did not receive a hearing before a reasonably impartial, noninvolved tribunal because City was both prosecutor. and - adjudicator, and. -.at the --same -time; -was a defendant in SoCaT's pending lawsuit for damages. Preliminarily, we note that SoCal failed to raise this issue at the debarment hearing. (6) An. issue not raised at an administrative hearing, .including a _claim of bias,.may not be raised in later judicial proceedings. (.Anton v. San Antonio Community Hospital (1977) 19 Cal.3d 802, 826 [140 Cal. Rptr. 442, 567 P.2d 1162]; Chevrolet Motor Division v. New Motor Vehicle Bd. (1983) 146 Cal. App. 3d533 539 [194 Cal. Rptr. 270].) n5 - - - - - - - - - Footnotes - - - - - - - - - - - - - - n5 In its reply brief, SoCal claims it asked .City to provide an independent body to hear the debarment proceeding and also asked the trial court to hear it; but both refused. However, nothing in the record before us supports this claim. - - - - - End Footnotes- - - - - (7a) In any event, in this context, a Party-claimingthat. maker was biased must show actual bias, rather thanthe appearance the decision of bias, to establish a fair hearing violation. ( Andrews v:Agricultural :Labor Relations Bd. (1981) 28 Cal.3d 781,.791-794 90 623 P_2d 151 0171 Cal. Rptr. 590,. ].) "[B]ias in an administrative hearing. con text can never be implied, and the mere suggestion or appearance of bias is sufficient. [Citation.] It is not also -well established that a party is not denied an impartial adjudicator merely because an administrative entity performs both the functions of prosecutor and judge. [Citation.] Overlapping investigatory, prosecutorial and adjudicatory functions do not necessarily deny a fair hearing and are common before most administrative boards.. [Citations.]" ( Hongsathavi' v. etc. Medical Center (1998) 62 Ca1.A Queen of. Angels 695].) pp.4th 1123, 1142 [73 Cal. Rptr. 2d (1f) Socal further asserts City was biased because. it was named as a .defendant in SoCal's-multimillion-dollar lawsuit alleging improper debarment. Although the probability of bias can arise from "the pecuniary interests of board members" ( Gai v: City of Selma (1998) 68 Cal.App.4th 213, 225 [79 Cal. Rptr. 2d 910]), the. individual City Council -members are not named as defendants in SoCal's lawsuit thus have no personal pecuniary interest in the outcome of tha, and Further, any financial impact ot case. f the lawsuit against City is remote, contingent and uncertain, and is thus insufficient to constitute the type of pecuniary interest necessary.:to disqualify City from participating in the debarment proceedings. (See Central &West Basin Water etc. Dist. v. Wong (1976) 55 Cal. App. 3d 191, 199 127 Cal. Rptr. 448].) Nor is there evidence of any financial gain to City from debarment, which "is designed to protect the City by ensuring full and open competition by granting awards onl (y 00.01.) y to responsible contractors." This -case does not implicate due process limitations on pecuniary conflicts of interest. Debarment decisions are vested exclusively in the City Council. (§§ 22.0101, 22.0803.(b)_) (7b) Where, as here, "an administrative body has a duty to act, and is the only entity capable of acting, the fact that the body may have an interest in the result ..-..,does not- dis ua-l-ify it—from -acting-.--The rule- of necessity precludes a claim of bias from the structure of the process." ( Hongsathavij v. Queen of Angels etc. Medical Center, 11-43.) supra, 62 Ca1.App.9th at pp. 1142- 4.. Conclusion (1g) Having analyzed the private and governmental interests at stake and the nature of the debarment procedures; we conclude SoCal was . afforded due process. ( Mathews v. Eldridge, supra, 424 U.S. at p. 334 [96 S. Ct. at pp. 902-903):•) Although the private interest in this case is considerable because of the severe economic impact of .debarment Golden Day Schools, Inc. v. State Dept. of Education, supra, 83 Cal.App.4th at pp. 703-704), City has established a review and hearing procedure that assures fairness and reliability before a debarment decision is made. Allegations were made, and evidence presented, that SoCal engaged in corrupt practices in the administration of its contracts with City. SoCal received an administrative review in the form of a bearing. This procedure afforded SoCal an effective Opportunity to defend, including the ability to conduct discovery, present unlimited documentary evidence, cross-examine adverse witnesses at their depositions, present witness statements and testimony, submit written argument and make an oral presentation before the decision maker. Given these procedural protections, the risk of an erroneous deprivation of SoCal's interests was minimal. Finally, t in dealing with irresponsible contractors and administeCity's interest Citiduties with efficiency is substantial. In view of the fiscal and administrative burdens additional proceduralsafeguards would impose such safeguards are not warranted. ; Under the test set forth in Mathews, SoCal received a fair hearing. IV. CITY'S APPEAL Discussion City's Permanent Debarment of SoCal Was Proper Since SoCal Was Engaged in Both the Performance and Administration of Its Contracts with City (8a) City contends. the court erred by granting SoCal's petition for writ of mandate -directing the City Council to vacate its resolution permanently debarring SoCal and to adopt an alternative resolution debarring SoCal for a period of three years. City asserts the City § discretion to permanently debar SoCal. Council properly exercised it for "corrupt practices involving the administration . within the meaning of section 22.0803 b of a contract ( ). (Italics added.) In resolving this issue, we must'interpret-the term "administration" as - used in the context of the debarment pro (9) The intvision of the municipal code. inter vision a statutory scheme to an undisputed set of facts is a question of law subject to de novo review on appeal. ( Burden v. Snowden (1992) 2 Cal.4th 556, 562 [7 Cal. kptr. 2d 531, 828 P.2d 6721 Russ Bldg.. Partnership v. City and County of San Francisco (1988).44 Cal.3d 839, 847 [244 Cal. Rptr. 682, 750 P.2d 3241; Usher v. County of Monterey (1998) 65 Cal.App.4th 210, 216 [76 Cal. Rptr. 2d 274J.) (8b) According to its statement of purpose, debarment is "a sanction to be imposed only- %n-- the --public -Interest- for- tfie City's -protection- and not for purposes of punishment. Debarment is designed to protect the City by ensuring full and open competition by granting awards only to responsible contractors." (§ 22.0801.) The debarment scheme has both a three-year debarment provision and permanent debarment provision. Under section 22.0803(a), the City Council may debar a contractor for three years for a variety of reasons, including unsatisfactory performance of a contract, unjustified refusal to.properly perform or complete contract work or warranty performance, or .any offense or action that indicates_a lack of business integrity and that may directly affect the reliability and credibility of performance of the contractor on future contracts with City. (5 22.0803(a)(3). (a)(5), (a)(10)*) Permanent debarment is governed by section 22.0803(b): "The City Council shall permanently debar any bidder or contractor for a violation of Charter Section 97, and may.permanently debar such bidder or contractor for a conviction under federal or state antitrust statutes involving public contracts or the submission of bid proposals, for any corrupt practices involving the administration or award of a contract with the City, or " permanent debarment of the bidder- or contractor by another governmental agency." n6 (Italics added.) - - - - - - - - - - - - - Footnotes - - - - - - - - - - - - - n6 San Diego City Charter section 97, not applicable here, mandates permanent debarment of a contractor who is bidding process. guilty of collusion in the End Footnotes - The trial court determined that the word "performance" contained in the three-year debarment provision, and the word "administration" contained in the permanent debarment provision, were not synonymous, and apparently.concluded that the terms were mutually exclusive. The court stated: "The drafters of the Municipal Code apparently recognized this distinction because they used the word 'performance' three times in [section) 22.0803(a), the section which allows debarment for a period Of up to three years. The word 'administration' is used only. once, in [section] 22.0803(b). The court finds the choice of words is significant and that SoCal did not engage in any practices, corrupt or otherwise, involving the administration of contracts. Therefore, there are no statutory grounds. supporting SoCal's permanent debarment." In interpreting the phrase "administration of .a contract," we apply principles of statutory construction. (10) Our role in this regard is to ascertain the intent of the Legislature or other enacting body so as to effectuate the purpose -of the law. ( Select Base Materials v. Board of Equalization (1959).51 Cal.2d 640, 645 [335 P.2d 672).) We first examine the words themselves, seeking to give them their usual and ordinary meaning. ( California Teachers Assn. v, San Diego Conmiunity- College Dist. (1981) 28 Ca1.3d 692, 698 [170 Cal. Rptr. 8561; Lungren v. Deukmejian (1988) 817, 621 P.2d 115, 755 95 Cal -3d 727, 735 [248 Cal. Rptr. P.2d 299).) If the language is clear and unambiguous, there is no need for construction. However,- if the terms of the statute or ordinance provide no definitive answer, we resort to extrinsic sources, including the ostensible objects to be achieved according to the apparent - intent-- o-- the -1 egi�-nature:--In we avoid an interpretation that would lead to absurd consequences. ( People v. Coronado (1995) 12 Cal.4th 145, 151 [48 Cal. Rptr. 2d 77, 906 P.2d 1232].) Further, "[w]hile the ultimate interpretatio an exercise of the judicin of a statute is al power [citation agency is charged with enforcingparticular )� when an administrative tatu interpretation of the statute wiill beaccordedsgreat erestect b y the courts 'and will be followed if not clearly erroneous. (CCitations.] [Citation.]" ( Judson Steel Corp. v. Workers' Comp. Appeals Bd. ' 22 Ca1.3d 658,.668-669 [150 Cal. Rptr. 250,s5'86 P.2d 564).) (1978) (80 The San Diego. Municipal Code;does not define the phrase administration of a contract" and thus provides no definitive answer as to its meaning. We therefore look to -the usual and ordinary meaning Of that term, consistent with the purpose of the debarment scheme. "Administration" is commonly defined as "the act or process of administering; performance_ of executive duties: management.,, (Webster's New Collegiate Dict. (9th ed. 1988 ') "THE ACT OR ART OF ) p' S7 "Management" is defined as MANAGING; the conducting or supervising of something (as a business)." (Id. at p. 722.) Black's Law Dictionary 1990) at page 44 defines "administration(6th ed. " as "Management or conduct. of an office or employment; the performance of the executive duties of an institution, business, or the like." Within the context of the phrase "corrupt practices -involving the administration of a contract with the City," the word "administration" "supervision" of.the contract, means the "management" or "Performance" -is defined as "the.execution of an action, something accomplished, the request" ( fulfillment of a claim Webster"s New Collegiate Dict., supra, at promise or fulfillment or accomplishment of a promise, contract? orB7other) and [t]he obligation according to its terms . at p. 1137.}There is nothing in these .definitionsStoLaw Diet., supra, contractor that performs est that under a contract cannot, at the gsame time,a administer the contract. In this regard, a single contractor may ver well carry out both labor and -management y a contract. functions in the execution of SoCa performing ming la fulfillment of its contractual obligations included performing labor as well as managing or supervising. The evidence .showed, and the City Council found, that in five separate instances, on four contracts, SoCal took water from City fire hydrants in a manner that allowed SoCal to avoid paying for it:.twice with no water meters., twice with inoperable water meters SoCal had reported as having been lost or stolen, and once with an operable meter SoCal had reported as lost or stolen.-SoCal had been notified on several occasions that this practice was improper, yet continued to engage in deceptive practices to make it appear water was being measured. A reasonable inference can be drawn that SoCal, in the management or supervision of i'ts contracts, was intentionally avoiding having to pay.for water, in an attempt to reduce its costs and thereby increase its profits. The evidence also showed two instances in which SoCal falsified traffic permits. In one instance, SoCal added a street name to a preexisting permit to make it appear that the permit covered SoCal's work on that street when in fact it did not. In the second instance, SoCal cut out an "approved" stamp from a previously approved traffic control plan and pasted --it. -onto --another plan that had-nott�e-en approved: Add-1--tiona-1-1--- - yr City documented 11 instances on three contracts in which SoCal either worked in the public right-of-way without having obtained required traffic control permits, or failed to implement proper traffic control, all of which resulted in written violation notices or stop work orders. The City. Council concluded that SoCal had falsified traffic control documents and had "repeatedly and egregiously ignored [its] legal and contractual obligation to obtain traffic control permits." It is .reasonable to conclude that SoCal's conduct resulted from management or supervisory decisions. The City Council further found that SoCal had submitted false claims for compensation not owed to it: (1) false daily extra work reports on four contracts in which SoCal claimed inflated labor rates of $ 28 per hour rather than the actual rate of $ 11 per hour; (2) fa -Ise daily extra work reports on one contract where SoCal physically altered the model number on a backhoe in order to charge a higher rate; and (3) three -instances in which SoCal submitted false workers`. compensation claims to City's owner controlled insurance program for workers who were not performing work on the site at.the time of their injuries as SoCal claimed they were. This conduct is reasonably attributable to management decisions. Additionally, the City Council found that SoCal deceitfully_ misrepresented that it had replaced dilapidated sewer laterals. When SoCal was required to excavate one of these laterals, City workers discovered. that the work SoCal claimed it had done had not in fact been completed. SoCal then made an unauthorized excavation of other sites in order to attempt to cover up its failure to replace the sewer laterals. This evidence also reasonably implicates SoCal's management or supervisory functions. The City Council found that each of these four. grounds constituted a corrupt practice sufficient to warrant permanent debarment under section 22.0803(b). It further found that all the conduct, "when taken in totality[,] represents.a serious pattern of repeated,.persistent, and frequent corrupt practices,".thus .constituting a fifth ground for Permanent debarment. The City Council is the only. entity charged with applying section 22.0803(b). We must therefore accord great respect s interpretation of that provision, and folloto its it if it is not clearly erroneous. ( Judson Steel Corp. v. Workers' Comp. Appeals Bd., supra, 22 Ca1.3d at pp. 668-669; Edgar v. Workers' Comp. Appeals Bd., supra, 65 Cal.App.4th 1, at p.-9, 76 Cal. Rptr. 2d 83 .) The City, Council's findings are consistent with -our interpretation of the term "administration" as used in the permanent debarmentis Provision. SoCal documented conduct exceeded mere unsatisfactory or improper performance Of its contractual duties. Much of the conduct involved policy decisions and cost-cutting tactics that could inure only to the benefit Of SoCal as an entity. SoCai's administration of its contracts with r ,z. City involved supporting, condoning or participating in corrupt practices. The use of deception and falsification emanated from SoCal's role in managing and supervising its contracts. Such corrupt practices warranted the City -Council, "in the public interest for the City's protection," to permanently debar SoCal. (§ 22.0801.) In view of -all of these findings, the City Council's permanent debarment of SoCal under - - sectioa-22.0803-fb}--was---not...clea-rly-erroneous The trial court erred in failing to defer to City's determination. V. DISPOSITION The judgment granting soCal's petition for writ of mandate is reversed. The matter is remanded to the trial court with directions that the City Council may reinstate its resolution permanently debarring SoCal. In all other respects, the judgment is affirmed. on appeal_ City is entitled to`costs Benke, Acting p. J., and McDonald, J., concurred. A petition for a rehearing was denied May 20, 2003, and the petition of plaintiff and appellant for review by the Supreme Court was denied August 20, 2003. Baxter, J., did not participate therein. THE CITY OF SAN DIEGO MANAGERS ,REPORT DATE ISSUED: June 7, 2001 REPORT NO. 01-113 REVISED ATTENTION: Honorable Mayor and City Council Docket of June 19, 2001 SUBJECT: Proposed Debarment of J.G. Pipeline, Inc., its divisions and organizational elements, its Affiliates, Richard An Jaime Parraga, George Rogers Frost, Judy Ng Go, and James Jackson [These individuals, the corporate entity, its divisions and organizational elements, and its Affiliates will hereinafter be referred to as "JI.G. " for convenience and clarification].' This debarment is separate and distinct from the procedural process of the debarment of SoCal (defined below). SUMMARY ---is-sue-- Should the City-CdUiiCfrpermanently d bd T . under San-iego Municipaf ode sections 22.0801, et seq.? Manager's Recommendation - Permanently debar J.G. Pipeline, Inc., its divisions and organizational Elements, its Affiliates, Richard Andrade, Jaime Parraga, George Rogers Frost, Judy Ng Go, and James Jackson. Fiscal Impact - None. Reference - Revised City Manager Report No. 01-068, and any and all documentation therein incorporated by this reference. INTRODUCTION 'Where the full name J.G. Pipeline is used, it refers to the corporate entity itself. It also applies to the Southern California Underground Contractors, Inc. because they both are the same company operating under different names. Recently, this City Council permanently debarred Southern California Underground Contractors, Inc., its divisions and organizational elements, its Affiliates, James Craig Jackson, and George Rogers Frost [These individuals, the corporate entity, its divisions and organizational elements, and its Affiliates will hereinafter be referred to as "SoCal" for convenience and clarification.] Debarment of J.G. is separate and distinct from the debarment of SoCal. This is a separate hearing at which J.G. has the opportunity to refute this evidence before the City Council. Even though evidence pertinent to debarring J.G. may, in certain respects, duplicate evidence pertinent to debarring SoCal, J.G.'s debarment hearing is independent of SoCal's debarment hearing and of SoCal's debarment status. BACKGROUND On June 26, 2000, after a noticed public hearing, SoCal was permanently debarred by the San Diego City Council. Four days after that debarment, SoCal, and other individuals related to and working with SoCal, created J.G. Pipeline, Inc. in order to circumvent the debarment. All of these individuals were involved with SoCal both before as well as after that debarment. As described in the Revised City Manager's Report No. 01-068; previously distributed to the City Council, SoCal sued the'City in an Administrative Writ action. This writ challenged the notice of the debarment provided to SoCal. The Superior Court remanded the matter to the City Council to allow SoCal additional time to prepare. That debarment rehearing was heard on May 22, 2001 and May 26, 2001. After the rehearing, the City Council permanently debarred SoCal. Because SoCal is a debarred contractor, the corporate entity J.G. Pipeline, Inc., is also permanently debarred under the Municipal Code without further City action. However, in order to allow J.G. an opportunity to respond to the City Manager's recommendation, J.G. will be afforded a debarment hearing. This debarment hearing is separate and distinct from debarment of SoCal. It is a separate hearing and is based upon a sufficient factual basis which stands alone. -------- All--parties,—includ-ingJ-im Jackson-(offrcer-oFSoeal)-and-George Frust -(owner of-S-aCa1J-- opportunity to rebut all evidence presented before the City Council in this hearing. onsequent y, pursuant tot rs e arment earing, r is permanently debarred, their debarment is not based upon, nor reliant upon SoCal's debarment status. The City Manager is recommending permanent debarment of J.G. based upon the information in this Report and any and all documents referenced and incorporated herein. J.G. BIDS J.G. has submitted a total .of fourteen bids, seven on which J.G. was the apparent lowest bidder, P.G. Pipeline Bid History Chart, Exhibit B): September 22 2000 K01013 Construction of Cather St. Sewer Rehabilitation & Replacement; October 20 2000 K01023 C Construction of Dale Street Storm Drain; -2- November 15, 2000 K01029C Sewer and Water Group Job 527A; February 2, 2001 K01045 Sewer and Water Group Job 489 [non-responsive]; February 7, 2001 K01043C Sewer and Water Group Job 494; February 8, 2001 KO 1041 Sewer and Water Group Job 623(a); and March 15, 2001 KOI 051 Construction of Hensley St. Accelerated Sewer [non-tesponsive]. FACTUAL BACKGROUND 1. J.G. & SOCAL'S SHARED PERSONNEL - The connections revealing that SoCal and J.G. are the same involves key individuals. In order to allow the City Council to keep track of these names, we are providing the following chart outlining the involvement of each of these individuals: -3- Personnel Relationship to: SoCal J.G. Pipeline Leon Lopez Submitted -SoCal's Bids, Co -Owns Submits Bids, Co -Owns Numerous SoCal Vehicles with Numerous SoCal Vehicles, Southern California Underground drives vehicles, owned solely by Contractors, Inc., Admittedly SoCal to City offices to drop Forged SoCal Traffic Control bids off for J.G. Permit Employee, Submits Bids, Jim Jackson Vice -President, Secretary/Treasurer, Submitted Solicits Price Quotes, Requests Bids Credit Applications for J.G. -- -George Frost---- -- -Officer,--100°!o St -ac Owner - - --: _ Judys-law,NGisistr-n - - is the owner of J.G. Richard Andrade . Former Officer, Provided Legal -Executed Articles of Representation, Incorporation, Responsible Managing Employee, Provides Legal Representation, Filed Application for Expedited Contractor's License Judy Ng Go Sister-in-law to SoCal Owner President, Owner George Frost, same address as SoCal Don Minium Insurance Agent (Meridian Ins. Insurance Agent g (Meridian Ins. Co.) Co.) -3- 2. J.G.'S CREATION June 1996 - J.G. argues that they are a separate company than SoCal. However, clear Iinks-between.-the-two-sompanies-e_x_Es - A. As far back as 1996, George Frost (owner of SoCal), his sister-in-law Judy No Go (owner and President of J.G.), his wife Katie Frost and the corporate entity Southern California Underground Contractors; Inc., were located at the same - -- ----------adfiess, as described -below. ------------------------ B. According to a Dun & Bradstreet Report dated October 12, 2000, George Frost holds 100% of capital stock in SoCal. (Dun & Bradstreet Report, Exhibit C.) Now his relative Judy Ng Go is the owner of J.G. Pipeline. (National City Business License Application, Exhibit D.) Judy Ng Go is believed to be George Frost's sister-in-law, and familiar with SoCal. She appears to be named as a J.G. Pipeline officer, in order to allow George Frost, a debarred contractor, to maintain his influence in the operations of J.G. June 26, 2000 - SoCal was initially permanently debarred by the San Diego City Council. (San Diego (Debarment) Resolution No. 293401, Exhibit E.) -4- June 30, 2000 - Merely four days after theal debarment of SoCal, J.G. was created by Richard Andrade, former SoCal officer andinitiJ.G. Responsible Managing Employee ("RME"). _ (Articles of Incorporation, Exhibit F.) July 7, 2000 - Jim Jackson (Vice President, Secretary, and Treasurer of SoCal) spoke freely about the SoCal debarment with the :City Resident -Engineer Collins Soloman on Group Job 530A, a contract on which SoCal was performing. Jim Jackson indicated that he was not concerned about the debarment because they were going to do business as another company. (Declaration of Collins Solomon, III, Exhibit G.) July 20, 2000 - Engineering and Capital Projects Department (hereinafter referred to as "E&CP") advertised a public works project entitled Water Group Job 522. This was the first Group Job to be put out for bid since the debarment of SoCal. Group Jobs are typically the types of E&CP projects on which SoCal bid. (Declaration of Anita Welker, Exhibit H.) July 25, 2000 - Five days after E&CP's advertisement, Richard Andrade, who in addition to being an attorney and previously a SoCal officer, is a licensed contractor, filed an application for an expedited contractor's license in order to bid Water Group Job 522. (Application to Contractors State License Board, Exhibit 1.) This was less than after the SoCal debarment. one month 3. J.G. AND SOCAL'S SHARED USE OF INDIVIDUALS WHO COMMITTED THE CONDUCT WHICH TRIGGERED DEBARMENT July 31, 2000 - Judy Ng Go (owner and President of J.G.) submitted a letter to the Contractors State License Board requesting that Richard AndradCs application be expedited. (J.G. Application to Contractors State License Board, Exhibit I.) A. The expedite was requested expressly for the purpose of allowing J.G. to bid Water Group Job 522. Allegedly, an expedient approval would allow J.G. to avoid an "unnecessary lay-off of [SoCal] employees." In Judy Ng Go's letter supporting the request to expedite, she indicated that J.G. intended to hire twenty-one SoCal employees to be "unemployed" within two weeks. These people were allegedly to be unemployed because SoCal "was moving out of San Diego after finishing up two City of San Diego jobs." (J.G. Application to Contractors State License Board, Exhibit I.) Despite these representations, many of these employees listed in Judy Ng Go's request were working for SoCal as late as December 2000 -early 2001, described below. (Declaration of Ky Stratton, Exhibit J; Pianavilla Report, Exhibit K; Declaration of Mario Reyes, Exhibit L.) -5- B. Not only do these workers continue to work for SoCal while "J -G." is bidding City work, some of these workers committed the conduct which led to SoCal's debarment in the first place. 1) Jim Jackson (Vice President, Secretary and Treasurer of SoCal) submitted numerous false claims on Group Jobs and falsified a traffic control permit. (City Manager's Report No. 01-068, Exhibit A.) 2) On Group Job 530A, Tony Barrios, a J.G./SoCal foreman, was cited for stealing water by using a non -operational water meter on a SoCal job. On this Group Job, Tony Barrios, a City Resident Engineer, in direct violation of the City's directive to avoid a concrete encased high voltage electric conduit, chipped away at the concrete encasement, damaged the electric conduit and caused a power outage in the surrounding tourist and residential area of Old Town. (City Manager's Report No. 01-068, Exhibit A; Declaration of Collins Solomon, Exhibit G.) 3) On Group Job 496, Reuben Mendoza, a J.G./SoCal foreman, was cited for failing to be present on the job at all times as required by the contract including: a) When the crew was working without traffic control; and b) When SoCal installed a sewer main without inspection and failed to replace laterals in violation of the contract. Both of these - instances posed serious risks to the public health and safety. (City Manager's Report No. 01-068, Exhibit A.) -------------__-.4�____Leon LOPez1_a_SoCalem_plo_yee,admittedfalsifying_traffic_control___.____ documents as described above. (The Revised City Manager's Report . 6$;hibit A August -September 2000 - Shortly after the SoCal debarment, E&CP noticed the following irregularities in J.G.'s bidding practices: A. Phone _e_Calls 1) The E&CP Contract Services Division handles most of the City public works bids. The receptionist received calls from a man named Rick Han. He called regularly to obtain project information: copies of bid documents, project plans and specifications. Sometimes he would say he.was with SoCal, other times J.G. On January 31, 2001, he called and represented himself as from SoCal. (Declaration of Danielle Mower, Exhibit M.) 10 2) Some time in September or October, 2000, Anita Welker, Contract Administrator for E&CP Contract Services Division, received a voice mail message from Leon Lopez of J.G. Pipeline, Inc. which began as follows: "Hi, this is Leon from SoCal, (pause) uh, I mean J.G. Pipeline ...." (Declaration of Anita Welker, Exhibit H.) 3) Once when Stacey Stevenson;. Deputy Director of E&CP's Contract Services Division, was contacted by Leon Lopez on behalf of J.G., the cell phone number he left for Ms. Stevenson to return his call was the same cell phone number listed in SoCal's bid documents previously provided to the City. (Declaration of Stacey Stevenson, Exhibit N.) 4) In addition to these telephone calls, E&CP was notified by other contractors that J.G. Pipeline was, in reality, SoCal. (Ortiz Letter, F -hihit n;-Dectaration-af-Da,v-id-Znu.rnaras,--_gxhibit-p-.-)-Ata-goniraGt bid opening where J.G. Pipeline submitted a bid, John Cady, of Ortiz Construction Corporation, said to Anita Welker, "You know who that Is - that's SoCal," referring to J.G. Pipeline's bid. (Declaration of Anita Welker, Exhibit H.) 4. J.G-'S COMPLETE LACK OF BUSINESS EQUIPMENT AND/OR FACILITIES A.. Leon Lopez,.a SoCal-employee, was seen -submitting-bids-on many-E&CP contracts on behalf of J.G. Pipeline. On many occasions, Leon Lopez would actually arrive in SoCal trucks. (Declaration of Richard Culpepper, Exhibit Q; Declaration of Anita Welker, Exhibit H; Declaration of Mario Reyes, Exhibit L; Declaration of Edwin Shoemaker, Exhibit S; Declaration of Wendy Kramer, Exhibit R.) B. Leon Lopez was known to E&CP staff. Before the debarment, Jim Jackson would usually submit SoCal bids to E&CP. However, at times when Jim Jackson was unavailable, Leon Lopez would submit bids for SoCal. In fact, Richard Culpepper (a former SoCal employee who was responsible for submitting bids for SoCal until he left SoCal's employment on June 16, 2000) informed the City that Leon Lopez assumed this job responsibility for SoCal when Mr. Culpepper left. (Declaration of Richard Culpepper, Exhibit Q.) C. San Diego contractors who bid City work told E&CP that they saw a person pick up a bid for J.G. Pipeline, leave the building and get into a SoCal truck. On several occasions, persons exited trucks marked with SoCal insignia to submit bids for J.G. (Declaration of Edwin Shoemaker, Exhibit S; Declaration -of Mario Reyes, Exhibit L.) -7- D. Subcontractor's from whom J.G. requested price quotes indicate that Jim Jackson (Vice President, Secretary, and Treasurer of SoCal) answers J.G.'s cell phone. (Declarations of Mark McDaniel, Exhibit U; Mike Powell, Exhibit T; Edwin Shoemaker, Exhibit S.) The Contractors State License Board only had a cell phone number on file for J -G. as well. (Declaration of Celia Griffin, Exhibit V.) E. The "official" J.G. fax number is located at Jaime Parraga's National City personal residence. However, the actual fax line being used (see discussion below) by Jim Jackson to receive J.G. price quotes from subcontractors is the SoCal fax number. (Declarations of Mark McDaniel, Exhibit U,- Mike Powell, Exhibit T.) F. J.G. Pipeline has no established business location. 1) On J.G.'s bid sheet, in response to the City's standard form providing a place for contractors.to insert their business address, J.G. provided a P.O. Box. When E&CP Contract Services Division asked for a business address, Leon Lopez advised Contract Services that he did not know the physical address of 7.G., nor did he know where the company was generally located. Ultimately, the business address provided was Jaime Parraga's National City residence. (Declaration of Stacey Stevenson, Exhibit N.) 2) Contract Services contacted National City to obtain additional information on J.G.'s address. However, at that time National City had no information onbecause they had not issued, nor had J.G. applied for, a National City business license. (Declaration of Celia Griffin, Exhibit V.) 3) The Contractors State License Board had two addresses on file for J.G. ---- - - - wtii_ch J.G_had nevet_pro_v_i_ded_to_the Ci One-.of_these-addresses_was-the- home address of Judy Ng Go. The second address was for the law offices of Richard Andrade. (Declaration of Celia Griffin, Exhibit V.) 5. J.G./SOCAL BID PRACTICES A. J.G. only bids City of San Diego work. J.G. bids the same type of work on which SoCal exclusively bid. (Declaration of Anita Welker, Exhibit O.) I) . The cities of Chula Vista, Los Angeles, and Long Beach, as well as the local federal Naval offices, have no record of J.G. submitting bids or doing work for them. (Declaration of Celia Griffin, Exhibit V.) Incontrastwhile , J.G. was submitting bids to the City in the fall, SoCal bid a Chula Vista public works project at the same time. ' -8- B. SoCal and J.G. have similar bidding patterns. I) They both have a pattern of bidding low on various pipeline projects in quick succession. O.G. Pipeline Bid History Chart, Exhibit B; Declaration of Stacey Stevenson, Exhibit N.) 2) Jeff Scheidel, Vice President of Scheidel Contractors and Engineering, Inc. [Scheidel], and Board Member of the Associated General Contractors Association [AGC], indicates that based on his twenty-five years experience in job estimating, J.G.'s low bid pricing is not reasonable or responsible. J.G. was the low bidder on seven out of fourteen City jobs (50% of the time). In fact, Mr. Scheidel indicates that bonding company officials have advised him that a red flag is raised any time a contractor is low bidder over 10% of the time. The concern being that the contractor is taking risks and may not be able to complete all the work satisfactorily, which would then force the bonding company to intervene and complete the work. (Declaration of Jeff Scheidel, Exhibit W.) a) According to Mr. Scheidel, bidding on public works projects is an involved and complex process. Responsible contractors typically are only the low bidder on approximately 5% - 10% of the total number of jobs they bid. Any contractor who is low bidder on 50% of the jobs he/she is bidding is probably not basing the bid on the plans, specifications, and actual field conditions. Generally,.when this occurs, the contractor either loses money, uses shoddy materials, or seeks numerous change orders with exorbitant change order pricing, all of which can result in delayed completion of projects and strained contractor/agency relations. (Declaration of Jeff Scheidel, Exhibit. W.) b) For Project No. K01023C, Construction of Dale Street Storm Drain, on which Scheidel was the second low bidder, J.G. Pipeline's bid was approximately $100,000.00 lower then Scheidel's. The City Engineer's estimate was approximately $500,000.00 which equals a 20% price difference between J.G. Pipeline's bid and the City Engineer's estimate. The rest of the bidders on this project were within approximately $10;000.00 - $20,000.00 of Scheidel's bid. Mr. Scheidel indicates that nothing in Scheidel's post bid analysis of this job would indicate that the job could be done profitably in accordance with the plans and specifications, nor completed on time for $100,000.00 less than Scheidel's bid price. (Declaration of Jeff Scheidel, Exhibit W.) _ 0 C) According to Mr. Scheidel, the San Diego county public works construction market is a very difficult market in which to compete profitably. When contractors succeed in setting unreasonably low pricing on public works projects, the contracting community, the agency and the taxpayers suffer as a result of shoddy work, delayed projects and significant staff time spent on ensuing litigation. (Declaration of Jeff Scheidel, Exhibit W.) 6. J.G. COMPANY PROFILE A. San Diego Municipal Code section 22.0801, et. seq., prohibits all City departments from executing a contract with a debarred contractor. In light of the law, E&CP became concerned about whether it was lawful to award a contract to a corporation that was SoCal operating under a different name. Itis the customary practice of E&CP Contract Services Division to request company profiles from new companies who are the lowest bidder and who are considered for bid awards, in order to gain information about unknown companies. Anita Welker, the Contract Administrator, sent such a request to J.G. on September 26, 2000, and in response J.G. sent a letter back on October 4, 2000, profiling the company's experience. (J.G. Company Profile, Exhibit X; Declaration of Anita Welker, Exhibit H.) B. In J.G.'S "Company Profile," J.G.'s organizational structure was substantially the same as SoCal's. The San Diego Municipal Code extends debarment to include any and all "organizational structures" and "divisions." In a contracting scenario, the organizational structure is comprised of, including but not limited to: foremen, superintendents, officers and owners. Both SoCal and J.G. include Jaime Parraga and Ruben Mendoza as superintendents, Tony Barrios as a foreman, Jim Jackson as officer then, bird preparer now, and George Frost via Judy Ng Go. (J.G. Company Profile, Exhibit X.) And, as described below, this organizational structure was working for SoCal at the time J.G. was submitting numerous bids. (Pianavilla Report, Exhibit K; Declarations of Ky Stratton, Exhibit J; Collins Soloman, Exhibit G.) C. In addition, every job listed for J.G. Pipeline's "Construction Experience" was a SoCal job. (Letter from County of Los Angeles, Exhibit Y; Declaration of Anita Welker, Exhibit H.) Further, the listed contracts account for more than one-half of the contracts on which SoCal was debarred (five of nine Cityjobs). (J.G. Company Profile, Exhibit X.) Mid -November 2000 - The J.G. Company Profile raised more questions than it resolved. In light of the cumulative evidence that J.G. was SoCal attempting to circumvent the debarment, E&CP rejected J.G.'s bids. Anticipating that J.G. would continue to submit -10- bids, E&CP contacted the City Attomey's Office for assistance. Additional research obtained the following information: A. Wendy Kramer, City Attorney Investigator, was instructed to ascertain if there was any connection between SoCal and J.G. Within the first day of this research, Ms. Kramer performed computer searches of: a) both companies' corporate records and corporate officers to determine if there were any bankruptcies, liens, or judgments filed against any of them; b) Dun and Bradstreet reports on both companies; c) certified records on both companies from the California Secretary of State and the Contractors State License Board; Department of Motor Vehicles Records; and d) Superior and Municipal Court records for Orange, San Diego, and Los Angeles Counties. (Declaration of Wendy Kramer, Exhibit R.) B. ,.DMV records revealed that George Frost (owner of SoCal), his sister-in-law Judy Ng Go (owner and President of J.G.), and the corporate entity Southern California Underground Contractors, Inc. were located at the same address. Records show that SoCal officer George Frost's wife, Katie Frost, was "also known as" Katie Ng Go, and resided at 418 West 39`h Street, San Pedro, California 97031, as of September 14, 1994. Judy Ng Go resided at the same address as of June 5, 1996. George Frost was served a small claims court judgment dated June 3, 1996, at this same address, 418 West 39`f' Street, San Pedro, California. And, Southern California Underground Contractors, Inc., was served a judgement entered into by a Superior Court at this very same address, also in 1996, specifically, October 3, 1996 Because Judy and Katie are two years apart in age, Judy Ng Go is believed to be George Frost's sister-in-law. (Declaration of Wendy Kramer, Exhibit R.) She appears to be involved with J.G. Pipeline in order to allow George Frost, a debarred contractor, to maintain his influence in the operations of J.G./SoCal. C. According to a Dun & Bradstreet Report dated October 12, 2000, George Frost holds 100% of capital stock in SoCal. (Dun & Bradstreet Report, Exhibit C.) Now is re rrerofJ.13.Pipeti (JtlatTorral C—ityBusiness E Application, Exhibit D.) November 2000 - Jim. Jackson requested that several bids and quotes, and a credit application for J.G. Pipeline, be faxed to.SoCal's fax number: (Declaration of Mike Powell, Exhibit T.) November. 27, 2000 - A. At about 230, Mario Reyes, a City.resident engineer, saw Jim Jackson (Vice President, Secretary, and Treasurer -of SoCal) leaving the J.G./SoCal yard in a white Ford Explorer. (Declaration of Mario Reyes, Exhibit L, with attached photos.) -11- B. Numerous City Resident Engineers received phone calls and/or messages from an individual allegedly working for "Tretrault Consultants." The individual stated that Tretrault was doing consulting for the City of Encinitas. Mario Reyes, resident engineer, inquired how to spell the consulting firms name. The individual spelled it, then paused and said hold on a minute. When he returned to the phone, he spelled it again but this time differently than before. He inquired regarding the quality of SoCal's work. The individual appeared to become defensive upon hearing that SoCal was debarred and stated, "but that is only for work with the City of San Diego." Mario Reyes obtained a call back number. That number was the voice mail for "Mario Ramirez from SoCal." Luis Duenes, Ky Stratton and Ken Zerehpoush also received similar phone calls. (Declaration of Mario Reyes, Exhibit L.) Aiovember-30,-2000 A. Mario Reyes, a City resident engineer, witnessed Leon Lopez driving a truck, License No. 6464033, owned exclusively by Southern California Underground Contractors, Inc. and enter City offices. Right after Mario Reyes observed Leon Lopez driving, Luis Duenes, another City resident engineer, observed Leon Lopez at a City bid opening as the J.G. representative. They communicated what Mr. Lopez was doing by way of a cell phone. Mario Reyes saw Leon Lopez return to the SoCal truck after the bid opening. (Declarations of Mario Reyes, Exhibit L; Luis Duenes, Exhibit Z, both with attached photos; Wendy Kramer, Exhibit R .) B. Mario Reyes went to the J.G./SoCal yard located at Imperial Avenue and 45th Street. All equipment was the same SoCal equipment (painted green bumpers, some white., some yellow), the same trailers (gray with green trim) which appear to be the same mobilehomes/trailers in which meetings with SoCal were held. Trucks with SoCal colors, and the name "SoCal" painted on the driver's door entered and exited the yard. (Declaration of Mario Reyes, Exhibit L.) December 12, 2000 through December 13, 2000 - A. Because several contractors notified the City that SoCal, and therefore J.G., had a yard near 45d' and Imperial Avenue, the Pianavilla Investigative Agency took photos and videotape of persons and vehicles at the yard, and at any job sites to which these people went. License plates for vehicles in these photos disclosed that eight were registered to either Southern California Underground Contractors, or Southern California Underground Contractors dba Leon Lopez, or Leon Lopez doing business as Southern California Underground Contractors, or Leon Lopez. -12- Another vehicle was registered to Jaime Parraga (J.G. Officer as described above). The following is a chart setting forth the registered owner of the vehicles at the SoCal/J.G. yard: D.M.V. LICENSE PLATE \REGISTERED OWNER 6GO7774 SO.CAL. UNDERGROUND CONTR. OR LEON LOPEZ 5G04255 SO. CALIF. UNDERGROUND CONT. INC. 6A64580 SOUTHERN CALIF. UNDERGROUND CONTRACTORS INC. SE488135 (generator) S.CALIF. UNDERGROUND CONTRACTORS INC. 2ZOJ900 PACHECO, CONSUELO SE497264 (water truck) WRATISLAW MASONRY INC. 5H89928 SO -CALIF. UNDERGROUND CONTRACTORS, INC. 51`69598 SOUTHERN CAL CONTRACTORS 6F81949 SO -CAL UNDERGROUND CONT. INC.- LEON LOPEZ 4ELE886 WHEELER, STEPHEN MARK 4CNZ548 PARRAGA; JIM 5X76766 SO. CAL. UNDERGROUND 9C40189 ALL EQUIP LSG. LSR., SOCA. UNDGRND. CONSTR. INC., LSE. 6A64033 SO. CAL UNDERGROUND, CONSTRCTN. (Pianavilla Report, Exhibit K; Declaration of Wendy Kramer, Exhibit R.) B. Collins Soloman, a City resident engineer, reviewed the Pianavilla videotape. He recognized Joaquin Garcia, a laborer/operator; Alfredo Salgado, a laborer/pipelayerknown as "Chaparo," who wore the same hat in the tape as he did when he worked for SoCal on Job 530A. Collins Solomon also recognized a vehicle typical of SoCal because it is a white Chevy -truck, has a chain in front, a -13- green bumper, green stripe, and green grille. To the City's knowledge, no other contractor in San Diego uses these particular distinctive markings. Other indicia of SoCal included a SoCal pipe -layer who worked on a City Group Job; a SoCal gold generator with green trim attached to a white and green Chevy truck; Ruben Mendoza, the most senior SoCal foreman (also identified by J.G. as a J.G. Superintendent); and a SoCal employee known only as "Chute" (red sweatshirt, red hat, mustache); Julian Mendoza Tapia, a SoCal foreman; another SoCal truck (white Chevy with a silver -stripe, green bumpers, chain around the license plate, tinted rear -cab window) used by SoCal foremen; a typical SoCal barricade (with "S.C.U." imprinted on it); one SoCal water truck (white with a green stripe in the middle of the water carrier compartment) and a second water truck, with graffiti on its side, that SoCal has been using for an extended period of time; SoCal backhoes manufactured by John Deere; and a mobilehome/trailer, owned by Jaime Parraga that looks similar to a SoCal trailer for use by SoCal workers. (Declaration of Collins Soloman, Exhibit G.) 7. J.G./SOCAL CONTRACTING COMMUNITY INPUT A. This particular facet of the construction industry is described as a "small community." Many contractors and subcontractors were reluctant to reveal information about J.G./SoCal because they -feared repercussions in the pipeline community. Although many contractors were reluctant to provide information, well-established contractors, those with many years in the business, provided declarations detailing their knowledge that J.G. is SoCal. However, even these individuals revealed a great deal more information than they were willing to put in a declaration for fear of reprisal. One declarant, aware that CGU was J.G.'s bonding company, contacted his own insurance agent. His agent informed him that a CGU representative described J.G. as a large company that had done a lot of work in San Diego before it was banned. The precise definition of SoCal. This contractor disclosed this. information confidentially and would not allow the City to disclose his name, contact his agent, nor.the CGU representative. (Declaration of Wendy Kramer, Exhibit, R.) 8. J.G./SOCAL COMMON USE OF CONSULTANTS A. Not only are J.G./SoCal represented by the same attorneys, the initial correspondence from J.G.'s attorney on behalf of J.G.. was executed as "Attorney for Southern California Underground Contractor's, In." (Declaration of Stacey Stevenson, Exhibit N.) B. J.G/SoCal have the same surety company providing bonds - CGU Insurance Company, 1340 Treat Boulevard, Suite 400, Walnut Creek, Northern California, CA 94596, Candy M. Coons, Attorney -in -Fact. J.G. and SoCal obtained their 44- bonds on July 10, 2000, and November 8, 2000, respectively. (Bond and Insurance Documents, Exhibit AA.) Please note that when the City attempted to obtain basic information regarding J.G.'s bond, J.G. refused to provide even simple information such as who signed for J.G.'s bond. (Letter from E&CP to CGU Insurance, Exhibit BB; Letter from Andrade & Associates to City, Exhibit CC.) C. J.G./SoCal have the same insurance company - Meridian Insurance Service, Inc., 4501 E. La Palma Avenue, Suite 150, Anaheim, CA 92807, Don Minium, Insurance Agent. J.G. and SoCal obtained their insurance policies/certificates on August 15, 2000, and November 11, 2000, respectively. (Bond and Insurance Documents, Exhibit AA.) December 20, 2000 - J.G. obtained a business license to operate a business in National City. A. On that application, Jaime Parraga is listed as Vice President, Secretary, and Treasurer. However, on the California Contractors State License Board license, Judy Ng Go is Treasurer, Secretary, and President. But, on the National City application, Judy Ng Go is not only listed as President, but is also listed as Owner. Richard Andrade is the Responsible Managing Employee. (Contractor License No. 782984 for J.G., Exhibit 1; Declaration of Celia Griffin, Exhibit V.) B. Although Jaime Parraga, was the Vice -President, Treasurer and a Superintendent for J.G. as of August 9, 2000, Jaime Parraga's, and another "J.G. employee," Joaquin Garcia's, vehicles were parked at SoCal's yard. SoCal's yard is used to store equipment and trucks for SoCal. J.G. employees were working for SoCal as described_ below. (Declarations of Collins Solomon, Exhibit G; Ky Stratton, Exhibit J; Pianavilla Report, Exhibit K.) C. Ky Stratton, a City resident engineer, was paged by Reuben Mendoza, a foreman for SoCal/J.G. Reuben described his location, at the corner of Halecrest Drive and Telegraph Canyon Road, Chula Vista. He told Mr. Stratton he saw him drive by and that Mr. Stratton should stop to say hello. The next day Mr. Stratton stopped at this location and talked with Reuben Mendoza. Mr. Mendoza stated that he was working on a SoCal job as the foreman replacing a storm drain for the City of Chula Vista. (He also has been identified as a superintendent for J.G. as described above.) At this job site, Ky Stratton. saw equipment painted .green which he recognized to be SoCal equipment, a 225 or 235 excavator, a SoCal water truck, and SoCal barricades. Ky Stratton also saw numerous employees who had worked on City Group Job 636 for SoCal. Ky Stratton reviewed a copy of Richard Andrade's expedited applicationto the State .Contractor's License Board and the list of SoCal employees who were to be "laid off' sometime in August 2000. Four of those listed J.G. employees were working on this-SoCal job site: Reuben Mendoza, Tony Barrios, Javier Mendiola, and Alfredo Salgado. (Declaration of Ky Stratton, Exhibit J.) -15- January 2001 - A. J.G. requested bids from subcontractors to prepare a bid for a City job. When the subcontractors called the cell phone number given for J.G., Jim Jackson (Vice President, Secretary and Treasurer -of SoCal) answered the phone. Ed Shoemaker would not reveal the names of the subcontractors because the subcontractors told him in confidence. They feared that by disclosing this information they would be "cutting their own throat[sj-" (Declaration of Ed Shoemaker, Exhibit S.) B. Ed Shoemaker saw a woman submit a bid to E&CP Contract Services Division on behalf of J.G. Pipeline, Inc. When she left, he saw her get into a truck which had a Southem California Underground Corporation, Inc. insignia on the side. (Declaration of Ed Shoemaker, Exhibit S.) February 2001 - A. A brief and accompanying documentation pertinent to J.G.'s post-SoCal debarment conduct was provided to J.G. in full as early as February of this year. That information is substantially the same information as the information provided to J.G. described below. May 10, 2001 - A. Although personal service is not required under the San Diego Municipal Code, the City personally served a draft-- of this City Manager's Reportand accompanying documentation on J.G. Pipeline, Inc-, Richard Andrade, Judy Ng Go and Jaime Pan-aga, through their attorney Andrade & Associates B. Although personal service is not required under the San Diego Municipal Code, the City personally served a draft of this City Manager's Report and accompanying documentation on Jim Jackson ata trailer on a lot at 9509 Hermosa Avenue, Rancho Cucamonga, CA 91730. C. The City left a copy of the draft City Manager's Report and accompanying documentation at George Frost's home address. Although personal service is not required under the San Diego. Municipal Code, the City attempted several times to personally serve George Frost at his various addresses on file. 1) George Frost's address of 1599 Seabright Avenue, Long Beach, CA 90813 is a vacant lot. z A draft Report summarizing the City's evidence was prepared and provided to J.G. to afford as much advanced notice to J.G. as possible. In order to ensure impartiality of the City Council, that Report was not formally issued nor provided to the City Council or City Clerk until subsequent to the SoCal debarment hearing. The draft Report was updated to include pertinent information obtained at the SoCal hearings. -16- 2) George Frost's address of 1045 South 43`d Street, San Diego, CA is a vacant lot. 3) Tom Musick went to George Frost's address to serve him with documents. At George Frost's home address, 418 West 39`h Street, San Pedro, CA 90731, a woman appearing to be approximately fifty years of age and of oriental descent opened the door. She indicated that George Frost would be unavailable for several days. She provided George Frost's cell phone number. A man who identified himself as George Frost answered the cell phone. After Mr. Musick described the documents to be served on George Frost, George provided an address of 9509 on Hermosa Avenue, Rancho Cucamonga, CA 91730. He provided directions to the site and stated he was staying there in a mobile home on the site. When Mr. Musick arrived at the site, no one answered the door, but a man spoke to him through a window and stated that George Frost departed a few minutes before. It was dark inside the mobilehome but Mr. Musick could discern that the man had a mustache, appeared to be Caucasian and in his early fifties. On May 10, 2001, Mr. Musick, familiar with Jim Jackson's Ford Explorer, followed Jim from his home to the same Hermosa Avenue address provided by George Frost the previous day. Mr. Musick inquired of Jim Jackson where Mr. Frost could be located. Jim made a phone call, addressed the person on the phone as George and stated, "There is a guy -here looking for you." Jim Jackson got off the phone andindicatedthat George Frost was not present, that he was not on the site, and that Jim did not know when George would return. Jim Jackson would .not.divulge any add itional.information regarding where George Frost could be located. Mr. Musick then personally served Jim Jackson as described above. Mr. Musick provided the documents to the woman at George Frost's home address. Approximately June 8, 2001 - Revised City Manager's Report No. 01-113 was. issued and personally served on J.G. Pipeline, Richard Andrade, Judy Ng Go and Jaime Parraga, at the law offices of Andrade & Associates. The City will use diligent efforts to personally serve. George Frost and Jim Jackson notice. CONCLUSION The totality of the information described in detail above indicates a willful effort on the part of SoCal/J.G. to circumvent the permanent debarment mandated by the City Council. Such corrupt practices violate in letter and spirit the principles of "responsible" bidding and are prohibited by law. -17- A swift and permanent debarment of J.G. is necessary to protect the health and safety of the citizenry, the full and open competition, namely the integrity of our bidding system, granting contract awards only to responsible contractors. ALTERNATIVES I . Debar J.G. for a period of three years. 2. Do not debar J.G. Respectfully submitted, Stacey Stevenson Approved: George Loveland Deputy Director Senior Deputy City Manager Frank Belock, Jr. Director Engineering & Capital Projects Dept LOVELAND/BELOCK/SS " -18- THE CITY OF SAN DIEGO MANAGERS REPORT DATE ISSUED: July 16, 2001 SUPPLEMENTAL REPORT TO REPORT NO. 01-113 REVISED ATTENTION: Honorable Mayor and City Council Docket of July 24, 2001 SUBJECT: Failure to Provide Information Solely Within J.G.'s Control Bearing on its Relationship to SoCal. Proposed Debarment of J.G. Pipeline, Inc., its divisions and organizational elements, its Affiliates, Richard Andrade, Jaime Parraga, George Rogers Frost, Judy Ng. Go, and James Jackson [These individuals, the corporate entity, its divisions and organizational elements, and its Affiliates will hereinafter be referred to as "J.G." for convenience and clarification].' This debarment is separate and distinct from the procedural process of the debarment of Southern California Underground Contractors, Inc., its divisions and organizational elements, its Affiliates, James Craig Jackson, and George Rogers Frost [These individuals, the corporate entity, its divisions and organizational elements, and its Affiliates will hereinafter be referred to as "SoCal" for convenience and clarification.) Reference:- Revised City Manager's Report Nos. 01-113, 01-068 and all documentation incorporated by reference. Both Reports.are incorporated into this Report by this.reference. I Where the full name J.G. Pipeline is used, it refers to the corporate entity itself. It also applies to the Southern California Underground Contractors, Inc. because they both are the same company operating under different names. INTRODUCTION J.G. has repeatedly failed to provide information solely within their control. This report is a Supplement to two Revised City Manager's Reports previously provided to you. As you know, SoCal was originally debarred on June 26, 2000. Four days later SoCal created another corporate entity named J.G. Pipeline, Inc. It is the City Manager's contention that SoCal created J.G. in order to circumvent the debarment and to continue doing business with the City. The individuals that created J.G. to circumvent the debarment include: Richard Andrade, Judy Ng Go, Jaime Parraga, George Frost and James Jackson. These parties, acting under the new name, continued the same bidding practices as they did under SoCal as described in the City Manager's Reports d J referenced above. As a result of their conduct, the City rejecte.G.'s low bids. Under San Diego City Council Policy 000-29, a bidder may protest a contract award and have an administrative hearing by a Protest Board. HEARING In February of 2001, a Protest Board hearing was held relating to five separate contracts on which J.G. was the apparent low bidder. This information was not previously included in City Manager's Report No. 01-113, because J.G. had filed a writ in Superior Court challenging the Hearing. Once the City noticed depositions pursuant to this litigation, J.G. dismissed these cases, as described below. At the Protest Board hearing, J.G. requested that the hearing include not only three bids rejected by the City in the fall of 2000, but also two additional contracts rejected in early 2001. However, at the hearing, J.G. changed its mind and argued that testimony and evidence should be limited to only those specific reasons for rejection enumerated by the City in the rejection letters for the first three contracts. J.G. objected to consideration of any.other evidence known to the City supporting the City's rejection. IfJ.G.'s motion were granted, J.G. argued the City would be precluded from introducing any evidence not specifically mentioned in the rejection letters. The Protest Board heard arguments on the motion, reviewed pertinent correspondence, took the issue under submission, and ultimately decided that all evidence was admissible in the administrative hearing. The Protest Board heard all evidence and testimony, engage m ex enswe ques coning of Dolnparties, an rued�iaJ G.- was :Soca Board.-upheld-r-ejection-of-J:G.-'s-bids_ - DEPOSITIONS Subsequent to that Protest Board hearing, J.G. filed two actions against the City. On June 12, 2001, the City noticed the depositions of Judy Ng Go and Jaime Parraga pursuant to the litigation. The depositions were to take place on June 25, 2001 (Jaime), and June 26, 2001 (Judy). However, on or about June 15,2001, J.G. dismissed the litigation. By dismissing those lawsuits J.G. now could argue that the City had no legal authority to compel witnesses to appear for depositions. It is possible J.G. will seek to refile this litigation subsequent to the debarment. We believe that a court would require a significant factual showing before.allowing J.G. to re- file. -2- Suspicious that J.G.'s dismissal of the litigation was to thwart the City's ability to depose Judy Ng Go and Jaime Parraga, individuals who possess crucial information regarding J.G., the City again noticed their depositions pursuant to the debarment. Two working days before the depositions were to take place Andrade & Associates, attorney of record for Judy Ng Go, Jaime Parraga, J.G. Pipeline and Richard Andrade, faxed a letter to the City. The letter indicated that Andrade & Associates no longer represented anyone other than Richard Andrade. The letter did not mention that the Andrade & Associates' office location was moving or had moved despite that Judy Ng Go's noticed deposition was scheduled to be held at the vacated office in a matter of days. By dropping the representation, Andrade & Associates' clients again avoided depositions. Although there is no absolute right to depositions in an administrative hearing, the City previously accommodated SoCal's request to depose six City inspectors prior to the June 2000 debarment even though no litigation was pending. Neither Judy Ng Go nor Jaime Parraga attended their depositions. On June 25, 2001, Deputy City —AttorneTSirrr-Vorr-Kalmowsl`� ,--and-a-court reporter, were-available-tmtake-Mr.-Parrage., ---- — deposition, but Mr. Parraga never showed. On June 26, 2001, Mr. Von Kalinowski and a court reporter arrived in Orange County at the Andrade & Associates law firm where Judy Ng Go's deposition was scheduled to take place. The office had moved. Mr. Von Kalinowski called Jennifer Friend and informed her he was at their vacated office. Jennifer Friend informed Mr. Von Kalinowski that Judy Ng Go would not be attending her deposition. Ms. Friend did not mention why Ms. Ng Go would not attend, nordid she say anything about Ms. Ng Go retaining a new attorney. However, at 10:40 p.m. that night James DeOlden, Esq., faxed a letter to the City stating that he represented Judy Ng Go and Jaime Parraga. His letter was back dated to June 19'x'. In that letter he objected to the depositions on the basis that all Superior Court matters were dismissed and as a result, the City had no legal authority to compel the depositions. Any information dispelling the aura that J.G. is SoCal operating under another name is entirely within the control of these individuals who have consistently and repeatedly refused to voluntarily provide information on this issue. Finally, the City encouraged the newly retained attorneys to have their clients voluntarily deposed. In that letter, the City informed J.G. that if they had any information disproving the --Contents—offthe Revised-City-Manager's-Report-No.-Ol;1-13-and No_ 01-=068, the City -Attorney's Office would recommend that the City Manager reconsider moving forward on the debarment. There has_been no response. -3- CONCLUSION SoCal and J.G. have committed and continue their corrupt practices. Swift and permanent debarment of J.G. is necessary to protect the health and safety of the citizenry, the full and open competition, namely the integrity of our bidding system, granting contract awards only to responsible contractors. Respectfully submitted, Stacey Stevenson Deputy Director Frank Belock, Jr. Director Engineering & Capital Projects Dept. LOVELAND/BELOCK/SS -4- Approved: George Loveland Senior Deputy City Manager Z00 eDed ORO r ` w'3 `XO34i E1t8ti9ti9Z9-� ma , _ � Y9�Z0 SO-OE-1eYt penls�ea M; TO THE In compliance to perform all incident instirs the office of th therein to the and to enter int within 50 work BIDDER decla Specifications,, uccepted for ai lump swn privi Cater into a con tl,e guartutty I ata BIDDER and forth in the cohipensation completed. T CONTRACT. expenses, taxi bid opening d and will readv gnvern over ei A SECTION C PROPOSAL for the construction of Fir Street Stogy h Drain - Phase 2— City Project No. 7507 and ta Avenue%Vajencia Street Storm Drain — City proiect No. 7521 in the CITY OF UREA MAYOR AND MEM>3ER5 OF THE COUNCIL OF BREA! ith the Notice Inyiting Sealed. Bids, the undersigned hereby proposes and agrees he work fl=eim;deseribed, and to fiv" all .labor, material, equipment and .e necessary therd'ore, in accordance with the plans and specifications on file in City Engineer of t}ie City of Brea. The undersigned agrees to perform the work isf'action of and itmder the .supervision of the City Engiiieer' of the City of Brea, a. contract at the Following prices. The undersigned agrees to complete the work g days including pipe delivery, starting from the date of the Notice to Proceed. s that this. proposal. is based upon careful exarriination of the work site, .plans, ismxtions to Bidders. and all. other .contract documents_ if this. proposal is !rl, BIDDER .egfees to -enter Into a contract with AUENC:Y at the unit and/or =t-furtli.in. tlfc _Fullowing_Bid-Schedule... BIDDE2Z..understands- that failure _to Lt .in the manmr and trine prescribed will result. in forfeiture to AGENCY of rripwrying II is p#TU.4; 1. ands that a bid is required-foi thr).cutiic wurk, that the es[imated quantities set Scheduilo ore i stilcly for thtpavposO of compaiiigi fids and that final let the contract will be bred upon tune actual quantities of work satlafnewrily AGENCY ItE R'VES_ 'THE R1014T TO -DELETE ANY ITIS FROM THE is agreed that the unit and/or lump sum prices bid include all appurtonant 3yalties, fees,.,.and will be guaranteed for a period of sixfrom ty days the lfat such tim�the corftract is not awarded, the AGENCY will reject ell -bids .e the project Int the case of discrepancies in the amounts bid, unit prices shall W amounts, anti. wards shnll goveraover figures: £Li8VVV9Z9 ss:GT 500Z/0E/E0 E00 aapd OH�IN 0 'X0�-0i B1lBggt9Z9- -- mtl . � g5�Z0 50=0�-�pN psn�a�ea If awarded Contract, the unde fined agrees that in the event of tho BlbbIIt'S dcfnull in executing the aired contract~ and filing the necessary bonds and insurance catcs within 10 World d. s after the date of the AGENCY'S notice of award of Contact to the g Proceeds of. Security accompanying this bid shall become the property of the AGENCY and IDDMt, the this bid and acceptance herepf may, at the AGENCY'S option, he ennsidered null aad :void, Accompanyin this. proposal of -bid, find B.'d ers RI S9 amount'i not_Iess than (4%° of the m amount of S_ !D %� which aggregate of the total bid price_, as required by the Notice - Inviting Seal. $ids, payable :to the AGENCY. (Please insert Me words "Cash", "Certified Check", or "B der's Bond", as the case may be). -Bidder shall s 'iy receipt of all Addenda here, if any.. Amend Na Date Aeicelved t, DS r' S nature .2—► -cis �j GZ 60 39Vd QJ coo 6LI801709Z9 55=51 s00Z/0E/co tog 01Ed CHOIN SVS 'X0�-ol EIlBVti9919 9 �dyS ZO 90-OE-JEA POA19508 SECTION C Fir Street Storm Dralit - phase 2- City Project No. 75U7 and "a an AYenucl yaylencia Strcr[.Sturm Drain - City project No_ 7521 Pxvlecl Bid Schedule rr)EM ES TI1viA ram yVTTTi UNIT i'RTC1; WRITTEN 1N WO}ZbS UNTl" YKIt;E EXTENDED NO.. iJ FIT Street Storm D to - Phase 2;Cr Piro l ect No. 7507 AMOUNT 1.1 1 Mobilization & Bonds 7t 6`L% `t"y",f Dollars ' o Cents '20)C,00. 2o)cco. 1.2 1 Traffic Control iS. (a@ OnQ 'fl�tiusa►tr.{ Dollars _ ct a CentsOGQ- 13 610 18" RCP 2001�D L.F. � Q. e� ,l►-,eo.� �%;.,-A,,t l�i'.�9ollars o Ce"ts 12 S. -76� 1.4 1 PCC PIP0 to Pipc Transifion StrudW-c pei APWA Std. EA. 340-1 cents Conc=tc Colla per APWA Std. 380-3 EA. @ OC 1.6 15 6" PCC Curb & Gutter (Type A-l) per ;Ay WA Std. L-F. 120-1 Dollais -�G 1.7 465 PCC Cross-Gutter and Club Return per City of Brea S.F. Sid. 209 Dollars65r3:-- 'e+-o: Cenm 1-8 1 PCC 13lallket pci "WA Std. 225-1- EA. {�v �i,,.A�.4-oci Dollars o Cents- Ly 1 Sho ' L S. @"" ..Dollars Cents 1.10 610 Temporary A.C. PaVemeiit LR Qa - i-Dollars Cents l D . 6 lGO �e Subtotal Fir Street Sto Arnim - Phase ars 39V b0d ' �'J ELTBbbb9Z9 55 =5i 500Z/0£/£0 9DO end OH�IN /,,-XM-01 EIlBt6ti9d9-'�� and ti9 Z0 So-DE-jen pen100H ITEM ESTIMA NO. U D ITZM WITH Y1I�tPT PRICE WRITTEN I1J WORbS Madrona ei 'Valencia ire Scor Draih Pio'eet LYN" PRICEMEXTLD— IM UNT 2.1 1 a 7521: Mobilizationl Bonds LS. ' @ ------ — rs Dolla 2.2 1 L.S.- Cents Golf Cusc Landscaping and litigation Restoration LaCflC'1-� C UdlIars 2.3 1,005 tL o• Cents 48" itup — 2000D % 10&0 L.h. @ Dollars 2.4 55 e�c� .ants 18" Rrp – 2600D 2.5 Dollars r0 Cents 12 06— 6c-- 4 EA. PCc Junction Chamber per APWA Std. 320.1 Q 1 Dollars cents. - 2.6 Brook 43636, ted Catch Drain EA. (), 2.7 bollart; * p C",t, 3/ 000-, 1 EA Concrere Collar e pr AY WA Std." 380-3 Dollars 2.8- l r pL cents - Sao;- •5oa,-- Shoo Dollars ii Dubin: Muri rona Avenue/ Valencia Street Storm Drain: �� O6"1�v 1 Dollars �37 � �.rVCj t 9Eo Lents �'• "" 0"mm limn — Phase 2 and Madrona Avenue) Valencia Strcei Storni E in i 3 �Pq Totmo " t lsid - Ea Stream ton7j Drain Phase 2 and Srozm in i ords- Madrona Avenue/��'V��alencia Street 90 3JCd C -2s om ELT8b17D9Z9 99:9T 900Z/0E/co 9D0. and ovw X03-01 E1l8Ytiti929-� � mdP9�Z0 50-DE-�ey� psn�o�aa LIST ON SUBCONTRACTORS In accordance 'th Government -Code Section 41.04, the Bidder shall set forth_ the name and business addres of each subcontractor who will perform work or refider service to the bidder an said contract in . mhotmt in excess of one-half of one percent of the total bid and the. portion of the work to be ne by such subcontractor. Portion 111u»te rrnrlA rens of SubcontraUor State License Class o Work Nu;nber By submission this proposal, the Bidder certifies: 1. That it able to and wild perforin the balance of all work which is not covered in the above bcoutractors listing_ 2. That th AGENCY will be furnished copies of all subcontracts entered into and bonds fiunish by subcontractor for this project. -3 90 39bd w ELT80009Z9 ss:GT 900Z/0E/E0 100 BDed CH31N '' 1'SVJ `Rpa-ol E1leYtiti9i9-e� ma ti9:Z0 40 -DE -Jell poAleaea NoNcoi,r:XYSIo.N .A.MDAVIT TO R F:CUTE16 BY BIDDER AND SUBMITTED WITHBID State of Calif is ss. County of 0 ge first duly sworn, deposes and says that he or she is r'c�iPn.t Of Gntcla.ltlaroz ConcnL foregoing bid the bill is nitit made in the inter ori or on the bebaif *=party u osEd person, panne 'p; company, tlssociation, organi2l6on, or co and not collas a or slim; thatHie bidder.has not directly or : �diiec induced ortsolicitedd11anY oilier bidder put in a false orIham bid, and bas not dlrectl connived,y or indirectly colluded, conspired, or with any bidder' anyone else to put in a sham bid, or that anyone. shall iehain irvrn dding;� that the bidder liar not in any mariner, directly or indirectly, soup, t by agreement, co' . uniCation, or conteretice witlt anyone to fix the bid primo, or that of any other bidder, or w i ate any advantage against the public bo awarding -the iitterested in proposed contrac • contract of anyone t, that. all statements contained in the bid are true; and, forth - that tate bI has not, directly or indireetly, subitiitted las or her bid price or' an ihcreof; or the tents thereof, or divulged information or data re Y akdown not a fee to relative thereto, or paid, and will payY Y corporation, partnership, company association,. organization, bid dcpository,� or to any mcut or agent thereof to erre=* a*le a collusive or span[ bid. Subscribed • sworn NOTARY P LIC L0 39Vd Juarez Cont anon )n0. odder P6..A0X -30q Bre c, Address of Bidder to bcfure me lliiy day of- , 2005. NOTARY SEAL C4 X0 £LT8bbh9Z9 95:5T 5007,/0£/£0 BUD etfed OH�IN �� s)*J 'X0 1 E11B➢➢9919-+ and➢5 Z0-50-DE-JtR PeAleaea CALIFORNIA /ALL PURPOSE ACKNOWLEDGMENT State of Call& County of Los e1Pe On e hTwu� t Z�S, before me, Julie M. Ormondroyd . Notary Public; personally appeared )im )ackson Personally known to me to be the person whose name Is subscribed to the within instrument and acknowledged to mo that ho executed the coma in hie nnthari7i:d capacity, and that by his Signature on the instrument the ,.,.��-+•��>'� ; x I�R DYD �, person, or the entity Upon behalf of which the person acted, executed the r r4 ;UL•„ ::R. ORF instrument. WITNESS my hand and official se51_ Signature `of : tarry Public Noce Norary Scal Thoogh the Infolllfilkq] helot. is not required by low, iLmay prove valuAble to perconc rdyinp on the doromrnt wn,l rnnLl prevent rtaudultnt X71) removal and manichmm of this form to another doeumml. pcsctiption of Att eIked Docnmetnt Title or Type ofDc ument: Document Date- Nulitim ofpagcs Signcr(a) Other 7h I Named Abovs - CspactWes) C)a ed by Signer Signer'sName: _Individual X Corporate Offs r Title(s):_Pres(dPm and Seoretaty _ l.im d_General _Partner- Attomey-iil-Fa _Trustee _Guardian (7th C1 _ Signer is Represe 1ng:_Garcia )uargz Construction, Inc. 80 mid £LTBbtih9Z9- 55:5T SoOZ/0£/£0 gpp eyed WIN . !a{BYtii•9Z9 � mdg4�l� 90-pE-tefl peAla�ea 1JM—TTY .AAGREEMENT HONOkOLE MAYOR AND CITY COUNCIL CITY OPUREA. CALIFORNIA Gentlemen: The undersign hereby promises:and agrees that in the performance of the work specified in the contract, kno as the IMPROVEMENTS, (1)(W,)(it) will employ persons, as. The s he defined, to: work in P Y and utilize only qualified facilitieproximity to any electrical secondary or tarismission ".'Qualified Person" is defined in Title 8, California Adminisiiative Code, Section ollows: "Quapiied Ye , n:. A person w116 by. reason of experience or instruction, is familiar with the - operalton to.6e performed acid the hazards involved " The .undersign also promised and agrees that all such worm shall be performed in with allaccordance .applica le electrical utili(y company's requirements, Public Utility Commission orders, tmd State of Cel ornia Cal -OSTIA requiremenrs. 7116 urldcrsign further prvinises, acid ams .that the provisions herein shall tic and are binding upon any subco tractor or subcontractors that may be tctaicccd ur employed by the undersigned, and that. the u ccsigncd shall take sops as a= ncccssary lu assure compliance by any said subcontractor ntractors with the requirements contained htut:itc. V�f�Sr cQ e,t -t Title Date: 60d ELi8bbb9Z9 - 5S:5T 500Z/0E/E0 No BDed oHoiN� �sv� Xo�-ot eliettrtisasf 1 . ®ati9�Z0 5D-OE-1eYl penie�oa bTSQUA; -.KATION QUESTIONNAME In accordance 'th Go vernment Code Seeiinn 1431D.S, the 13idder shall complete, under penalty of peijury, the bilowing questionnaire. QUESTIONNAIRE Has the Didde any officer of the Bidder or any eMPIDyee of the Bidder who has a proprietary interest in the idder ever.been disualified, reinoved or otherwise cntrd from ding on Or completing a decal, State or Ideal-' overnment project because of aeviolatio of lawanr a s fery _ regulation? l] Yes E No If the answer i yes, explain the circumstances in the space provided. Note: This leMionnajm constit"te_c a Mrt of the Pmpnsal, and .a signature portion of the Propo al shall constitutes signature of this gxlestinn»sire. 01 _-Dvcl C-6 is CAIMb9Z9 SS:51 500Z/0E/E0 ll0 Bded ON�1N( �_j�� `X01 f �. mdg9�Z0 50-DE-1eFl Pan�a�ea E1lBt1'i•9Z0 COMPENSATION INSURANCE CERTIMCATE pursuant to s on 1841 of the fitatc IANw Code, each: contractor to whom a public works contract has b awarded shall sign the foil lowing certificate_ t am a of the provisions of Section: 3706 of the Labor Code which require every employ to be insured against liabilil-y for worker's cornpensatiOn or to undertake self insuran in accordance.with the provisions of that code, and I will comply with such provisio before commencing the peiforinance of the work of this contract. z• cfilon Inc. Con for By Title C-7 11 31Cd ELT8titib9Z9 55=9T 900Z/0E/E0 Z10 Died onw 91.191+ a/Z0 edti9 Z0 9D-0�-tep1 Po�le50a UNDERGROi3Nn 9ERWCE ALERT 11DENMiCATION NUM$EFt be completed only by the awanlyd Contractor prior to excavation) No exr.Avat' will be permitted until this form is completed mid rctwoed to the AGENCY. Section 4216 4217 of the Cnvc nrnent Code requires a big Alert ldcutificatiun Numb before a 1° it to Excavate will be valid. er be issued Tu obtain a ig Alert lder'"cation Number, eAl Underground Service Alert at 1-800-422-4133 a miniII]um two working, days before scheduled.excavation. MgAlert Id tifrcadon Number: '!• S r` ki t, %t t�-(cs� t �,i Date: "0-,5 GafWa Juarez Cb uafion Inc. Con ,tor A- 3 -- $y' ii e Note: This . rm is required for every .Pig Alert Iderlhfkation Number Issued by USA: Buri the course of the Work Additional form may be. obtained from the AGENCY upon equesr. C-8 ZT 39d8 Ma ELi8bbb9Z9 55=5i 500Z/0E/E0 eto GIN WIN SVS �XO�-ol ` E1l8gpY9Z9-� mdy9�Z0 SO-OE-1eK penle�eb BIDDER'S INFORMATION BIDDER Cern r, that the following information is true and coned; G=lo Juarez coftftonon Ino. PiddeT Name susuness Address City, State Zip 56z 981-7.aya Telephone NWnber State Conifactor's License No. and Cl= Original Date Issued ExplratiowDatc The work site inspected,bY `T%'' i of our office on Ij 2005. The following person-,, firms, and corporations having a principal interest in this proposal: ET 39ttd ELT8bbb9Z9 99:9T 900Z/0E/E0 i!l0 aced WIN ` SVS 'X03 -C)1 E118M9Z9- �: mdtiS:ZO SD-OE-1eY1 Pen�a�oa The undersig otherwise. to the plans and Subscribed at d is prepared to satisfy the Council of the City of Draa of its ability, financially or erform the contract for the proposed work and improvcments in eu; ecifications set forth, cnnJance With Jia Ine. Signature of Bidder Printed or Typed Signarnre worn to before me this clay of ru I005. NOTARY P LIC NOTARY SEAT, Listed below i re the 'names, address and telephone- numbers for three pytblic agencies for Which the bidder has erformed similar- work within the past two years: Name an Address of Public Agency Naive mi Telephone No. of Project Manager. Contract ount Type. of Work Date Completed 2. Name Address of Public Agency I Lame anj Telephone No. of Project Manager. Contract Type of Work 3. � :Nwnen Address of Public Agency Telephone No. of Project. Manager, Dunt Type of Work C-10 Date Completed Date Completed bT 39tid 11 wo £LT8ti6b9Z9 55:5T 500Z/0£/£0 91.0 .erred CHOIR" V3 'X03-ol EtlBirtitr9Z9� 1_ mati9�Z0 90 -0E -lett penlsstta CALIFORNIA ALL-PURPOSE ACKNOWLEDOMENT Statc urcalifou i,2t County of Los A ngoles hrforr. me. Julie M. Ormondroyd , Notary Public- Personally appeared Jim Jackson Personally known to me to be the person whose name is subscribed to the wlthln instrument and acknowledged to me that he executed the same .7644' a+�•^••e4•t o in his huthorized capacity, and that by his 3igntuuro on the in3trurncnt tho ' per. -nn, nr the rnti a wi heha►f of which the person acted, executed the3iL instrument. �u. WITNESS my hand and official seal. Signature 6Q4o6iy Public Mace Notary seal vc Optional 3on Wow is not regbjred by taw. N may prove valpable to persons "tng on the document and could prcvcnt fraudulrrn- Thovgb the Informs removal and rtanaehment orthls form to another document. DescrlpUuu of +--,-.irrnmT- Document ebod x)oanment Title or Type of Date: Slgner(s) Othrt T all Named Abovc: Cap;1tily0ts)Ip mt d by Sipper Signer's Name: Individual X' Corporate O r - Tillc(s): ^Frc$idcnt and Seorctnry. Panner _Li ted General T_Anerrtey-ih-F -Trustee ^Guardian other. Signer is Repres ting. 12 Juarez Construction, Inc. Number of Pages 5I 39tid OWI. ELTBbb69Z9 55:51 500Z/0E/E0 9EO BDed OH31N 03 'X03-01 ELl8tY1!919-� mtlfi4�Z0 SO-OE-1eY( Panlesaa Rev 11/24/04 GARCM I iXA,I XG01y5TRUG"I'IDN, INC Contract References Projects completed by Jim Jackson while employed by SCI City of l lawaLn Gardens, 5667;000 "Carson Street brain", (Hawaiian Gardens) M. Elroy Ki�pke w/ Wildan (562) 908-6278 Compton Unified School District, $99,000 "Demolition ind Site Clearing'` (Compton) Mr. Jeff Truman w/ GKK (714)423-9804 Los Angeles County Depatvneni of Public Works, 51,471,000 "Atlantic Avenue - Phase IF' (Compton) Mr. JOluuiy 09boorian (626) 712=4820 Mr. Issa Ada*iya (626) 786-5807-,(626) 458-4931 Los Angeles County Departriient of Public Works,. 56,200,000 "Project 9037" (Long Beach) IVlr. Rene $r=axnontes (310) 487-9254 City of YorbB_Linda, 5723,000 "Denver Ave.uue Storm Drain" (Yorba Linda) Mr. Scott Walker (714) 875-4714 (714.) 986-9546 Los Angeles County Department of Public Works $138,000 "Proj�ecr554".(Montvvia)- Mr. VictorBCmmude (626) 688-8275 Los Angeles County Sanitmion Dfsalcts, $8,380,000 "Joint OutPdl "IT', Unit 2" (Parali ounE) Mr. David 13*ug (310) 830-8050 Mr. Dan Cory (310) 701-4925 Los Angeles (rbunty Department of Public Work$, S504,000 "110'h Street Orrin" (Athens) Mr. Jimmy Shadab (310)770-1990 Los Angeles County San itationDistricts. S1A04,000 "Wright Roaci_Replacement Trunk Sewer" (Long Beach) Mr. Jon Ganz -(310) 830-8050 City of Seal Beach, 5652,000 "Seal Beach 13otllevatd Rehabilitation" (Seal Beach) Mr. Gary Torfasetti (714) 412-2262 9i .3�tid - 6Li8VVV9Z9 55:51 508Z/06/60 .110 aged 6N31N Y3 ,Xt13 0l al Page 2 01 Contract El1B1'tig929 �_ �oayg:i0 90 -DE -JEW PaA1e0e8 City of Beverly Hills, $259,000 "Roxbury Drive Storm Drain" (Beverly Hills) Mr, Ara Maloyatt (310) 285-2557 County Department of Public Works, $1,102,000 "Access Roads Project" (Los Angeles County) Mr Jimmy Shadab (310) 770-1990 Los Angeles County Department of public: Wurks, $721',000 'Uollyhills Main" (Beverly 11ills) lei, Tony Tajoli (626) 695-7292 Los Angeles County Department of Public Works, s1,200,000 IiDe Soto Avenue Drain " (Chatsworth) Mr. Gary Ewells (626) 335-3966, (805) 338-3654. City of Rialto, 5270,000 "Baseline Waterline" (Rialto) Mr. Mark Devlin (909) 820-2533 Los Angeles County Department of public Works, 55,800,000 "Devonshire train- unit 1" (North Bills) Mr Del Quevedo (626) 45 8-63 10 Citybrv�,,;ul,, 51,220,000 "CIvID Sewer Phase II" (Vernon) Mr_ Vince RQdrigt= (323) 583-8811 Is Angeles CountyDepartrnent of Public "Worl , 52,300,000 Burnett Drain" (North Hi11s) Mr. head Abboud (626) 458-3104 Los Angeles County Department of Public Works.. $2,200,000 "Paula Drain" (Glendale) Mr. Ruben Ameaeua (323) 720-9768 Los Angeles County Department of Public Works, $880,000 Bombardier Uraixl" (Norwalk) Ms. Sumitha Shivel (626) 438-3104- LT 38-3104 Rev l It24/04 Lt 39Vd W EL18OPP9Z9 99:51 9ROVARIPP - 810 93md OH3IN ,.. tl� 'X03-01 ELt8 ti9Z Wdp9 Z0 90-o¢-�eyl ponleooa ' 31 Rasponsiblo Bidder— Supplemental Questionnaire 1. HOW my years has your organization been in business in California as a contractor, under ur present business -name and license number? _ L 'Years 2. What i your firm's Average Gross Revenue for the last three years? 3. Is your currently the:debtor in a bankruptcy case? ❑ Y Q�No If " yes," indi to the case number, bankruptcy court, and the date on which the petition was filed. Case N ber Bankruptcy Court Date Filed 4. Was yc ir firm in bankt*cy any tirue dwiug tl,c lasrt ii�vc yam,? Mis yuestlon refbrs unly to tbw4auptisy actiun that was nut dcacribcd in answer to question 2, above.) ❑ yr, 21"No If yes," indic to the case number, banlxuptcy court, and the date on which the petition was filed. Case N bei Bankruptcy Court bate Filed S. 146s an CSLB license held by your firm or its Responsible Managing. Employee (RIS) or ncihle ManaEing (mice r (RMO) peen suspended within the last five years? D Y CI�NO F_ At any inn the last five years, has your firm been a_csmted and paid liquidated damag after Completion; of. a Project, under a construction enntract'with either a publie or Privi c owner? ❑ Y d'No 7. Has y r firm ever defaulted on a construction contract?. 1' CNo If "yes," explai on a separate page. C -I1 8T 39bd O.MELT86bti9Z4 55�5i 5002/0E/E0 BID Died CH3IN ' IM 'X03-01 ElIWV929-01 �. mdkpto 50-OB-1eVi panlasea 8. In the t five years has your firm_ or any firm with which any of your oompany'9. Ow , officers or Vers was associated, been debarred, dismrAlif,ed, removed or o se prevented from bidding on, or completing, any govcmrne-nt agency or public works roject for any reason? dY No �1j,ii ..moo`►- otue go 4 v.'oitlrSdrt o'��i1a.tJ lf'yes," expl n on a separate page. State tho naive of the organ�'tzatioti debarred, the year of the event, the o r of'the project, and the basis for the action 9. In. the t five years, has your firm been denims' award of a public works contract haled on aft ding by a public agency that your company was not 8 responsible bidder? U Y . a -No If "yes," on a crate page identify the year of the.event, the entity denied the award, the owner, the PrDJeC14 the basis for the finding by the public agency. 1 t). Lt lith t five years, has any claim against your firm concerning your firth's work on a co 'tivi, pxuiect, been filed in court or arbitration? 0 Y GNo . if "Yes;" on a parate- page, identify the claim(S) by providing the project name. date of the claim, name .of the cl ' luarut, die ,tame of the entity the claim was filed against,. a brief description of the (tura of the a 'm, the court and case nuinber, and a brief description of the status of the claim (pending or, i solved, a brief description of the resolution). I. In the - t Prvo Ycats;.6as yow I-iitit made any claim against a project owner c°ncertun8 work o a project or paymctit for a contract; aW rlctl that claim in court or arbitration,? (> Y - No If "yes", vi, aIfen state page identify the claim .be providing the name of claiman the name, date ofelan, name of the entity t, l�IeM tY (or entities) against wham the Claim was filed, a brief description ofnature of the claim, the court and case, t,umbcr, and a IiriCf rlesc riptian of the status of the c(tending, ar if resolved, a brief description of the resolution. 12- Adieing the past five years, has any surety counparuy made nu E$On elialf as a result of A default, to satin an claims made Y payments on or fY Y _ against a Payment bond issued on your liirM s behalf in connection with a project, eithtrpublic or private_? D -Y ire! No GT 3Dtld 0M ELT8Vmzq 85:5T 5OOZ/0E/EO On sled ONJIN ISYS 'X03-01 et►etivvsz'� ma- q4 20 90-OE-teyt pentosoy 13. In the I tst five years, has.any insurance carrier, for any form ofinsuiaticc, renew refused to a insurance polio• for your firm? Q Ye UrNo 14. Has yo found r firm, or any of its owners, offiieers, or partners ever been liable in a civil suit, or jilty in a criminalntity? action, for to any .making any false claim riusrepr,=ntatioti or material ue- blic agency or V Ye Q`No 15. Iles yo invol ' firm, or any of its owners, officers or partners ever been convicted of a crime g any federal, state; or local law related to construction? D Ye �No If'yes," evi victim, the stat on a separate page, iucluditig identifying victPd; the name of the of the conviction, the cottri conviction. and case number, he es, and the grounds for the 16. Has yo state firm or any of its own ers, officers or Partners ever been convicted , of federal or a of fraudtheft,: or any other act of dishonesty? ED UrNo If "yes," identt tl,C crimes, and on a separate page, the person or persons convicted, the court and care number, a year convicted. I?. Ifyour rind was mquired to pay apremium ot•more than one ent for a nnanee cnt..bonaon-&q.PWjeM(s)-ou-svhiclr:your-IiMwork-ed lest an t an years, state thu P� a that ow firrri was regirin'd to y - -dari Y gam.. on for a perceu c rate Jif PaY- You may provide . than gher one per cent, if you wish to do so. 1$. Miring t e last five years, has your EM ewer been denied bona credit by .a swety or has tlrene eves been placed a peritxl Of tune when your has no surety bond in g a Public construction project when on w,is "Wired? ❑ Yee 19. Has C OSHA cited and assessed Penalties associate regttlatio against the t3eut:raI C for arty ontractor or its "serious,r"IIfW" or `repeat" violations of its sa(bty or health in the past five years? (Note.- If you b Appeals Board e Bled alt appeal of a citati6n, And the OccuFntiobal Saf and as -Dot yet ruled ioii your appeal, you need not include i»fornibunn about it.) G73 OZ 39Vd ELI8bti69Z9 99:91 GDOME/E6 lZD eted wig -'y3 IXOD-01 EilegYf9l9 � � _ map4 Zfl 90-OE-1eN Psnio�ea <I I ri 0�. WNo If "yes," on araie Page describe the citatinn�, the a date O. Citati Pah' 6��'t whom the cl[utlun waq made, ri, nature of Bi018tiott, project nn which the citation vvsa issued, uWner Of pt eject, end a amount of penalty paid, if any. State the decision_ case number and date of airy 13 OSHA 2U. Has Federal Occupational Safety and Health Admi Penn 'es cited and assessed es against the General Contractor or its associates in rhe past five yens? (Note: )f 8n ppeal of the citzltion has been tiled and the Appeals Tinatrd bas bot yet ruled, or There is a co appeal peAditiig, you need bot inelgde information about the citation,) 0 $ f No if "yes," ori arste page describe the citation, the date of i..ilati . nature of the PaTtY 09 1 whom the citation was made, v�olativit,. project on which the citation was issnr4, ourner of Project, and a amount of penalty Paid, if any. State the case number and date of any decision. •21. Ilas t*31C bocci more than one occasion dUiingthe.last five years in �+vhich the (ycr oral Coll . for of its associates was required to Pay either back to co ly with the state's p + req g wage laws? des or Penalties for failure ❑ Y l IN d to of on- date n aratc pair, d�5CTibe � 'violator, nature of each violation, dote of ata co action, tree public. en foi vvtcictt it was constructed, .naipe of the project, P the number bf employees wiio.were ani y underpaid euf the atitount of back wages and penalties that were assessed. the Inst fc_ve Yom,has,ili rrx-beerLmoxe-than. one.. o Con r or its nwocialcs have been peztall2ed or evasion -in -which the (}eneral . to co ly with the Federal Davis -13 on provailine d Pay beck des for fai]itre g wag requirements? D Y CrNo if s„ on ° P�"-', dc -w -T a the violator, n date of its lett , . atone of each violation, Heine of the project, o� public agency for which it was co who were inti ly underpaid au the amount ofback �' thy-humber-of employees wages and penalties that were assessed_ C-14 TZ pfd w ELi8VVV9Z9 99:91 900Z/0E/E0 Z1:0 Bled OHOIN: '` 'X0 1 Etl8gtiY9Z9 r mdg9-20 50 -UE -Jen peAlo398 C rry OF BREA, BIDDEn LIST All BiddCj,/py posers are regtured to provide tha following information for all bRF. and non - ME cuntracto s. who provided a proposal, bid, quote, ar were contiacted b This infortiiali n is also re uireii frofn the y the proposed name. with their bid/ to sel. 9 Proposed prime contractor, and must be submitted Ix► ' The city of Brea will use this information to maintain arta update a "Iliddcrs" list a+•sist in ilie overall annual DIAB oat seniA Firm. Garcia Juarez I UC;t1ortrltrVCc----- Phone: r- 2- 8`l- 73yb Addrem P.O.; BOX 369 00— Fax: 56 �8y- 734/ contact Persozi No. of years in business %_ Is the firm. cu tly certified as ME under 49 CrR. Pact 26? .01 YES [f -NO Type of work'. 'ces/materisls provided by firm? What was our rip's (timcs Annual recei for last carp • f�I,ess than $1 Million 0 LOSS than. S5 Million ❑ Less than $10 Million 11-tMitlim SIS L] More their $15 Million This form can if necessary to reliort all bidders (DBFs and non DBi✓e) iriformstiun. C-13 ZZ 39dd 033ELTBtit'ti9Z9 99:91 900Z/0E/E0 BIDDER'S NAME � CITY OF YORBA LINDA PROPOSAL FOR EOSP06 STORM DRAIN PLUMOSA DRIVE AND BASTANCHURY ROAD TO. CITY OF YORBA LINDA, as AGENCY: In accordance with AGENCY's "Notice Inviting Sealed Bids', the undersigned BIDDER hereby Proposes to furnish all materials,. equipment, .tools, labor, and incidentals required for the above stated project as set forth in the Plans,. Specifications, and Contract Documents therefore, and to perform all work in the manner and time prescribed therein. BIDDER declares that this proposal isbased upon. careful examination of the work site, Plans, Specifications, Instructions to Bidders, and Contract Documents.. If this proposal is accepted for award, BIDDER agrees to enter into a contract with AGENCY at the unit and/or lump sum prices set forth in the following Proposal Bid Sheet. BIDDER understandsthat failure to enter into a contract in the manner and time prescribed will result in forfeiture to AGENCY of the Bid Bond accompanying this proposal. BIDDER understands that a bid is required for.the entire work, that the estimated quantities set forth in the Proposal Bid Sheet are solely for the purpose of comparing bids, and that final compensation under the contract will be based upon the actual quantities of work satisfactorily completed. It, is agreed. that the unit and/or lump sum prices _bid include all appurtenant expenses, taxes, royalties, and fees. .In the case of discrepancies in the amounts bid, unit prices shall govern over extended. amounts. BIDDER understands that no bid will, be accepted from a. Contractor who has not been licensed in accordance with the provision of Chapter 9, Division- I11, of the Business and Professions Code of the State of California at the time the bid is submitted. Your attention is also directed to Section 70.28.15(e) of the Business and Professions Code_ BIDDER agrees and acknowledges that he is aware of the provisions of Section 3700 of the Labor Code which requires every employer to be insured against liability for workman's compensation or to undertake self-insurance in accordance with the provisions of that code, and that the BIDDER will comply with such provisions of that code before commencing the performance of this Contract if awarded to.it. Spc03-11 Yorba Linda - 13564 P-1 BIDDER certifies that in all previous contracts or subcontracts, all reports which may have been due under the requirements of any AGENCY, State, or Federal equal employment opportunity orders have been satisfactorily filed, and that no such reports are currently outstanding. BIDDER declares that the only persons or parties interested in this proposal as principals are those named herein; that no officer, agent, or employee of the AGENCY oris personally interested, directly - firm, indirectly, in this proposal; that this proposal is made without connection to any other individual, firm, or corporation making a .bid for the same work; and that this proposal is in all respects fair and without collusion or fi-aud. BIDDER certifies that affirmative action has been:taken to seek out and consider disadvantaged business enterprises foi those portions of the work to be subcontracted, and that such affirmative actions have been carefully documented, that said documentation is open to ffiinspection, .and that said affirmative action �hll.remain in effect for the life of any contract awarded hereunder.. Fwtherrnore, BIDDER certifies that affirmative action will be taken to meet all equal employment opportunity requirements of the contract documents. BIDDER'S NAME TE pec 2 1 2004 BIDDER'S ADDRESS- Po (3ox 30`? BY (Print Na Br ems. 6.4 (sign TELEPHONE NO, fLlt f2 y TITLE Subscribed and sworn to before me By this day of (Signature of NotaryPublic) (SEAL) Spc03-11 YOF-ba Linda - 13564 P-2 2004 TITLE (Print Name) (Signature) r r - - - - CALIFORNIA ALL-PURPOSE ACIti1IOWLEDGMEIj,f State Of(,alifoniia County of Los Angetes On bcforc me. Julie A1.Ormondro}'d .Notary. Public, Personallyappeared PP d Jim Jackson Personally known_ to me to be the person whose name is subscribed to the wilhin instrument and acknowledged to me that he executed t :...., ............................... in his authorized capacityand that b he same ure on the Y person; or the entity upon belial(of which the persgn.acted, executed tthe JULIE M. ORMONDRO(Q the R COMM. #1302326 G . instrument. 2 h'OTARYPUBUC=GALIfORMA s 2 LOS AHOELESCOUM 2 WITNESS m MY COMM. • y hand and official seal. .e........... ws............i ioiidl..w. ( n l Signature /f N01; y Public Place Notary Seal Above .Optional . Though the information below is not required by law, it may prove fovaluable to persons relying on the document and could prevent fraudulcn removal and r�altachmcnt is mr to another document - Description of Attached Document. Title or Type of Document Document Date: Number of Pages Signers) Other Than Named Above: Capacity(ies) Claimed by Signer Signer's Name: Individual X Corporate Officer - Title(s): Limited President and Secretary Genera _Panner -_l _Attorney -in -Fact _Trustee '_ Guardian ____Other: Siener is Representing:_Garcia Juarez Construction, Inc_ CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT State of California County of Los Angeles On (��C Oji 7 y before me, Julie M_ Onnondroyd Notary Public, personalty appeared Jim Jackson Personally.known to me to be the person whose name is subscribed to the within instrument and acknowledged to tile: that he executed the same "......•.......•.•........ in his authorized capacity, and [flat by his signature on the instrument the R — JULIE M: #13023 6 • person, or the entity upon behalf of which the person acted, executed the R COMM.:#1302326 instniment- . S NOTARY PUBLIC • CALIFORNIA 5 2 Los ANGELES C01MY 2 WComrn.Expires April 26,2005 WITNESS. my hand and official seal. :...« .......................e......: Signatur of Notary Public Place Notary Seal Above - Oplional Though the infurmation below is not required by.lau,. tt may prove valuable to persons relying on The document and co removal and reattachment of This fomr io another document - old prevent 6audulcnt- Description of Attached Document Title or Type of Document: Document Date: Number of Pages_ Signer(s) Other Than Named Above: Capacity(ies) Claimed by Signer Signer's Name: Individual ------------ X Corporals Officer - Tit le(s):_President and Secretary _Partner- Limited_ General _Attorney -in -Fact _Trustee _Guardian Other: Signer is Representing:. Garcia Juarez Construction, Inc. BIDDER'S 14AME LIST OF SUBCONTRACTORS BIDDER proposes to _subcontract certain .portions of the work, and to procure materials and equipment from suppliers and Vendors as follows (add additional pages, as necessary): Subcontractor Name Address License No. and Class Percent of Total Contract Specific Items of Work Subcontractor Name Address License No. and Class Percent of Total Contract Specific Items of Work Subcontractor Name -Address License No. and Class.. Percent of Total Contract Specific Items of Work Subcontractor Name Address License No. and Class— Percent of Total Contrac Specific Items of Work Spc03-11 Yorba Linda- 13564 PA BIDDER'S NAME .� REFERENCES The following are the names, addresses, and telephone numbers for three -(3) public agencies for which BIDDER.has performed similar work within the past two years: .AGENCY -Name_— Address_ / 9 SS C..�v+ is +..� / 1,'/ l • C.•h �t�i et' (�f 4'�� o l Telephone No _al_g) 7e> 1 S'Q 2S Contact. Description of Work .5coo-, o 90" R C P AGENCY Namea t Address o s, f $ d3 Telephone No. (3io) y87_ yzs4 Contact: Description of work _ //&CPO -, i+)r 79 d p AGENCY.Name_�Cm b p� `(�c,b�i,L �c%�r�S Address . !Zoo,S F�r-�erld�r-r Telephone No.F3i6) 770 / p 90 Contact /'I� SA��G b Description of Work Socvv. o F X1'8" lzc P DESIGNATION OF SURETIES The following are the names, addresses, and telephone numbers for all brokers and sureties from whom BIDDER intends to procure insurance and bonds: Name S L ^4 r,'4- Su rem -Address_ /S�9U ro/oorwo(o t3N� dos /}ntP�eS (, Telephone No,'.(3) X56 t Facy1// O�� 6 Name fir• --S A d dress_______6 8 6 Telephone No. C:9-7?) Narne Haeress - Telephone No Narne Telephone No, SPC03-11 Yorba.linda - 13564 P -S c 3•. CONTRACTOR'S LICENSING STATEMENT BIDDER certifies that the following is true and correct. T71e_unders.igned is licensed in accordance with the laws of.the State of California providing for the registration of CONTRACTORS. CONTRACTOR'S License Number y o / Name of Individual CONTRACTOR(Print or type): Signature of OWner(S} Business Address or Name of Company Business Address Officers: Name Title Name Title Name Title. or Name of Corporation �%IF flffld�r 3o.q.. Business Address P.C: 92 Corporation organized under the laws of the State of Subscribed and sworn to before me this day of 2004 c, tur of Pr , " nt o Corp./Company Signature of Notary Public) Si. re of Secr of Corp./Company (SEAL) (SEAL) Spco3-11 Yorba Linda - 13564 P-6 "CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT Stateof California County of Los Angeles On before mc,lulic M. Onnondroyd , Notary Public, personally.appearcd Jim Jackson Personally known to me to be the person whose name is subscribed to the within instrument and acknowledged to me that he executed the same in his authorized capacity, and that by his signature on the instrument the ............................. persorr, or.ihe entity upon behalf of which the person acted, executed the JULIE M. ORMONDROYD G instrument. R COMM. #1302326 fT S NOTARY PUSUC-CALWORNIA S WITNESS my hand and official seal 2 LOS ANMI B COUNTY ? My Conlrtt. [XWMn April 26, 2005 Signa�eof-W�Olary Public Place Notary Seat Above Optional (hough the information below is not required by taw, it may prove valnablc In persons relying on the document and could prevent fr removal and reauachment of this form to another document. audulent Description -of Attached Documeut Title or Type of Document: Document Date, Number of Pages Signer(s) Other Than Named Above: CapacitAies) Claimed by Signer 'Signer's Name: Individual X Corporate Officer - Tille(s):_President and Secretary . _Panner Limited_General _ Anorney-in-Fact _Trustee _Guardian Other: Signer is Representing:_ Garcia Juarez Construction, Inc. STATE OF CALIFORNIA Arnuld Schwarzenegber, Gor�rrnor DEPARTMENT OF INDUSTRIAL RELATIONS www.dir.ci.gov DIVISION OF APPRENTICESHIP STANDARDS 455 Golden Gate Avenue, 10th Floor San Francisco, CA 94102�ECEIU E ADDRESS REPLY TO: Tel: (415) 703-4920 Div_ of APprenticesLip Standards Fax: (415) 7035477 P. O. Box 420603 JUN 1 5 7006 Sar Fronclsco, CA 94142-0603 02/06/2008 09.53 626633' LABORERS SCHC PAGE 02/02 Southerly California Laborers Training School & Apprenticeship Program February 6, 2008 Pierre Weakley Center for Contract Compliance 1168 E. La Cadena Drive, Suite 202 Riverside, CA. 92501 Re: Apprenticeship requirements for Garcia Juarez - O'Neil Park Sewer Conversion project, Dear Mr. Weakley, 1 am writing this letter in response to your inquiry regarding the apprenticeship requirements for the above-mentioned contractor/project- Did the contractor file a D.A.S.140? YES nX NO D Did the contractor request dispatch of an apprentice? YES 0 NO Q Should you have any further questions, please call me at 626 -610 -1700 - Sincerely, Mary Vizcaiiao ,Apprenticeship Representative Laborers Training School & Apprenticeship 1385 West Sierra Madre Avenue, Azusa Ca 91702 • Phone (626) 610-1700 • Fax (626) 633-0204 Exhibit A Q_ —,�jc 3 FILE NO. ED43049 PUBLIC FACILITIES & RESOURCES DEPARTMENT CONTRACT CHANGE ORDER NO. I AGREEMENT NO. D06-028 For: Construction of: O'Neill Regional Park Sewer Conversion To: Garcia Juarez Construction, Inc. Contractor You are hereby directed to make the following described changes from the plans and specifications, or do the following described work not included in the plans and specifications for this contract. Description of work to be done, estimate of quantities, and prices to be paid as determined in accordance with the Specifications: As directed by the Engineer, provide all labor, equipment and materials to perform the following work in accordance with Section 3-2, "Changes Initiated by the Agency", Section 3-3 "Extra Work" and Section 3-4, "Changed Conditions" of the Standard Specifications for Public Work Construction and the Special Provisions: I. Extra Work at an Agreed Upon Unit Price: Provide. labor; materials, and equipment to install approximately three -thousand (3,000) linear feet of six-inch (6") domestic waterline_ Cost to include excavation, removal and proper disposal of interfering portions of existing asbestos concrete pipe, new pipe placement, lateral connections, testing, trench backfill, and asphalt repair. Agreed upon cost of $160.00 per linear foot for 3000 feet for an estimated cost o£ .....:................. $480,000:00 TOTAL ESTIMATED COST OF THIS DIRECTIVE ................... ..........................$480;000.00 Page 1 of 2 O'Neill Regional Park Sewer �_ -version Garcia Juarez Construction Exhibit A CCO No -1 Page 2 ----------------------------------------------- ___ SUMMARY OF CONTRACT COST STATUS: Original Contract award: $5,763,690.00 Approved as to Form Preceding Changes $ 0.00 County Counsel This Change (+)$ 480,000.00 New Estimated Contract Cost $6,243,690.00 NET CHANGE (ALL CHANGE ORDERS) (+)$ 480,000.00 B}c 8 { 26 ---------------------------------------------------+-1 By reason of this change order, the time for completion shall be extended fifteen (15) working days. ------------ -WeWe, , the undersigned contractor, agree that if this proposal is accepted, We will provide all equipment, furnish all materials, except as may otherwise be noted above, and performall services necessary for the work specified. In addition, our signature offers and indicates acceptance of prices quoted herein as full compensation for all direct and indirect costs for all work described above, and as full compensation for any effects this change ma .have on the project in its entirety and/or on the time required to complete the project Acce ance ate f 2 2 a0 % Contractor: Garcia Juarez Construction Inc. By: Title: pr _e HBP Conc By: - Title: f/H/�� ��111^�Ci .S�is�niirnr Submitted B Approval Recommended: avid L. Rocha, P.E. pher.G_ ubasek, P.E. Senior Resident Engineer Engineering Supervisor Approval Recommended: 10 Victor. Valdovinos, P.E. Manager. APProved By_ Date: Chair, Board of Supervisors Signed and certified that a copy of this document has been delivered to the Chair of the Board . Darlene J. Bloom, Clerk of the Board Page 2 of 2 AOEN11V- S1 AI'F KEPOWF http://cams.ocgov 1011916_2007_file. AGENDA STAFF REPORT Agenda Item ASR Control 07-001917 MEETING DATE: 10/16/07 LEGAL ENTITY TAKING ACTION: Board of Supervisors BOARD OF SUPERVISORS DISTRICT(S): 3,5 SUBMITTING AGENCYIDEPARTMENT: - Resources and Development Management Department (Approved) DEPARTMENT CONTACT PERSON(S): Victor Valdovinos, _(714) 56777801 Hiram Downard, (714) 567-7812 - SUBJECT: Approve Contract Change Order -O Neill Park Sewer Conversion CEO CONCUR COUNTY COUNSEL REVIEW _ CLERK OF THE -BC Concur Approved Agreement to Form Disci 3 Votes Board M; Budgeted: Yes Current Year Cost: $480,000 Annual Cost: N/A `Staffing Impact: No # of Positions Sole Source: N/A Current Fiscal Year -Revenue: N/A Fundng.Source: Harbors, Beaches& Parks Fund 405:4 00% Prior Board Action: May 2, 2006, Agenda Item No. 26 RECOMMENDED ACTION(S) 1. Find that the. subject project is Categorically Exempt (Class 2) from the provisions of CEQA pursuant to Section 15302 of the CEQA Guidelines. 2. Approve Contract Change Order- No. 1 to Agreement No:_ .D06-028 ' with Garcia -Juarez Construction, Inc. for $480,000. SUMMARY: Approval of this Contract Change Order will fund replacement of anaging waterline which will provide O'Neill Regional Park and its visitors with a reliable, low maintenance water system well into the future. BACKGROUND INFORMATION: The O`Neill Regional Park project includes replacing the 50 year-old septic tank and leach field sewer system. with a sewer main and lateral pipes that connect to the Trabuco Canyon Water District sewage 1 of 2 11/7/2007 4:17 PN AGENDL STAFF REPORT hrp://cams.ocgov .(Web_Publisher_Sam/Agendal0_16_2007_file.. treatment system. On May 2, 2006, your Board approved the contract with Garcia -Juarez Construction Inc. (GJC) in the amount of $5,763,690 for the Sewer Conversion. After commencing construction, GJC discovered that a 6 inch diameter water line serving the Regional Park, (installed in the early 1960s) would conflict with the sewer line installation. The location of the water line was inaccurately mapped on the 1960's as -built plans and the conflict was not known until construction was commenced. The existing water line is constructed of asbestos concrete pipe known as transite. Experience has shown that transite pipe of this age is brittle and subject to cracking where connections are made. Rather than relocation, Resources an�t Development Management Department (RDMD) recommends " installation of a new six inch diameter polyvinyl chloride water line through a Contract Change Order (CCO) as part of the sewer conversion and abandonment of the transite line. This CCO (No. 1) directs GJC to install the approximately 3,000 linear feet of water line as extra work at a.price of $160 per linear - foot for .a total- of $480,000. The CCO.w'ould-extend the time for completion by an additional 15 working days. The unit price of $160 per linear foot is competitive with similar projects. The CCO would be more advantageous than bidding the water line project because the bidding process would require substantially shutting down the sewei line project until the new waterline was advertised, bid and constructed This would cause a significant delay to the sewer project that would result in the cancellation of several major group activities scheduled in the park as well as the probability of a substantial delay claim by.GJC. Installation of the new line eliminates the potential for future increased maintenance costs on the transite dine. In addition; due to the park's aging water system, pressure to its fire hydrants .had been substantially reduced to avoid damage to the transite line. The new line will allow water pressure.to be increased, which will improve firefighting capability in the park should it ever be needed. CALIFORNIA ENVIRONMENTAL QUALITY ACT (CEQA) COMPLIANCE: The subject project is Categorically. Exempt (Class 2.) from. the .provisions . of CEQA :pursuant to Section 15302 of the CEQA Guidelines because it involves the replacement of an existing waterline system .in approximately the same, location and for .the same purpose. as the. original system being replaced. EXHIBIT(S): Exhibit A - Contract Change Order No. 1 to Agreement No. D06-028 Exhibit B - Location Map 2 of 2 1012007 4:17 Pt `THE LABORERS SCHOOL LABORERS TRAINING b RETRAINING TRUST OF SOUTHERN CALIFORNIA Southern California Laborers Trainin�� School & Apprenticeship Program February 11, 2005 Patrick Clifton Center for Contract Compliance 1168 E. La Cadena Drive, Suite 202 Riverside, CA. 92501 Re: Apprenticeship requirements for Garcia Juarez Construction — Citywide Sanitary Sewer Improvements project. Dear Mr. Clifton: I am writing this letter in response to your inquiry regarding the apprenticeship requirements for the above-mentioned contractor/project. Did the contractor file a D.A.S. 140? YES NO [�]X Did the contractor request dispatch of an apprentice? YES NO [XX Should you have any further questions, please call me at 626-610-1700. Sincerely, Mary Vizcaino Apprenticeship Representative Laborers Training School & Apprenticeship %i-Ii Y OF RIVERSID1 JAiL f Page 1 of 1 CONSTRUCTiOM RErOR e Project 06522 SEWER PIPELINE CAPACITY IMPROVEMENTS Contractor Garcia Juarez Construction L ocalion La Cadenza Dr., Spring Garden St Columbia SubcontractoAve. and Palma Rita AVB. r Inspector Anthony B. AllenOn duty ty 8h00 to 16h00) CONTROLLING ITEM: NUMBER EQUIP # WORK PERFORMED 3 . rhe Contractor removed the forms and prepared to place permanent AC in the saw cut areas from the previous days work. The Contractor informed the Inspector that they would not be working on the laterals that needed to be replaced according to the City standards. Ruban also informed the inspector that they would not be providing any more a fist of the labor on site. The Contactors forces were working on replacing the guardrail while this conversation was taking place. The Inspector told Ruban that if he was no mot a permitted to provide the names, the superintendent would be re uird to each and eve da y Provide a 1; of names_ Ruban requested the inspector to s q peak with Jim about the matter. After a heated debate with Jim on the phone and et after referring him to the Green book requirements, the Inspector issued a correction notice requiring the list of names and also a correction notice requiring proof of how asbestos pipe debris had being disposed of During the compilation of these documents, George Frost arrived on site and immediately began an aggressive attack both verbally and physically on the Inspector in that he Ind to grab a tape recorder out of the Inspectors hand and raisedhis fists. The Inspector warned him he would forcefully restrain him. George was told to move away from the vehicle and when he refused, ;nse touched him Beiare the Police arrived, George left the site. again, pector called 911. The COr.tractor told the Inspector that they would not finish the work on the guardrail and together with Sean and Dan informed the Contractor -that if the were leaving the site. The Ins _ __ ,- Inspector. guardrail safe, :he forces to do so at the Contrartors expense. The Contractor th n comple ed the guardrail and remov dI ly would bring ir, their all their oerso equipment to their storage yard after receiving a corection notice r nal ;nil regarding this. No tilt of labor was Additional Equip. J/D Broom Tractor RB -3 (Oh)provided for the I tours worked. . J/Deer 510C Back Noe Compactor (0h). 10 Wheeler Dump Truck 9 41 (7K98157) (Oh). Trench whacker (0h). Mikasa trench compactor 998186 (0h). CAT 910 Front End Loader. Plate compactor. (Oh) - TRAFFIC CONTROL COMMENTS: DESCRIPTION 93 BH31HOURS I PERSONNEL 31 OD John Deer Backhoe ` _ - _ CLASSIFICATION L18 2 Ruben Mendoza - HOURS - .544H J/D Front End Pi -- Pe Loader 1 Lope -- - --- -- ForemaNppe�a� 4 tJC13 235 CAT Excavator `Jesus Lopez ----- _----- -' "' Laborer 0 Jaime Asce -' 9817417 10 Wheeler Dump Truck - -- - - -_ 4 Laborer €Davki Flores - 4 8K59677 Crew (Pb Pickup _ --- - -- - - ----- --_ - - ----'- 4 Laborer 4 4ZO9112 Flatbed Service Pickup .Gorge Valdez - -- -- -- — _ 4 - ;Adolfo Pacheco - Labom 6X53434 - - - n Utility Pickup --- -- 4 AleturWro No — Operator 0 487189 ingersoL Rand Lighting Plant . - - — - -- - - - — 0 :Samuel Pucheco - --- - Laborer , - - VVT-06 Ford Water Truck -- --- -- -- - 0 544E John :Ramon Brisseno - - - ---- Deer Front End Loader ----- _ _---"----- - Operator _ - . _ 0 5,119884 - --- - 10 Wheeler Dump Truck `— 0 - - Laborer EX 12 - __ . _ osendo Akxx er — 235 CAT ExcavatodCom "--- - - - --- ---. -_ -.- _ __ pactor :Jose Luis Vu - Contract--- - - -- ------ -- - - _--_ - ------ squez _ - a--�------ ---0 Weather '- _ Da Days Used - Extra Work ----------- ---__Laborer 8 Days Remaining Days _.------ _ 7ota1�-- - - 1/31/2008: 10:37 AM Signature Jan -30 Jan-xls 113012008 Wednesday Start 8h30 Stop 14h00 AM Traffic Light PM Traffic Light Weather Clear Cloudy Rain Wind Still Moderate High Humidity Low Moderate High AM Temp ° 45 PM Temp 5 WORK PERFORMED 3 . rhe Contractor removed the forms and prepared to place permanent AC in the saw cut areas from the previous days work. The Contractor informed the Inspector that they would not be working on the laterals that needed to be replaced according to the City standards. Ruban also informed the inspector that they would not be providing any more a fist of the labor on site. The Contactors forces were working on replacing the guardrail while this conversation was taking place. The Inspector told Ruban that if he was no mot a permitted to provide the names, the superintendent would be re uird to each and eve da y Provide a 1; of names_ Ruban requested the inspector to s q peak with Jim about the matter. After a heated debate with Jim on the phone and et after referring him to the Green book requirements, the Inspector issued a correction notice requiring the list of names and also a correction notice requiring proof of how asbestos pipe debris had being disposed of During the compilation of these documents, George Frost arrived on site and immediately began an aggressive attack both verbally and physically on the Inspector in that he Ind to grab a tape recorder out of the Inspectors hand and raisedhis fists. The Inspector warned him he would forcefully restrain him. George was told to move away from the vehicle and when he refused, ;nse touched him Beiare the Police arrived, George left the site. again, pector called 911. The COr.tractor told the Inspector that they would not finish the work on the guardrail and together with Sean and Dan informed the Contractor -that if the were leaving the site. The Ins _ __ ,- Inspector. guardrail safe, :he forces to do so at the Contrartors expense. The Contractor th n comple ed the guardrail and remov dI ly would bring ir, their all their oerso equipment to their storage yard after receiving a corection notice r nal ;nil regarding this. No tilt of labor was Additional Equip. J/D Broom Tractor RB -3 (Oh)provided for the I tours worked. . J/Deer 510C Back Noe Compactor (0h). 10 Wheeler Dump Truck 9 41 (7K98157) (Oh). Trench whacker (0h). Mikasa trench compactor 998186 (0h). CAT 910 Front End Loader. Plate compactor. (Oh) - TRAFFIC CONTROL COMMENTS: DESCRIPTION 93 BH31HOURS I PERSONNEL 31 OD John Deer Backhoe ` _ - _ CLASSIFICATION L18 2 Ruben Mendoza - HOURS - .544H J/D Front End Pi -- Pe Loader 1 Lope -- - --- -- ForemaNppe�a� 4 tJC13 235 CAT Excavator `Jesus Lopez ----- _----- -' "' Laborer 0 Jaime Asce -' 9817417 10 Wheeler Dump Truck - -- - - -_ 4 Laborer €Davki Flores - 4 8K59677 Crew (Pb Pickup _ --- - -- - - ----- --_ - - ----'- 4 Laborer 4 4ZO9112 Flatbed Service Pickup .Gorge Valdez - -- -- -- — _ 4 - ;Adolfo Pacheco - Labom 6X53434 - - - n Utility Pickup --- -- 4 AleturWro No — Operator 0 487189 ingersoL Rand Lighting Plant . - - — - -- - - - — 0 :Samuel Pucheco - --- - Laborer , - - VVT-06 Ford Water Truck -- --- -- -- - 0 544E John :Ramon Brisseno - - - ---- Deer Front End Loader ----- _ _---"----- - Operator _ - . _ 0 5,119884 - --- - 10 Wheeler Dump Truck `— 0 - - Laborer EX 12 - __ . _ osendo Akxx er — 235 CAT ExcavatodCom "--- - - - --- ---. -_ -.- _ __ pactor :Jose Luis Vu - Contract--- - - -- ------ -- - - _--_ - ------ squez _ - a--�------ ---0 Weather '- _ Da Days Used - Extra Work ----------- ---__Laborer 8 Days Remaining Days _.------ _ 7ota1�-- - - 1/31/2008: 10:37 AM Signature Jan -30 Jan-xls City ofRiverside NOTICE OF POTENTIAL CLAIM /'1e. Oar s *,w e_ NOPC # / FOR CITY SE ONLY Received by Date D p CONTRACT BID NUMBER 65 � DATE 9/,5/07 This -is a Notice of Pofential Claim for additional compensation pursuant to Section 3-7 01 the Specie) Provisions. The particular circumstances of this potential dafm are described in detail as follows: �on raeyc, r d ���Je�P YC' P r pig The reasons for which 1 belleve additional compensation and/or time may be due are: r The nature of the costs Gnrolved and the amount of the potaritlal claim are describedas Follows (IF accurate cost figures are not available. provide an estimate, or describe the types of expenses involved.) The undersigned orlgfnator (Contractor —Subcontractor as apprcpdate) certilles thaPthe above statements ary made In Tu!/ cognizance of the Gaff lar a Fels® Claims Act ,W a ,&d,0 Code sacllons 12G5tf-12M The undersfgned further understands and agrees that this poterrtlal ciahn to be further eonsldered unless resolved, must be restated as a claim in res Proposed anal es*Mte in accordance with Sectron 9.4 oftim Standard Speust be ons posse to the City's EZ copstruction !no. ;TOR or CONTRACTOR (Circle One) WNCE1I�-ThIf notice ofPotentlal claim is acknowledged anI forwarded by OCT 3 G 2007 P"11E CONTRACTOR F-CAt"Riverside Public Works Deportment (Aulhorfzed Represenlalive) Ci o Riverside NOPC # NOTICE OF POTENTIAL CLAIM FOR CI E ONLY Received by Date DO IV e. Ua�s%.r.ve CONTRACT BID NUMBER DATE --- This is a Notice of Potential Claim for additional compensation pursuant to Section 3-7 of the Special Provisions. The particular Wrcumstances of this potential Waim are desuibed in detail as follows: Cc"n'hf 0Lr--fC4 y- C'j a pd 0l� y-fA �',elt 4'�- S%td�/L O►� Ih� Cc;nu-rcc--t- Pk -'--s The reasons for which I believe additional compensation and/or time may be due are: t; 7' �:�� ,'✓► C u- � r �Pn�C Q � r `X, O�.c / c -v 4 r� po-fhd76A r The nature of the costs Involved and the amount of the potential Wail" ora desenbed as follows: (If accurate cost figures are not availabte, provide an estimate, or describe the types or expenses involved.) u. /),-q The rxrdree "th originator r -l" Claims or Subcontractor as appiopdaW ceriffies that the above statements are made /n hill co9nhar►ce ofihe.CaA/omta False Claims Rcy Goveinment Code sections 1?850-12835. The undersigned further understands and agrees that tills pote»tlal claim to be further considered unless resolved, must be restated as a eMlm hi response to the City s Proposed final t sfimate In accordance with Section 9-4 of the Standard Spedifcailons Prez Construction ]no, LTOR or CONTRACTOR (Circle One) r L/ tf++Rnonzeyep Fo r hf, notica of potentia! Ga1m fs acknowledged and forwarded Dy OCT 3 0 2007 P O City of Riverside 10kP0WkAVbrks Department (n�rnorfZadRe presentative) City of Riverside NOTICE OF POTENTIAL CLAIM NOPCN 3 EFOR C USE ONLY Received by Date O O TO �� per 5.;.,r.o�s CONTRACT BID NUMBER DATE /o// 7/o-7 This is a Notice of Potential Claim for additional compensation pursuant to Section 3-7 of the Special Provisions. The particular circumstances of this potential claim are described in detail as follows: The reasons for which i believe additional compensation and/or time may be due are: Co -,"A -r - Plc --is shC'G'-1 1117 Cal �t� (bou) w,-`+ k -'2`/X V F a CIeo_po-.,e t The natureof the costs involved and the amount of the potential claim are described as follows: (It accurate cost figures ae n le not provide an estimate, or describe the types of expenses involved.) +10' ✓l a-/ �f- 11�1- u -io lk The undarslgned originator (Contractor or Subcontractor as appropriate) certifies that the above statements are mads in full cognizance of the Califomin False Claims Act Government Code sections 12650-12655. The undersigned further understands and agrees that this potential claim to be further considered unless resolved. must be restated as a claim in response to the City's proposed final estimate in accordance with Section 9-4 of the Standard Specifications. Garcia or CONTRACTOR One) Fgr'subcontractor notice of potential claim RECEIVE® This notice of potential claim !s acknowledged and forwarded by . PRIME CONTRACTOR FORM REMED 041OW" City of Riverside (Authorized Representative) Public Works Department NOTICE OF POTENTIAL CLAIM C'/icy o'/�� ��Prs•�2 _tV of RZVP '.wa NOPC # �_ DATE _Gc-- /9 -.2007 This is a Notice of Potential Claim for additional compensation pursuant to Section 3-7 of the Special Provisions. The particular arcimu►ancesoff this potential Galin are described in detail as follows: Y q 6C1cal e— : _S -h-t)-', � & t,Q 1- -7 % r / pro't-ec_a-e15'1 4 5er1J.ze_ Q �- S'f,u_j�0� /z-� S-3 . /� SPCC w GC u rt sh vw•y Settil.'l�_ The reasons forwhicb 1 believe additionafcornpeasatlon and/or time may be due are: .._..... _...... _fc.cJ ...-._ _ . _. _.. . (,t�v-�.0 olt�'2 Yo Cc9 rale i•, sc+,...5' ►jt yr�.,to( The nature or the costs Involved end the amount of the potentia! Ga)m are described as follows: (If accurate cost figures are not avaflabls, provide an estimate, or describe the types of expenses involved.) ./f �P• � i �"�s �- `a,b m r PKryy�r-t e-r-�` e The undersigned originator (Contractor or Subcontractor as apprtp►iat, certllies that the above statements are made In full agrees that tithe CalNal C False Claims Acy G jd,,d fit Cods sections 12650--t2d33 The undersigned further understands and agrees that ih/s pt naly l claim to n hrrther ctnsldered unless resoled. must be rest~ as a claim irr ►rsporrse to the City's Prtposed final estimate in accordance with Section S-4 Of the Standard Specilfcatlonx oyez Construction Inc. '.:TOR Or CONTRACTOR (Citde One) For rTePrasentafire) subcontractor�t�����nJ.""'7f""' This notice or potentlar clabn Is ac*rrpw,� !9a and Ibirwarded by RECEIVED Gorcio Juarez construction Inc. 1MME CONTRACTOR OCT 3 0 2007 Foftv Rrwww City of Riverside (Aulhaized RePrasentatrve) Public Works Department City of Riverside NOTICE OF POTENTIAL CLAIM NOPC p S FOR CITY USE ONLY Received by Datt f0 s,:"..o .s CONTRACT BID NUMBER co 5 2 DATE /o L This Is a Notice of Potential Claim for additional compensation pursuant to Section 3-7 of the Special Provisions. The Particular Orcumstances of this potential Ualm are described in detail as follows_ co'^4-"C � e9 r -,-� o fxo ire a _ [ I C 'P enact CL /h e o j1% The reasons for which 1 believe additional co Pensauon and/or time may____.,_ .. �'�"� 4n� 7�t�s mum-s.��e - of,�►„Ql Chi e o� f >c� ► P� iliThe nature of the costs Involved and the amount of the Potential claim accurate cost figures are are described ab follows_ not available, provide an estimate, or describe the types of expenses involved.) -- - -- �'`.�- The enderslgned or'Or-lor(ContraclorOrSubconbactoras cognhance of the Callibrnla False Calms Act, Gaveirnnent C s date) c"fles that the above s98tements are made /n My agrees that this potaftLw Balm to be further actions 1263af2835 The undersigned further understands and Proposed Anal estimate in accordance with Section 9.4 of the StandardresoAmPa �� x restatedbe a clam in responsr to the Clt),•s F3 C011St action moo. Cron or CONTRACTOR (Circle One) (A thorrz :;mor subconbacnor nnrr • aP ' This notice of potential claim /s acknowledged and forwarded by -RECEIVE® OCT 3 0 2007 F0A4 nIYDM pwM" City of Riverside Public Works Deportment PI? W COHTRA&TQg (Authorized RaPBseMabve) =-Citv o riverside NOPC A NOTICE OF POTENTIAL CLAIM FOR CITY USE ONLY Received by Dat TO CONTRACT BID NUMBER DATE ' This is a Notice of Potential claim for -additional compensation pursuant to Section 3-7 of tho Special Provisions. The Particular circumstances of this potential claim are described in detail as follows: T e X� 5 %`� p^-CG.L� r" C� GF ! Glx ►� riQ 4yt tl_ S'Pa�V'Plr' /r r � C.t>aS �Xsrt- C!�"'r�-� c�Ci' ` � �'ei �/ �y lSit� nc�►c�S The reasons for which I believe additional compensation and/or time may be due are: 'e o -L as ca �-�.., S'p r� r� /G� a pert -fc> f S CcZv. n ortl 1C__ ya %t e 07` Co'r at b U wet' The nature of the costs Involved and the 4 (he�u a.waim are -described as-raiows_ (If accurate cost poten ifg"res are not available, provide on estimate, or describe the types of expenses Involved.) -a'A&2 ���• n�.� snr-cam r-2, oCC) The undersigned originator (Contravior or Subcontractor as appropriate) certifies that the above statements are made in full cognfrancs ofthe Cadlomla FBI" Claims Ac4 Government Code sections 12650-12853. The undersigned further understands and agrees that this potentiat claim to be further considered unless resolved, must be restated as a claim In response of the City's Proposed final estfinats.fn accordance with Section 9a of the Standard SpecHicadons. 1 B ON GTOor CONTRACTOR• (Circle One) (Au ed Representative) For subcontractor notice of ootenrlal cl-im This notice of potentia! claim is acknowledged and forwarded by RR.1tivtu `ithR Z ` City of Riverside Public Works Department PRPAE CONTRACTOR (Authoth*d Representative) , ofRiy=ersi.de NOPC NOTICE OF POTENTIAL CLAIM F-7-77 _Fo_R -cTy USEONLY Received by Date TO t�ACTBID NUMBER DATE A_-10 V 2- ,2 00 This is a Notice of potential Claim for additional compensation Pursuarjt.to. gaction 3-7 61 -the Special -Provisions. The particular circumstances Of this pot -e-6 :5? /17- - .- e V - h7 rk i9 a 7A). .$is lnv.o nofsYa e, ib --•of tiO� ex pe . 04 S- ..)904 tp.,es ems. The. unorersign6o �Q9�?izarce.gftha Ga! F>�ptrsedf ileal esfir»ate in..accoydance with Section Fr elS,9rredJi�rih'el�iriilers�iiifla anti For subcontractor n tic of. aDtia claim 'rhft —fice orpotentfol c1alr» !s -CwwOwj&dq*d and forwarded by of ..Riverside NOV _. NOPCAl / FOR CITY USE ONLY NOTICE OF POTENTIAL CLAIM Received by S �,,,,, e„s CONTRACT BID NUMBER �vers�/e G'S22 Date DATE �Q,n 7--L- "5 6 to -7 =_ This Is a Notice of Potential Claim for additional compensation pursuant to Section 3-7 of the Special Provisions. The particular circumstances of this potential Calm are destrlbed in detail as follows: 1 t;5z ,; j a'C-- sy�ro,� Tc�.� t�a��_, �.1a2 i`Cua{• Go er- City-- o_6apicJc teW 0'e-- The reasons for which 1 believe addluonal compensation and/or time may be due are: on We ra •.1 y -,ed %. `t� e �: e !'oQ� �r�C 't eIQs tion` z box ecf- YAe ct b- The nature of the costs Involvsd end the amount of the Potential Calm ere described az follows: {If ac -rate cost figures are not available, provide an estimate, or describe the types of e*enses invoked.) The undersigned orlglnator(Contractor or SvbconfYactor as appropriate) cer"es that the above statements are made in fbl! cognhance olfhe Llellfomle False Claims Aci; Goveinment Code sections 12650-J� Tryb ve st a! agrees that this potenBa! claim to be further cons/dared unless resolved, must fated as a tial rO n further rmde�fands and propo"d final estimate in accorrhnce with Section 9- Of the Standard SpecNfeationx sponse to the city's I.0 TRACTOR or NTRACTOR {Clrcle For subcontrac*.+r not p „i , claim —P, This notice of potenflal chi” is acknowledged and forwarded by I'MMtE CONTRACTOR F0iW;routs D47D6iO4 (Authorized Repiossntative) it ON of Riverside NOTICE OF POTENTIAL CLAIM NOPC # / 0 FOR CI USE ONLY Received by Date TO �r. 0— 25,--, �..-f—CONTRACT BID NUMBER DATE 4.e v r -T1,, rs "e>I This is a Notice of Potential Claim for additional compensation pursuant to Section 3-7 of the Special Provisions. The particular circumstances of this potential claim are described in detail as follows: �XPcwaYe Gtc�vnvl vrs)N0 4T$ -T boxPS sPt.�e� a+ S la�,ori 17f2- afPaS e"C,E ). C4ni+ %-y pc SS over pCc��CJSPa� Jg' d�-e 4TrT W -e acv b/_rss Uric�Pr 1 Oct, 106-s ( / 8 v c i9 5 e,—., e -4' - The reasons for which I believe additional compensation and/or time maybe due are. /{TAT boi<es G"e- Nat- t��✓1 6h COnfrYCi ()/,�n5. ." oma sti ow r. o,-\, Co., -f rc•.c� p lee IS The nature of the costs involved and the amount of the Potential claim are described as follows: (If accurate cost figures are not available, provide an estimate, or describe the Wes of e)(Penses involved.) r IAo(d Eo.t� til „ to of z�7) The undersigned originator (Contractor or Subcorrbactor as appropriate) certifles that the above statements are made in full cognizance Of the California False Claims Act Government Code sections 12650-12653. The undersigned further understands and agrees that this potential claim to be fwtirer considered unless resolved, must Pposed be restated as a claim in response to the City's roTina! estimate in accordance with Section 9-4 of the Standard Speciflcatlons. �SUBCONTR TORrCONTRA TO• ' j' tCirde n ( o pre attve) For subcontractor notice of pote fiat claim This notice of potential claim Is knowledged a d forwarded by PRIME CONTRACTOR FORM Rumm o~4 (Authorized Representative) c� o iv=erside .i..� NOPC # FOR CI gg.OMLY NOTICE OF POTENTIAL CLAIM Received by c Date TO /' 1l Dcn S �rroK CONTRACT:7:�NUMERBDATE 2/I 29 o7 -� �� go o7 ; �,, o �EZ;,,e r-s,e2 - - This is a Notice of Potential Claim for additional compensation pursuant to Section 3-7 of the Special Provisions. The particular circumstances of this potential Balm are described in detail as follows: t) n S W 11 Corm /f TFT G.ox ® /71-21 (-UCc-ate S�pt7o✓t . 0c e -f- rcc'rosQo� Se,✓�. ,%x'h� box �✓ (' 1 i�, F�rCu-r+ -1`e> l`►�u� Pxcs�,,.q e.,<1�c CA a sed(-SC=we,/� PrrCG$ PMPN`J �� The reasons for which 1 believe additional compensation and/or tlme maybe due are: bo)( -e-> 0—re- !jc)t- /o it CG.S' Q�� N The.4aluis of the cots irntohred sndlhe.amount-af.the potential clakn aredesuibed as to{bws: pt accurate cost figures are not available. provide an estimate, o1r describe the types of expenses involved.) cxx� -�' W �p cc cs t� S �S The undersllpred—ori�rfafor(Contractor-or-Subcontr>3 late) c"fies that th s above statements ars made In W coQnJsar►ce of Nra Calilof"la Fake ClahRs Act, Co-v-10Ment Coda se iins iTB5�iT633�Ths undersi®na er Mndarstereda trrd agneas Bibi Phis Poftft i/ claim to be ►umber eonatWwvd nnlesa nisch ed must be restated as a claim M response to proposed Mai estimate in accordance withSect/on 9-4 or the Standard SpecHicaffons Gorci orez Construction Inc. Su CO CTOR or CONTRACTOR (Ciro One) - (Authoriz eprasanbtive) 10 of botentiai claim This notice orpotentW cia)m is adwowledged and forwarded by .:,nt PRIME CONTRACTOR (Authorized RopresentaDve) —0tv_n _R�v_ E..". ... ";01 NOTICE OF POTENTIAL CLAIM Received. by TO Dan otis CONTRACT BID NUMBER �verS,9e X 52 2 NOPC # 12— Dafa. DATE $ V r► - urs '�L — 3 0 -7 This Is a Notice of Potential Claim for additional comp erwation pursuant to Section 3-7 of the Special Provisions. The partkular draanatancea of this potential claim are dasutbed in detall as follows; CCq✓l><Yj,�'e `�'� �,cC�tJc�-'f2 O�!'Gwcl �,,r S%�c�✓i i -t, Ca6le"0.. RP1�ove v✓iS4a—V1/�� 2P � h ►�.�d(� /%f.2i P« en (4sa+ t o a ! y ID �re � n � � eCa�s e '-Tq T bnx S�� ,�jrKrq o•t-PGY'- uv�sh�c.�n�Seu•e+r e�ncssPrt�w7: � G 01 P 0 /7f Y2 TO /7151 C•e PCG s C.'i-t uoo-'Iems- -f7-o4T l�rt S The reasons forwhlch 1 believe Itlonal compensatlon andlor toneaH t % �o INiS m /� maybe due ate: -^p U0 3 h¢' w #/XO✓L L fan ` l' -C4— plG_N S - • /f7 -`E l Cm,rr�u�'�S 4` %rix PS The nature of the curb hrvolved and the aamount of the potandal claim aro dasuibed as follows: pfaccurate coat figures ere not available, provide an estimate. or describe the - 1 types of e"nses involved.) �GIGPr`irtjrl 1G�Jfl� ccr� P�u. !"r�N� �pS7S 77►e"nc*/of )b-1 s � odg (ContractorSubcontractor as appropd J "'W93 that the statements are statemenare made /n hdl a9rss at th/spOWW Wshn fo be ilnrhercGWdqred unless r�oh,+ V -1200-12M The underalprtsd /brdw undwftnda aril -proposed-flnat.estimate.tn_accondence.w/th-Secilon- 04 MW be restated a: a claim /n 9-!<-oftlte-StandanlSPeeMesBorrx-- • - - ---... _ _.. _ �Ponse to an CUy's SUBCO�OR oCONTRgCToR (Circle One For" (ufhor/zed Retam) f Thls notice —rpt—,df claim /s a J—Mdgod d forwardedby PR%W COMB CTOR FOAL ft=8b DU0Na4 - (Authwizad RepresentaBve) �-t - C ° - f R ° versside NOPC A _[3 NOTICE OF POTENTIAL CLAIMFU 9IT-Y .: =,�NIY ecelvt3d byyjRO p TO CONTRACT BID NUMBER �vers,cQeDATE �vPs wP� ro 5 2 2- This Is a Notice of Potential Claim for additional compensation pursuant to Section 3-7 of the Special Provisions. The particular clreraMtancbs of this poteMJal Galin are described in detall as follows:: Pres e -rt, � a-Kr�C ,Qrr� Y -•PG-►' � nS 1.C�w ,'� f � c�nocu .'f- . Ffvr1 sty 0✓r j3 I JY �o Stc`,�:orl /3 +9 re l P �G(pril /t0 e OSI /%g,1 U tlr°S The reasons forwh" 1 believe additional compenaailon and/or time may be due are: Rc-r o ti / -h f ,t.9e-t- s Ace L-41 incl ��, Plus The nature of Me coag kwolvsd and the a "—. of the potential claim are described as follows: pt accurate coat figures are not avallable, provide an estimate, or describe 'he a of • tYPe e*anses involved.) Aotd,- igAal Cost -s 49r - P/ --Sf - P/ --S rz>�-t- -to ,Yo.),1 4 -job CZ,4- z2s The underalgned oNglnamr [Contractor or Subcontractor ea appropriate) centiles that tha cognisa»ae of die C*Wbm/a false MOMS A4Goyainmant Cods asrSwts f 2050.1.2 above statements ere made M rod underalaned ftniher understands and Proposed fUrat satbnate in accordance nh Section 9-4 0 Sha» n►t+;t Ds testatodas a claim In respons& to the aV$ SpscMcstlons. Garda Juarez ConsfrucHon Inc. IJBCONTRA or( OWMCTOR (CJrzie One) • - r - For subeontrattor notlee of ootsnti t taim o ed ReprssentabW) RECEIVEDThis notice ofpotential claim !s clrnow►ed and forwarded by DEC 14 2001 tM>ECONTMcToft `°'MMerside Public Works QePartment City ofRiverside NOTICE OF POTENTIAL CLAIM Received by TO /�S. nNs-f-CONTRACT BID NUMBER R,vers,iPe rn52 2 DATE NOPC # /(, 161/10 7 j y ? T/O-' This is a Notice of Potential Claim for additional compensation pursuant to Section 3-7 of the Special Provisions. The particular circumstances of this potential claim are described in detail as follows: 6!JC:- )'!G S r e� � r�`� fL i itit t l t-� �/` tE�f -t c r -f w 'T -Y G Secy o n 306 - /. S I Co_ Ca ed ZVO! ✓ a00 The reasons for which 1 believe additional compensation and/or a may be clue are. The nature of the costs Involved and the amount of the potential claim are described as follows: (if accurate cost figures are not available, provide an estimate, or describe the types of expenses involved.) z1 TSU The undars/gned originator (Contractor or Subcontractor as appropriate) certifles that the above statements are made In fan cognizance of the Cal/fomla Hiss Claims Act, Government Codi sact/ons 12650.12653. The undersigned fvrffior understands and agn»s that th/s potsrrtlal claim to be further cons/dered unless resolved, must be restated as a claim In response to the clty's proposed flnaf estimate /a accordance with section .9-4 of the Standard Spaclflcations. Garcia Juarez Cnnshucfion Ina, SUSCO CTOR or CONTRACTOR (Circle One)For subcon — {Authorized Representative) r 1 f Hilal claim RE E!, This notice ofpofentW tial is ackno edged and forwarded by DEC 2 1 2007 PRIME CONTRACTOR F&*efoRiirerside Public Works Department (Authorized Reprosenfativo) City Q[Riversi . e l� Non#_ f* SI3:O1NE?ff NOTICE OF POTENTIAL CLAIM f teWved: by Q8 TO CONTRACT BID NUMBER DATE 14,14 6-522— IT)ec 2 0 2-a27 This Is a Notice of potential Claim for additional compensation pursuant to Section 3-7 of the Special provisions. The particular dreumstatnces of this potential claim are -described in detail as follows: L n C cn� n %Gr e.4 9 n r -i �1 �S h vc,.�''r �v n K �+•'xf' 7* 3a- tiu-17 oY t1,v n Gh P/KrI � S'3v Oh CUlNmO�Lt The reasons for which 1 believe additional compensation and/or t1ma may be due are: �Vvt Jaw or'ec,f on Ae%tiy.pleYJc The nature of the.costs Involved and the amount of the potential claim are described as follows: (it accurate costNures ere not available, provide an estimate, or describe the types of expenses involved.) , uP. �Cn own ut 5vc,1_4e w�-� h S�{ cool Cv•,.�%e fiOrl 04 The undersigned.odginator (Connector of Subcontractor;as appropriate) certMes that the above ststements are nNde In AN copnhanca of Nn Ct+l)Iomla Esfse Ca)ms.4cy Got�sr»ment CodsaecVona 12630.12633. Ths uirdesTpned IFirfher ynilaatsnds.end agrevs that this;potentl* cWm to be further -considered unless rvsolved, must be restated as a claim fn rsapor►ss to the City s Proposed final estimate In accordance wHh:Swoon 9-4 of the Stannard Speclflcadonx Garcia .lira- rsa C4rS SUBCONTRACTOR of COWRACTOR (Circle One) (Authortzed pnrsenta W) rl) + subcoalsM �I claim Uce ofpotentW calm Is acknow)edged and forwarded by PRtMECOWMCTOR ,Gi ,$Wprside (Aurhwized Repasentativo) Public Works Department 2008 01--11 18:48 FAX 95165739' GARCIA HARES CO. RIVERSIDE lih00t i o Rives Mon a NOTICE OF -P(JT NTIAL CLAM Rte.. TO mnS CONTRACT BID NUMBER DATE (Jan S. •M r� This is a Notice Of PO%ntiai aaim for additional compensation pursuant to Section 3-1 of the Special Provielons• The pwftlet otreumstat►o6a of h potennat Geon Bre described in stall as Ilaxe: +sot •lo P I Gr � '`%P�- G �� �s -tom f'C'ca n PfryS�'rs %gP"ecakS I`v pio�oSAaQ .^+ash. 7 t Ce„,�r?[ +O✓► r/ f;�, r►. be/t a„dc Y PIP eThe Jo���s ham nai Cry Yca 7`�i G. The reason for wnl:kI belbve addRlonal comperlaadon andtof tkne may due aro: �Xclu�.�'ve/ �:•ti,LG, has The nature cf the oasts ktvoived And the aiTivurd of the potential clawn are oescmerr as fullu '• (1f acturete Cw tlpvres aro not o"Hable, provide on estimate, or debetibo the tppeeof exponsesinvoived.) G2A ,,v 17, o.tr'�Src�.r-► . . The vndem/Drred oit9b►ator (�out4aator w Speconbmctor as atrier she abovs.s A *jjr wN PAroW►ete) corNRoa M full cayrtlzartGe Of M• Gillbrr►frF+lse CAllma,+4et; Gov,Mnma»t Codd srWer►s fTQ3.0-i,26s�. 'fid v»derafP!etl h►ctf+rl' hd!a Rnd ,ynp th•f gris potifilW tJrdtn m be fu�f�r cara►dared unksa ttldarved, mtlaf tiq restated as a claim in e'lofha CItYa proposed tdroi Rsarr►rfe iR .eewd+ne..w1M seeaon a� 01 a» see+,da►a spee+fJtsfiona. - Gamgta Juarez Consfrod6n no. SUBCONTRACTOR or CONTRACTOR (Cimse one) (AuthWmd RBprdsentadve) For wls2ntmw notlotof potantit. and Iorwanfed by This notice or terrtlat rJslm fd.ckilow/od4ed PFumr: CONTmOTOR (Authorized R.pesentefr�e) NOPC 7 NOTICE OF POTENTIAL CLAIM Recelvbd: TO o,,, _> w. nns CONTRACT BID NUMBER D"ATE C; ,vers.bPe - _ro52 2- l- 3U -OE This Is a Notice of Potential Claim for additional compensation pursuant to Section 3-7 of the Special Provisions The particular dreumatances of this potential claim are described In detail as ooms: f- -� ere, // h � r`o J C. !n S Z°C �jr" S` � o �<_'i— �r�Se e �{�, ,� rev�d A-)0 �r/E The reasons for which 1 behave additional compensation and/or time may be due are: i V r 5 r S /UD Gt �O/1 % rG �. 7�c�G� The nature of the costs Invorved and the amount of the potential claim are described as follows. Of accurate cost'tiyures are not avallable,--provide an estimate, or describe the types of expenses Involved.) Cr'7y�U/► P� / r'� )`- o� � G r� �G-Y— r' S D/l / I Ths unders/pnsil.outy/natw (Contractor w:Su4contractoras approprhrte) ,cerdd}lea ffief, the .abovestet"nts are made in full coytUtance of thb:Cal/lbnt/a Fs/se'Ctalma, AcR t3o»Inment Code stctlana 1?sSa12tf33. Fh*,unoteralpn d hn*vr un0"tands and +yr+es dist thispotinW/Wlm,to Ds Arrtlierconsidered rmteaa rrao/vso; must De.restatedas s ctalm:)n:,msprvnsvYo d» tWk 3, Proposed it»at esdmsh by *=wdance with Section of the Standard Spech7caVonx ®orcla Juarez 4Donsiruc%bn IBS. - SUBCONTRACTOR or CONTRACTOR r (Circle Oise) (Authortr4d Representative) For subcormacoor nonce of oo sr ^���.- i ! 1uE)WIlDdaQ slioM oilgnd Trite notice orpotential Balm acknowledged and forwaMed by apiSJaAi810 40 PRIME CC" MCTOR _ Fom Rene mvam4 AI303d (Authorized Representative) r Emmmom ®EES ®gym ME •®mww®wwmm ®®� • w .ww . ��� w - ewow���w�www ®®®waw m� www�wwww®OEM wrwiwwww,�w �� . ■wwewwww®wwwwwwwwww �� ■ •- w •• ■®www9 mmm wwww w�'!wi'awwwwwww �3 a • • wrcawow • • on ONE ►�� . L�Owww�w�wdwwwww �Bw�wwewowwsiwwwwwww LA Page of CITY OF RUVERSI' ` � - Date � DAILY CONSTRUCTIO --' ~^~" T c/` Project SEWER Location-'--CAPACITY—IMPROVEMENTS La Codeno , Sprinq Gorden St.,/xColumbia Ave. ''- lmmr�o 'AM '" FYW� �Sunny, Cloudy Rain Sub- till still Moderate High Moderate Inspector And Beck Humid IT NO. EM _:The contractor Potholed on Columbia-~. ~".`"/mtoday. lContractor is clairnin g extra work for' !;.Columbia -_..,~ that �*/nvwno�e —PlansTq�-r� !S-�� Pedestal behind the curb at that locatiop. There is an 18"_water line at Sta. 12+41 that is not shown on the nto a __p!ans that goes i vault _ _location. .���area�o walk at. !he_ra work fo��c�ftliqq a 4" ,__-. gas line at Sta. 15+22 that is sho on Ithe but was T�Iss r��- rked by USA. The line was r city should pa r __��T��rked at E�ta 15t27 and the contractor claims Yfr_!�x�tapotholing Of miss marked utilities. - -_. _---- -_ r- _ �-------------_�__'__ OURS : FOREMANI/OPERATR 1— 8- 8 :JESUS LOPEZ JOPERATOR iLABORER 8 JOSE CRUZ daily report-l.xls CLASSIFICATION FOREMANI/OPERATR 1— 8- JOPERATOR iLABORER ' ` C (L5 Signature ^«^s�`�� \ �cp q �,/ v^"h EQUIP # •�� �:arne out to the job and informed the foreman. Ruben MPnan,„ fes.., Gviucnce of a connection off of a main line will not be paid for as T&M under potholir things such as vaults and pedastals. 310D JD BACKHOE---------------- _ 544 JD LOADER CHEVY 2500 PICKUP CHEVY 2500 PICKUP CHEVY 2500 CREWTRUCK 10 WHEEL DI MPTRUCK 1250OR HYDROHAMMER 131 OSE JD BACKHOE Y utilitY the that shows_ This would mean HOURS ; PERS^ ONNELHFOREMAN/OPE :ASSIFICATION"" _ HOURS " 8 :RUBEN MENDOZA RATR' 8 ;DAVID FLORES LABORER 8 ✓ 8 :JAIME ASSENCIO LABORER 8 ;JESUS LOPEZ8 LABORER 8 :ADOLFO PACHECO OPERATOR 8 8 -SAMUEL PACHECO iLABORER 8 8:JOSE CRUZ l LABORER $ 8 I � 8 D Signature daily report-lxls Page.�--. _ of—j_ CITY OF RIVERSIDE DAILY CONSTRUCTION REPORT Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Location I n rnr-i— r,.. - . Date Z C Day: M T D� F S The contractor spent 2.5 hours potholing a fiber optic telephone line that is not shown on the plans. Itis : at sta. -10+25 on Palmarita Rd. and is 7 5' deep. Ruben told me that the other 2 phone lines at that inter- _ rsection appear to be in conflict with the sewer installation. I told him to get the elevations to me or Dan Simmons as soon as possible so we can et it r -_.._ 9 esolved. EQUIP# I :a 310D JD BACKHOE 544 JD LOADER CHEVY 2500 PICKUP CHEW 2500 PICKUP CHEVY 2500 CREWTRI CK 10 WHEEL DUMPTRUCK j2500R HYDROHAMMER 1310SE JD BACKHOE i 1 PERSONNEL 8 :RUBEN MENDOZA rHOURS 8 ;DAVID FLORES 8 :JAIME ASSENCIO $ :JESUS LOPEZ 'ADOLFO PACHECO 8 -SAMUEL PACHECO l 8 :JOSE CRUZ r— 8 daily report -1 xts CLASSIFICATION 1-1OURS FOREMAN/OPERATR g �/ LABORER 8 LABORER 8 ORER $ OPERATOR 8 LABORER I 8 LABORER I 8 Signature PI b=it IE Ili -I. F -1— I City of Riverside Date 101210-7 Daily Construction Report Day: M X T F S Project Sewer Pipeline Capncity Lind R:i1myr_ita Avenue Improvements - Bid No. 6522 Location East La Cadena Drive, Spring „arden Street, Columbia Avenue, and Polmyri-a Avenue. _ Contractor Garcia Juarez Con,-truction, Inc, Subcontractor Inspector ANDY BECK EQUIPMENT AND PERSONNEL EQUIP# ! DESCRIPTION HOURS PERSONNEL CLgSSIFIC i I CJD-51� Bc.cicl,a� ��'��. • ----- �{b 1c) A 1Pr_d'eC'C> I d v C wt F—H Cr rl Z _I k C-6 Tin=i ` �---- '- --� a J a'_' L -M!7 r . Y I - --1 ----- 1 Sf,rti / P4 g - + - - ----- --�-- HOURS {I � I 8- EQUIP # 1310 JD BACKHOE 1544 JD LOADER CHEW 2500 PICKUP ----- ---CH€VY-2500-PICKUFF CHEW 2500 CREWTRUCK 10 WHEEL DUMPTRUCK 250OR I-IVI`)P JARAur� HOURS PERSONNEL CLASSIFICATION I HOURS 4 :RUBEN MENDOZA FOREMAN/0PERATR j g 4 ;DAVID FLORESLABORER ---r�----4-- 4 - :JAIME ASSENCIO LABORER $ �/ — -JESUS LOPEZ LABORER -- $ 4 4 4 ; i I I ' Signature daily report-1.xls Wage 1 of I PI IF11 IE 111-1. : i i,- t . ii- -t=u i ; iii : ii ; PPl F•-; City of Riverside Daily Construction Report Date O/� 67 Day; M WTFS Project Sewer Pipeline Capr!i.,ty cnid Po�myr,ta Avenue Improvements - Bid No 6522 Location -East La Cadens Gr,tipring Carden Street -- - - — - - -- Columbia Avenue, and Pcimyritu Avenue - Contractor Garcia Juarez construction. Ir -c_ Subcontractor Inspector ANDY BECK EQUIPMENT AND PERSONNEL EQUIP # `.EQUIPMENT HOURS PERSONNEL I CLASSIFIC ,. c Va t� - - Pte-. l-eY- I HOURS tai Page of CITY OF RIVERSIDE Date / 0 -- /'— o -2 DAILY CONSTRUCTION REPORT Day -. W T F S Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Location La Cadeno Dr., Spring Garden St-, Columbia Ave. Alvei rn Ave. IPWrraffic.:j Contractor -andPalmorita I W Sunny Garcia Juarez Construction Cloudy Rain Sub. Still Moderate _High Inspector Dry gry Andy Beck Moderate Humid r :T emp t ITEM NO: i Contractor started the project today. They started potholing on La Cade d Sprippj��q�a potholed a set of telephone ducts that appears tob in en The e possible conflict with the 24" sewer line to be iinstalled. EQUIP #.... 1%,rlr-VT CHEVY 2500 CREWTRUCK 00 WHEEL DUMPTRUCK :250OR HYDROHAMMER M HOURS PERSONNEL 4 'RUBEN MENDOZ 4 :DAVID FLORES 4 :JAIME ASSENCIO 4 4 4 daily report-1.xis CLASSIFICATION LABORER —8 LABORER 8 LABORER I a Signature 11 ii 11 IE I 4-j. PI I City of River -side Date / 0/' /0-7 Daily Construction Report Day &T W T F S Pf oject Sewer Pipeline Copc,(:;iy End klmyrita Avenue Improvements - Bid No. 022 Location Fast La Cadens Drive_, Spring (•ordcr) Stref-J, Columbia Avenue and P olrnyril.3 Avenue. Contractor Gorcia Juarez Construction, Inc. Subcontractor Inspector ANDY BECK EQUIPMENT AND PERSONNEL EQUIP 0 DESCRIPTIot,i t HOURS PERSONNEL I CLASSIFICATION I HOURS '72& v r - L0 ArwLj I ----------- M J 0 Y d i 0 0 r J d Q O Page of FAV Np. : City of Riverside Daily Constriction Report Project Sewer Pipeline Capacity and Palrnyrito Avenue Imp Location East La Cadem Drive. 5 ri Gorden Street, Golurnbia Avenue, and Palmyrita Avenue. Contractor Garcia Juarer Construction, Inc, Subcontractor Inspector ANDY BECK Oct- 31 _i=n�7 11:.1HM Pq Bid No. 6522 Date /0//-S/07 DaY:MT W TTFS Page I of_L CITY OF RIVERSIDE Date C - i�WS DAILY CONSTRUCTION REPORT Day. M TPro'ect 1 #652 2 SEWER PIPELINE CAPACITY IMPROVEMENTS Location La Cadem r), G. r EQUIP# 31 OD JD BACKHOE '544 JD LOADER -i I_ �ICHEVY 2500 PICKUP I i P.r►tyY 2500 PICKUP CHEVY2500 CREWTRt1(-IC 10 WHEEL DUMPTRUCK 250OR HYDROHAMMER 310SE JD BACKHOE )URS PERSONNEL I .:........:......:...:::?:::= CLASSIFICATION_ $ 'RUBEN MENDOZA FOREMAN/OPERATR 8 ;DAVID FLOF2ES ILABORER 8 'JAIME ASSENCIO .l A]ar,% m .JESUS LOPEZ :ADOLFO PACHECO _;SAMUEL PACHECO :JOSE CRUZ_ 'GO_NZALO TAP A_ :JOSE RAMIREZ daily report-1.x►s !LABORER -!OPERATOR I LABORER ---1 -�BRER— !OPERATOR HOURS_ 8 4 8 5 4 4 8—,- 8 LABORER i 8 i Signature Page i of 1 CITY OF RIVERSIDE Date DAILY CONSTRUCTION REPORT Day M T WUF S EQUIP # -- + I310D JD BACKHOE HOURS PERSONNEL _. _. : ......... I CLASSIFICATION TION .. . HOURS -- 544 JD LOADER 8 MENDOZA tFOREMAN/OPERATR 8 _ CHEVY 2500 PICKUP8 8 ;DAVID FLORES (LABORER - !CHEVY 2500 PICKUP8 8 :JAIME ASSENCIO LABORER CHEVY 2500 CREWTRUCK 8 ;JESUS LOPEZ ;LABORER 8 8 'ADOLFO PACHECO !OPERATOR I 10 WHEEL DUMPTRUCK —_ .2500R HYDROHAMMER- — 8 SAMUEL PACHECO 'LABORER 0 0 ___ 1310SE JD BACKHOE — i 8 I JOSE CRUZ LABORER j p — _ 8 :GONZALO TAPIA? OPERATOR 8 Signature daily report -1.x15 Page __L—of _L_ CITY OF RIVERSIDE Date DAILY CONSTRUCTION REPORT Day: M T ,yV T F S Project #6522 SEWER PIPELINE— —CAPACITY IMPROVEMENTS Locatinn I . r-.4-__ n_ _ _.. The contractor is claiming extra work for yesterday for potholing several utilities not shown on the plans. _ - An 8" water line at sta. 23+26 that runs to an 8"above ground double detector check behind the sidewalk_. i Eight inch water lines at stations 34+25 and 36+72 that run to above ground double detector checks and fire department conections behind the sidewalk.Also telephoneand d electric conduits between stations j 37+14 and 37+17 thar run from a power pole to a pedestal across the street and (The onlylace ththat they are claiming extra work that there is s no visual evidence of a ut the sidewalk. - — (would be the electric crossing at station 31+4 a utility crossing — _ I informed Jim Jackson that they need to make sure they have retroreflective traffic control for niht.w r per section 7-2.2.1 of the WATCH Manual. irk U: € .>`Q .IP EQUIP# I :A?IEIE1 Ai9l?'F?ERf?I!iIEL::€:::_ _i-- HOURS t PERSONNEL CLASSIFICATION 310D JD BACKHOE I 8 :RUBEN MENDOZA FOREMAN/OPHOURS 544 JD LOADER. _ ERATR 8 - 8 :DAVID FLORES CHEVY 2500 PICKUP LABORER i 8 8 -JAIME ASSENCIO (LABORER CHEVY 2500 PICKUP I 8 JESUS LOPEZ ---------------- I 8 CHEVY 2500 CREWTRUCK LABORER 8 8 -ADOLFO PACHECO •OPERATOR I10 WHEEL DUMPTRUCK I 8 8 ;SAMUEL PACHECO (LABORER 1;2500R HYDROHAMMERi 8 _ 8 :JOSE CRUZ (LABORER !31 SE JD BACKHOE I . - - 8-i -- 8 -- daily report-1.XIS Signature i x-rKA t Amaae / XTQA OMP_ Page / of 1 CITY OF RIVERSIDE Date 0'- %"- DAILY CONSTRUCTION REPORT Day: M W 'TF S T Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Location Lo Cadena br-, Spring Garden St-, Columbia Ave. — -- _ _ ondPalmarita Ave. _------- --------_-------- �Ah4 Traffic PAi1.Tfac'- Contractor i Garca Juarez Construction ---- u Cloudy Rain _ . Sub. 'Wind: Still j Moderate High Inspector Andy Beck �N�tnlldt ' ' Moderate i Humid ! --- CONfoou Gi�eITEM rn WQRK.PERFOk. The contractor potholed on Columbia and Palmanta-today_ _ .._----------- --- I informed Ruben Mendoza - tRA e ... 'jt Ei 0lvliVl [aiTS�'f -........ that they need to make sure they have reflective traffic control' fo-�-- rn-- r ght work. PMENT RN:PERSS-,E?I�1EL=::.:.:.:.:.:....:....... r - --- _ 310D JD BACKHOE HOURS PERSONNEL ..... . :::::.::::::::::::::::::.:::: :=::::::: - CLASSIFICATION HOURS ?544 JD LOADER 8 ;RUBEN MENDOZAFOREMAN/OPERATR g C -8 - ,DAVID FL ORES - (LABORER -.- . i--HEVY 2500 PICKUP 1 - - - --_-_. ICHE_V_ Y 2500 PICKUP 8 :JAIME ASSENCIOLABORER 1 8 8 - --___ !CHEVY 2500 CREWTRUCK r — 8 -JESUS LOPEZ !LABORER I 8 10 WHEEL DUMPTRUCK 8 'ADOLFO PACHECO OPERATOR I 8 250OR HYDROHAMMER a ;SAMUEL PACHECO - LABORER i 8 — 31 OSE JD BACKHOE I 8 :JOSE CRUZ � - LABORER 8 -- i 8 --�_ daily report-1.xis �� Signature AA 15 S ►Jfo L/kBoR>vQ �! aj r F F'1-11 I : Page_01 FH: r lo. : City of Riverside Daily Construction Report Project Sewcr Pipeline Capacity and Palinyrito Avenue Improvements Bid No 6522 Location East Lo Cadens brie, Spring Garden Street Columbia Avenue, and Palmyrita Avenue Contractor Garcia Juarez Construction, Inc. Subcontractor Inspedor ANDY BECK EQUIPMENT AND PERSONNEL -NM FP Date o 9 6 7 Day: M T WT F S FPut I : Fk; P1O. Oct. 1 cti O ( 11 : -fAf1 P7 Page—of City of Riverside Date icyz/k/ a Dally Construction Report Day: M T WT F S Project Sewer Pipeline Capoclty and Polmyrita Avenue Improvements Bid No 6522 Location East La Cadena Drive gpring Garden Street Columbia Avenue, and Palmyrita Avenue. Contractor Garcia Juarez Construction, Inc. Subcontractor Inspector ANDY BECK FOIIIbY tur �■... ��_�.�_.__-_ FF'GI I : FH: 1111 Page_of City of Riverside Daily Construction Report OC t. �i t3N7 11: �2AM F5 Project Sewer Pipeline Capacity and Palmyrite Avenue Improvements • Bid No. 6522 Location East La Cadens Drive, Spring Garden Street, Columbia Avenue, and Palmyrita Avenue. Contractor Garcia Juarez Construction, Inc. Subcontractor Inspector ANDY BECK Date /0 / 71, 7 Day: MTWT FS EQUIP DESCRIPTION EQUIPMENT HOURS AND PER30MMEL PERSONNEL CLASSIFICATION HOURS S!e"C-►o ab S Fla i -e 5 _ jU-L'� R�cfcle S o " g �a�e�evy 4r�� Cru- owlL ► .��- �� a �$rsbw tai 2 o I sem,' �cJ Q lvl7� _ 5;6r -A q/2 r 6i9rraturo Page—/ of ". CITY OF R `'roject Location Contractor IVERSIDE DAILY CONSTRUCTION REPORT #6522 SEWER PIPELINE CAPACITY IMPROVEMENT /6 Date i C-- Day:M(ij T F S La Cadena Dr, Spring Garden St-, Columbia Ave.and i AM Traffic - - - 9 ..------ PA�t Trac Palmarita Ave. - _-------. _.... i Weather Sunny Cloudy � Rain - -- -- Garcia Juarez Construction -- ------ --------_-- i Wind: Still I Moderate Subcontractor Inspector Andy Beck eONTROLLING 17EMI No. 9 HUrrt�dlfy Dry I Moderate j Humid AM Temp ``PM dein WORK PERFORMEp -----••-..>:.:-::-:-::: N`J`a_E::;[:::E'::;=::'-::3a:_E:[isa(.:;:>:::::E told Ruben Mendoza that all areas that are pulverized must be cut down and have 2" of cold. mixplaced in them as per Jim Jacksons conversation with Dan Simmons on 10-12-2007. [also told him that they could not do an work within the CALTRANS rioht of way�eoause_they-had-not-seLup-a-meeting-with-GAL-TRANS—The-contractors-permit-with-e-AC---- TRANS states that they must have a meeting 2 weeks prior to any construction within the CALTRANS right of way. Dan _ also informed Jim Jackson that they could not grind on Palmarita. By the schedule that they submitted, they should not Pulverize Palmarita Ave. until 1 6-26-2007. Jim Jackson called me at 1:20 p.m. and informed me that unless they have written directive not to grind Palmyrita Ave. he plans on doing it tonight. I told him that Dan gave him that directive email yesterday. ojynaiure FF'01.1 Fit— t1A. Ilr Page_oi City of Riverside Date io/a o Daily Construction Report Day: M T WT F S Project Sewer Pipeline Capacity and Palmyrita Avenue Improvements - Bid No 6522 Location East Lo Cadena Drive Spring Garden Street Calu►nbia Avenue, and Palmyrita Avenue. Contractor Garcia Juarez Construction, Inc. Subcontractor Inspector ANDY BECK I EQUIPMENT AND PERSONNEL DESCRIPTION HOURS PERSONNEL CLA3SIF1 16 -T Crn ab Val 2- ,tah oca LG.b � Lti�a , 9 V -P w m -..i ;4t— I Page J —of J CITY OF RIVERSIDt Date PERSONNEL DAILY CONSTRUCTION REPORT Day. —TF S Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS :RUBEN MENDOZA Location La Cadena Dr., Spring Garden St., Columbia Ave. AM Tia(fic ' Pa Trak j 0 andPolmorita Ave. _I 'LABORER Contractor IiVeather Garcia Juarez Construction S y Cloudy Rain -- — "— Sub. ItNtnd til I Moderate High - - -- - 9 Inspector ,Hirmldi— Andy Beck Dry Moderate ' Humid —! IAM Te i CONTROLLING E 1- PM Temp I -- -• - -_ ITEM No: i WORK PERFORM;✓ N . :ADOLFO PACHECO 'OPERATOR j :The contractor did not have any personnel or equipment working on site today. I tried calling P,uben 'Mendoza 110 WHEEL DUMP-TRUCK but he did not return my calls_ I took several pictures of existing I _Land _ conditions La Cadena. I on Columbia Ave. - ---- -- �2500R HYDROHAMMER 0 :J CRUZ EQUIP # 1310D JD BACKHOE HOURS PERSONNEL CLpASSIFICATIONI HOURS 1 0 :RUBEN MENDOZA FOREMAN/OPERATR I 0 54 4 JD LOADER _. _ j 0 ,DAVID FL -ORES... _I 'LABORER _ -. 'CHEVY PICKUP 0 :JAIME ASSENCIO ;LABORER p 2500 CHEVY 2500 PICKUPI �CHEVY2500 CREWTRUCK 0 ;JESUS LOPEZ I ,LABORER ' 0 0 0 :ADOLFO PACHECO 'OPERATOR j 0 110 WHEEL DUMP-TRUCK 0 _.SAMUEL PACHECO--_i .+LABORER �2500R HYDROHAMMER 0 :J CRUZ LABORER _. t) 1310SE JD BACKHOE 0 ,-OSE ;GONZALO TAPIA (OPERATOR I 0p :JOSE RAMIREZ (LABORER p --- Signature daily report-1.xls r r Al . FOX" t10. : Oct. �;1 2007 11 : -J1AM P4 Page of City of Riverside Date /d i5//o 7 Daily Construction Report Day: M T WT F S Project Sewer Pipeline Capacity and Palmyrita Avenue Improvements - Bid No. 6522 Location l=ast La Cadem Drive,.5Erinq Garden Street Columbia Avenue, and Palmyrita Avenue. Contractor Garcia Juarez Construction, Inc. Subcontractor Inspector ANDY 118CK EQUIPMENT nun omnenuu.. r u 0 Vp� �\ �' 1 FTl �'• ... J FNOfY . o 9 W F 9 ti v `-J - kv - a ° <a 0 o Cn 0 -- _9 - �' - 1p. S Jo �. �{ tl Jo K 6 ,lO ao -_° _ Oo ° ° ° ° • o �- y SO CL n o • ° 4 = V o h J .0 . 5 C� IST- A. %4 I 1. �t j W < S u v 'F Y ,rt O � 0 _• J' y�lwrt S CCC]]1--jjj r 0 r e'o Tom. J T F•'� n VE o o W � w 0 ~ z' < o- a O M O Z np 1�y.7' �U +iii wo•oM r as Z tIL H 071 k %4 I 1. Page / of -L - CITY OF RIVERSIL_ Date /D DAILY C®RpSTF2UCT1OPl REPORT z 6 Day: M W T Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Location La Cadena Dr,, Spring Garden St., Columbia Ave. and Polmarita Ave. AM Traffic light PM Traffic light Contractor Garcia Juarez Construction Weather Sunny Sub. Wind Still ! Inspector Anthony B- Allen (On duty 7h45 to 16h10) - Humidity Dry CONTROLLING I AM Temp !TEM NO. 50!PM Temp WORK PERFORMED 75 LI # 2 The Contractor tried to begin work at 8h00 and was request to wait until 8h30. The LI # 10 The Contractor placed 8 lengths of 24" VCP from station 11+47 Y waited requested. and jack shoring. There was a length of approximately sto 12+03 with the aid of minimum plate .abandoned water line that had being backfilled witha loose y 3' wide by 6' deep slide from above an small a 'required to be removed and correctly compacted during the trench 9ompaction operation. The Contractor fegate material. This area_ will be is. currently not backfilling and compacting the trench according to contract specification ' are not completing the compaction operation by the end of each working dayen s m that they LI # 20 !The Contractor cast the floor of MH #3. The forms were not co Y part was roughly hand troweld. No ticket was received and completed when concrete arrived and therefore Possible over mixing may have occurred. Despite being for warned to be out of the roadway by 15h30, the Contractor only completed Placing plating and temporary AC wedging over the manhole and clearing equipment out of the roadway bsteel u # 2 The Contractor closed E La Cadens Ave. FFIC CON heavy COMMENTS: Y y 16h 10. - equipment in contradiction of the Traffic Con. Plan. EQUIP # EQUIPMENT AND PERSONNEL HOURS PERSONNEL 310D JD BACKHOE CLASSIFICATION HOURS 54 - -- 4 JD LOADER 8 RUBEN MENDOZA :FOREMAN/OPERATOP, - - _ -7 DAVID FLORES CHEVY 2500 PICKUP 1 O ...LAB __.. --- --- - BER JAIME ASSENCIO--8 ' LABORER . __ :_ HEVY 2500 PICKUP - _ . _ - .. _ JESUS LOPEZ CHEVY 2500 CREWTRUCK ;LABORER-._-..- _---- - - 1 _ ._. WHEEL DU - --__-----r-----g- ADOLFO PACHECO !OPERATOR MP TRUCK - -- 4 SAMUEL PACHECO- LABORER — _.-_ 2500R HYDRO HAMMER ! g 2 JOSE CRUZ 310SE JD BACKHOE : LABORER ___-. --- _ 0 C-ONZALO TApIA :OPERATOR 8 -JOSE RAMIREZ :LABORER - - '-N_LrE • - - Contract V T/Oq/ Da Days Used Weather I Extra Work Remaining ' _Today — - ;—_Days _1 Via_ Da s TotalAna -------------- + ----' daiIYreport-1.xls Signature F Fir. I Ip. Uct• 29 --'397 1-2:212PM P - Page f of! City of Riverside Daily Construction Report Project -Se wcr Pipeline Capacity and Palmyrita Avenue Improvements - Bid No 6522 Location East La Coder* t>rive, Spring Garden Street Columbia Avenue, and Polmyrito Avenue. Contractor Garcia Juarez Construction, Inc. Subcontractor Inspector ANDY BECK EQUIPMENT AND PPaaoNwgi_ Date 101,25" o 7 Day: M Tvdf S Page 'Z of L City of Riverside Dale / O -a Y - "--)ject Daily Construction Report Day: M T(/9� F S #6522 SEWER PIPELINE CAPACITY IMPROVEMENT ,cation La Cadena Dr., Spring Garden St., Columbia Ave" and Polmyrita Ave. Contractor Garcia Juarez Construction Subcontractor Inspector Andy Beck - EQUIP # - _. DESCRIPTION EQUIPMENT AND PERSONNEL 310D JD BACKHOE HOURS PERSONNEL CLASSIFICATION I HOURS '544 LOADER 4 :RUBEN MEP DOZA f -- - -- - !FOREMAN/OPERATR I g .)D _ CHEVY 2500 PICKUP - 8 :DAVID FLORES I :LABORER _ 8 -- CHEVY 2500 PICKUP- 8 :M_ EAS_SENCIO _ JAI ,LABORER i 8 _ 8 :JESU_LOPEZS LO - -- --- --- -. . _ I � LABORER - I - - CHEVY 2500 FLATBED 110 WHEEL DUMPTRUCK - -- - - --- ----- ---- 8 :ALFONSO PACHECO (OPERATOR - - - - - 8 _ r— 8 ! _ 8_ :SAMUEL L PA_C_H__E_ CO ---- !LABORER - ;2500R HYDROHAMMAR --- 0 JOSE CRUZ .. T------ -- ----1---8--- __ '926 CAT LOADER - .- . - -- ----- - 8 : GONZALO TAPIA --L- -----.--_ 'LABORER - _ (OPERATOR - - __4_A_ ;235 CAT EXCAVATOR -- ---f------ 8 JOSE. RAMIREZ -- 8 __ .-- I . _._ 10 WHEEL DUMPTRUCK - ---- I 8.OPE - - RAMON BRISINO -, - LABORER _ _ i RATOR i 8 - -J i _ i --F --- - ONERIO RAMIREZLABO- -------:- r------ RER - -- 8 - 8 — , I _ -------PEDRO RAMIREZ I I ---- 'LABORER------------ - Signature P�iye Z of L- -- City of Riverside Date % 0' 2 .3- -i Daily Construction Report Day: NtqVTFS E"oject #6522 SEWER PIPELINE CAPACITY IMPROVEMENT _cation La Cadena Dr., Spring Garden St., cotumbia Ave. and Polmyrito Ave, ContractorGarcia Juarez Construction Subcontractor Inspector Andy Beck - EQUIP #EQUIPMENT AND PERSONNEL DESCRIPTION i . 310D JD BACKHOE 544 JD LOADER CHEVY 2500 PICKUP CHEVY 2500 PICKUP CHEVY 2500 FLATBED 10 WHEEL DUMPTRUCK '2500R HYDROHAMMAR .926 CAT LOADER .235 CAT EXCAVATOR :10 WHEEL DUMPTRUCK X310 JD BACKHOE HOURS j PERSONNEL CLASSIFICATION HOURS 8 :RUBEN MENDOZA FOREMAN/OPERATRI g 8 :DAVID FLORES (LABORER 1 I_ 8 :JAIME ASSENCIO _. ILABORER I 8 8 _ . 'JESUS LOPEZ -- —I LABORER-- 8 — - I8 :ALFONSO PACHECO OPERATOR 8 ;SAMUEL PACHECO jLABORER 0 JOSE CRUZ - (LABORER 8 8 GONZALO TAPIA (OPERATOR _8'JOSE - RAMIREZ -- -- _. LABORER 8 :RAMON BRISINO ---- - - -.. _ I OPERATOR.. 1_8, 8 ;RUSTY ALCOSER LABORER - — 'ONERIO RAMIREZ ILABORER I 8 PEDRO RAMIREZ LABORER 8 I 8 Signature Page —Of Z City of RiversideDate / 0 `Z -Z Daily Construction Report Day: W _TF S Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENT .ration La Cadena Dr., Spring Garden St., Columbia Ave. and Polmyrita Ave. Contractor Garcia Juarez Construction Subcontractor Inspector Andy Beck EQUIP # DESCRIPTION EQUIPMENT AND PERSONNEL '310D JD BACKHOE HOURS jI 8 PERSONNEL :RUBEN MENDOZA CLASSIFICATION FOREMAN/OPERATR HOURS X544 JD LOADER g _-_ 8 'DAVID FLORES !LABORER — CHEVY 2500 PICKUP I 8 :JAIME ASSENCIO I LABORER 8 - CHEVY 2500 PICKUP I 8 JESUS LOPEZ r LABORER g ' ,CHEVY 2500 FLATBED I10 � i 8 :ALFONSO PACHECO !OPERATOR 1 _ WHEEL DUMPTRUCK 12500R 8 :SAMUEL PA CHECO I (LABORER 8 — HYDROHAMMAR 0 :JOSE CRUZ !LABORER 926 CAT LOADER g _ 8 :GONZALO TAPIA 1OPERATOR — .235 CAT 8 I :JOSE-RAMIREZ I LABORER_ _ . 110 WHEEL DUMPTRUCK 8 :RAMON BRISINO i OPERATOR 8 i j 8 j :JORGE VALDEZ 'OPERATOR — :PEDRO RA M_IREZ 8 .. 'LABORER — -----• _.----:ONERIO RAMIREZ _ I LABORER 8 — -- - - - -- -- -- -- -- :RUSTY ALCOSER_--ILABORER I -- --- , i --- . — — i Signature bc Page _Lof CITY OF RIVERSIDE Date � 9 p DAILY CONSTRUCTION REPORT Day. T W F S Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Location Ln Cadenn Dr., Spring Gorden St., Columbin Ave. ' AM Traffic Light PM Traffic :light and Pnlmorito Ave. Weather Cloudy Contractor Garcia Juarez Construction Wind i Still Sub. Humidity. Moderate Inspector Anthony B. Allen (On duty 7h.-30 to 15h30) AM Tem ---- P 481PMTemp 72 CONTROLLING' ITEM No. WORK PERFORMED LI # 2 The Contractor placed traffic control and was only able to keep one lane open on E La Cadena Ave. LI # 10 The Contractor placed 6 lengths of 24" VCP from station 12+03 to 12+45 with the aid of minimum plate and jack shoring. The Contractor was still not backfilling and compacting the trench according to contract specs. in that they are not completing section compaction operations by the end of each working day. LI # 14 The Contractor placed 48" manhole rings at MH # 2 and 3 but the manhole rings are not according to City specifications and therefore is unauthorized work. ,The Contractor was instructed to support and protect in place the existing transverse sewer line as this -was not being done during excavations. TRAFFIC CONTROL COMMENTS: Traffic functioned relatively smoothly. EQUIPMENT EQUIP # AND PERSONNEL HOURS PERSONNEL ...----- CLASSIFICATION :.. � HOURS 31 OD JD BACKHOE- .544 8 RUBEN MENDOZA :FOREMAN/OPERATOII 8 JD LOADER _ DAVID FLORES - - - -- -- ;LABORER____ g CHEVY 2500 PICKUP - 1 JAIME ASSENCIO LABORER 1 HEVY 2500 PICKUP - - - --- JESUS LOPEZ- (LABORER 8 --. _ •CHEVY 2500 CREW TRUCK i 1 ADOLFO PAC HECO ;OPERATOR 1 10 WHEEL DUMP TRUCK --- ! 4 SAMUEL PACHECO 'LABORER g - 250OR HYDRO HAMMER 2 JOSE CRUZ _ LABORER 8 _ 31 OSE JD BACKHOE - 0 GONZALO TAPIA !OPERATOR 8 - - -- ---- i — ----- 8 ----.--__-_-- _ _ i JOSE RAMIREZ LABORER -- g - ---- ------ ---- -- - F' v �nPNAt _ - -- -- --- -r--- -- Contract Days Used Weather :Extra Work Remang -- - - ---- - - -- -- ---- _ DasDays _{ Days -- ------- Days Today � ! -- - - _NEW Total I ----- '+ '+ '_ daily report-1.xis Signature 44 S '6►► ll' p t ILI r1 s h -.V V N � r � r•• i O- X u � N eo a^y r f v r o Sr: S- ��77 I -A. , � P VL" Y1 `o Jp o0 too �t coo po S� �o p �N -O • - p� "� p � Z O r = .I l � > 44 S j W U 3 7 h Q 0— 4 O 4� V � 0 0 3 3 3 3 3 M M O S i W Z L D y V p V .y V � H N ) Y a V �H W I 3 _ J•� _ � c� � c� C" ti - ao' p o� — a* W < O Ttllo. t CA 6 00 "^ V3 Yo v` a uo O N O N. O H p O _O 40 cr j W U 3 7 h Q 0— 4 0 0 3 3 3 3 3 M M of y V p V � H N ) Q 0— 4 0 0 3 3 3 3 3 M M Page 1 of 1 CITY OF RIVERSIDE DAILY CONSTRUCTION REPORT 11/08/2007 through 11/09/2007 Thursday and Friday Start 20h00 Slop 3h00 Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS AM Traffic: Light PM Traffic Light Contractor Garcia Juarez Construction Weather ' Clear Cloudy Rain Location La Cadena Dr_, Spring Garden SL, Columbia Ave. and Palmarita Ave. Wind I Still .Moderate: Nigh Subcontractor Humidity Low Moderate High Inspector Anthony B. Allen (On duty 19h45 to 3h00) AM Tamp I 40 PM Temp I 51 CONTROLUNGITEUI •�� NUMBER WORK PERFORMED Line Item # 2 The Contractor began setting out the Traffic Control for Night work at approximately 20h00. Work ended 3h00 Friday morning. Line Item # 10 At the intersection of E.. La Cadena.and ..Columbia -Ave. The -Contractor had noF followed the correct offset from the survey stations: The result was kinks and the incorrect radius for the sewer pipeline. The error was difficult to detect due to the stations being staked at 25' and the extreme depth of the pipeline_ The Contractor spent the evening excavating the old trench and removing the incorrectly placed pipeline. The trench was backfilled and temporarily compacted and covered with temporary AC_ Significant Conversation:- Theinspector interviewed Ramon Brisseno and photographed him- He has worked on this site a number of evenings. The Inspector interviewed Jesus Lopez and photographed him. He has worked on this site for three evenings. The Contractor was instructed to pay attention to keeping a clean site and access for both vehicle and pedestrian traffic. Dan. Simmons - TRAFFIC CONTROL COMMENTS: Traffic signal were set to flashing all red in the intersections affected by operations in order to create a safer working environment. EQUIP # DESCRIPTION HOURS BH 31 1310D John Deer Backhoe 4 - -3 _ - L18 544H John Deer Front End Loader j e -EX13 - 235 CAT Excavator _.---------- _. _ _- l.._.. 7-_-- 9817417 10 Wheeler Dump Truck 5 BK59677 Crew Cab Pickup i 1 Javier Tones Elatbed_Service.Pickup......._.-- 6X53434 :Utility Pickup 1 487189 _Ingersot-Rand Lighting Plant 8 WT -06 Ford Water Truck -- -------- g O :544E John Deer Front End Loader i -- _ 3 5J19884 10 Wheeler Dump Truck — - 0 ' --`230 CAT ExcTa-vator/Compas!R . --- 1.5 - Contact Days Days Used Extra Work Days Dava Total 93 PERSONNEL CLASSIFICATION_ — HOURS Ruben Mendoza --' ----' -- — Foremardoperator- e Jesus Lopez' ---- - -- j ----Laborer- e Jaime Asceneio- - - -- - - - - --- David Flores --' — _---__ Laborer- t 8 Javier Tones - - Laborer I 0 4doftPachear!..__O.-.._. Jesus Rodriquez Laborer _ g Samuel Pacheco _ - --- — Laborer — 0 3amon Brissena- — tor F 8 lesus Ordones _ _—------- Laborer I e Remaining Days Y 11IM007 : 11:13 AM Nov.6 through Nov. 9 CITY OF RIVERSIDE DAILY Page 1 of 1 CONSTRUCTION REPORT 11/07/2007 through 11108/2007 Wednesday and Thursday Start 20hOO Stop 000 Project 116522 SEWER PIPELINE CAPACITY IMPROVEMENTS AM TratficLight PM Traffiqlight Contractor Garcia Juarez Construction Weather Clear Cloudy Rain Location La Cadena Dr., Spring Garden St., Columbia Ave. and Palmarita Ave. Wind 1 Still Moderate High Subcontractor Humidity I Low l Moderate; High Inspector Anthony B. Allen (On duty 19h30 to 4h00) AM Temp 42 PM Temp I 52 CONTROLLING ITEM i , NUMBER WORK PERFORMED Line item if 2 The Contractor began setting out the Traffic Control for Night work al approximately 20h00. Work ended 00O Thursday morning. Line llem # 10 At the intersection of E. La Cadena. and _Columbia -Ave _ The Contractor had not -follow -the correct offset- from- the survey stations_ The result was kinks and the incorrect radius for the sewer pipeline. The error was difficult to detect due to the stations being slaked at 25' and the extreme depth of the pipeline. The Contractor spent the evening excavating the old trench and removing the incorrectly placed pipeline. The trench was backfilled and temporarily compacted and covered with temporary AC. Significant Conversation: - The -Inspector iriCerviewed Jaime Ascencia and photographed him. He has worked on this site a number of evenings. .The Inspector interviewed David Flores and photographed him. He has worked on this site for three evenings. Dan. Simmons TRAFFIC CONTROL COMMENTS: Traffic signal were set to flashing all red in the intersections affected by operations in order to create a safer working environment EQUIP # DESCRIPTION HOURS BH 31 31 OD John Deer Backhoe --- �- .. -.- - 4 L18 i 544H John Deer Front End_ Loader -- 3 EX13 235 CAT Excavator___ -- 9B17417 10 Wheeler Dump Truck I 5 - 8K59677 !Crew Cab Pickup - 4Z09112 `Flatbed ServicQ _Laborer 6X53434 l ututy Pickup 1 487189 -, Ingersol-Rand Lighting Plant_ g ' WT -06 Ford Water Truck -- I - Samuel Puchew Laborer O 1544E John Deer Front End Loader 1 3 5J19884 10 Wheeler Dump Tnx k 5 _-:230 CAT Excavator/Compador Used Fla yy� Days T� 14��y !+ t+ - •- 1119/2007: 11:08 AM 93 PERSONNEL CLASSIFICATION HOURS !Ruben -- !R ---- I Foreman/Operator -s FJesus Lopez _. . Laborer I b Paime-Ascencio - - -- — - -- Laborer_ a _Laborer I 8 [Javier Tones -__ 1 taborer j p Adolro-Paeheco..._ _ -- ... - -------- ----- - -- _....-- - - - -- Operator_ _ 0 Jesus Rodriguez - — - - — Laborer I - Samuel Puchew Laborer p Ramon Brisseno JesusOrdones— I Laborer g Remaining Days Nov.7 through Nov. a CITY OF RIVERSIDE DAILY Page 1 of t CONSTRUCTION REPORT 11/0612007 through 11/0712007 Tuesday and Wednesday Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Start 20h00 Stop 5h06 Contractor Garcia Juarez Construction AM Traffic Light :PM Traffic. Light Weather_ Clear ,Cloudy Rain Location La Cadena Dr., Spring Garden SL, Columbia Ave. and Palmarita Ave. Wind Still Moderate- High Subcontractor - � Inspector Anthony B. Allen (On duty 19h00 to 5h10) HUmidrty Low I Moderate • High cONTROLUNG ITEM AM Temp 42 IPM Temp I 50 NUMBER WORK PERFORMED y Line Item # 2 The Contractor began setting out the Traffic Control for Night work at approximately 20h00. Work ended 3h30 Wednesday morning. Line Item # 10 At the intersection of E. La Cadena and Columbia Ave. The Qontractocdid.not.follow. the -correct -offset from the survey'statiom: - The result was kinks and the incorrect radius for the sewer pipeline. The error was difficult to detect due to the stations being staked at 25' and the extreme depth of the pipeline. The Contractor spent the evening excavating the old trench and removing the incorrectly placed pipeline. The trench was backfilled and temporarily compacted and covered with temporary AC. -- ' Line Ilem # 10 :The Inspector checked the compaction at manhole #1 and found that it was not compacted to standard. That very morning he had being forced into a lengthly debate with George concerning who was responsible for Quality Control and Quality Assurance Significant Conversation:- - -- .e. The Inspectorinterviewed Jesus Rodriquez and photographed him. He has worked on this site a num The Inspector interviewed Jesus Ordones and photographed him. He has workber of evenings. _ - - - --- - ed on this site for three evenings_ Dan. Simmons TRAFFIC CONTROL COMMENTS: Traffic signal were set to flashing all red in the intersections affected by operations in order to create a safer working environment EQUIP # DESCRIPTION • ---- HOURS BH 31 3100 John Deer Backhoe _ 4 _- L18 i544H John Deer Frent End Loader 1 -- 3 EX13 1235 CAT Excavator -_ _i 7 _ - 9817417 ' 10 Wheeler Dump Truck -._.. _ .. ----------------- 5-. SK5967T :Crew Cab Pickup ' 1 4209112 Flatbed Service pick ue- 6X53434 'Utility Pickup i 1 487189 _IngT? of Rapd Lighting Plant 7.5 i - WT -06 !Ford Water Truck i - - I 0.5 _ .0 544E John Deer Front End Loader 2 5J19884 - -10 Wheeler Dune Tmck j 5 kdol►o-Pacheco - - - -- �230 CAT ExcavatorlCom�actor --- 1 93 _PERSONNEL _ CLASSIFICATION HOURS Ruben Mendoza i Foreman1Operator I 7.5 Jesus Lopez Lam ' 7.5 Jaime Ascenao--- David Flores - Laborer 7.5 Javier Tortes - - ----- ----- -- I -- Laborer I o kdol►o-Pacheco - - - -- --- ..: --- lesus Ro nuez ! 0 -- - - Laborer 7.5 iamuel Pucheco Latxxer 0 tarnon Bdsseno �— C color 1 7 5 esus Ordones I Laborer I 7 5 cau�p i -- 3 Days UsedDays Extra Work Days Rema(ninp pays —Toda ITotal t---- _-- _.. --- ---- -- Signature 11114/2007: 9:46 AM Nov.6 through Nov. 7 CITY OF RIVERSIDE DAILY Page 1 of 1 CONSTRUCTION REPORT 11l05/2007 through tt10B12007 Monday and Tuesday Project t16522 SEWER PIPELINE CAPACITY IMPROVEMENTS Start 19h40 Stop 51106 Contractor Garcia Juarez Construction AM Traffi .Light PM T/afftCLighl Location La Cadena Dr.,Spring Garden SL, Columbia Ave. and Palmarita Ave.Weather Clear Cloudy Rain Subcontractor Wind Still Moderate High Inspector Anthony B. Allen (On duty 19h00 to 51110) Hum/tirfy Low Moderate; High CONTRou INc ITEM I AM Temp 45 PM Temp I 50 NUMBER ' WORK PERFORMED Line Item # 2 The Contractor began setting out the Traffic Control for Night work at approximately 191140- Work ended 5ho6 Tuesday morning. Line Item # 10 The Contractor removed the steel plates and continued excavating the trench for the 24" sewer line. The City Water Dep. personal arrived to shut off the water supply to the line uncovered the previous evening. The Contractor disagreed with the interpretation of plans as to their responsibilities with respect to this utlity. The Contractor was informed that it was their choice to continue the operation or wait approximately three weeks until the City had relocated the affected fine. The Contractor decided to proceed with :caution. This debate took place If Om approximately 21h00 too 22h30. Line Item # 10 IThe Contractor placed 8 feet of 24" pipe from from station 13+42 to 13+50 as they ran out of the short pipe required to make the radius after tunneling under the 8" water line. The City placed a band over a 118" hole the Contractor had drilled into the live line. 'On Tuesday it was discovered that the Contractor had being following the wrong radius and the pipes will have to be removed. Significant Conversation: - The -Inspector discussed with Ruben Mendoia the Contractors responsibilities to come interpret .services. The Inspector again discussed the requirements for two night crews upon working ssiimugly aouspnd that otrestrictiontectt traffic was to occur outside of the working hours. Ruben informed the Inspector that they would be working for approximately three days on a day shift starting the 11/6/2007 on Spring Garden St. Visitors On Site: - ;A City crew from the Water Dept. was present during the night to replace any damages to the B" live water line. Traffic signal TRAFFIC CONTROL COMMENTS. were set to flashing all red in the intersections affected by operations in order to create a safer working environment. EQUIP # DESCRIPTION93 HOURS _ BH 31 PERSONNEL 310D John Deer Backhoe _._-. --Ct11SSIFICATION _HOURS 4 €Ruben Mendoza L18 l544H John Deer Front End Loader I --' — Foreman/Operator g 3 IJesus Lopez - -- ----- -' - Dt13 235 CAT Excavator-- Laborer - --.-...---- - -- .- •-- _- . --- - L- -`9 EJafine Ascenao - - 9 9817417 -- - - -- -- - - -- ----- 10 Wheeler Dump Truck I 5 Flores -- Laborer 9 81<59677 IDavid :Crew Cab Pickup 1 Javier Torres T— 'Flatbed - - 4Z09112 Service Pickup-- - - -- -----� -----� I I -- -._-- :Adolro Pacheco -- -- - -- -- t 0 -- BX53434 --- _ .. — rator Utility Pickup 1 `Jesus Rodriquez t p - - 487189 ---- ersol-RandLightingPlant f - - - - - - -- - ..... ;Samuel Pacheco — -- — - 9 9 - WT06 - - - ;Ford Water Truck - --- - --- _-- - Labo►er ---.__-•- Ramon Brisseno 0 O - _-- � `544E John Deer Front End Loader 2- ;Jaime 9 SJ19884 - - ------ -i -- - Perraga ;10 Wheeler Dump rnt" I Laborer i - -- 5Rumon - g Briseno _ --- -_ - -!230 CAT Excavator/C_p_tor1 -- Laborer !Jesus Ordones 9 -- Contract Weather Laborer Days Used Dave Extra Work Days g rte. Oars i Remair>ing Days j Total I_T_--•------- ------- --- -- �' !+ !+ 11162007: 10:56 AM Nov -5 through Nov. 6 CITY OF RIVERSIDE DAILY Page 1 of 1 CONSTRUCTION REPORT 11(0412007 through 11105/2007 Line Item # 2 -The Contractor set out the Traffic Control for Night work. (The cones had new reflectorised tape on as requested by the inspector) Line Item # 10 The Contractor excavated the trench for the 24" sewer line and uncovered a 30" concrete water pipe. This slowed operations. The Contractor continued excavation and uncovered a live 8" waterline. The plans showed the line in a different location - The Contractor decided not to excavate and undermine the 8" line for fear of a blow out where muddy water could enter the sewer. Line Item # 10 -The Contractor could only place 13 feet of 24" pipe from station 13+29 to 13+42. Together with the Inspector, it was determine That a maximum of 37 feet could possibly have being placed in this nights operation due to keeping open a 12' traffic lane with 5' safety area, the time restraints etc. The Contractor backfilled and compacted what could be done then placed steel bridging plates and wedged with temporary AC. Significant Conversation: - The -Inspector disaissed iMth F26ben Mendoza the Contractors request to have Iwo teams of night work operations. The Inspector informed him that It is a possibility it the Contractor could guarantee and would provide written documentation that an Inspector would be present at all times that controlling operations were in progress and that no un -authorized work would be undertaken. Visitors On Site: - Traffic signal were set to flashing all red in the intersections TRAFFIC CONTROL COMMENTS Sunday and Monday Project 06522 SEWER PIPELINE CAPACITY IMPROVEMENTS Start 19h45 Slop 3h15 Contractor Garcia Juarez Construction AM TrafficLight 1 Weather PM Traffic Light Location La Cadena Dr-, Spring Garden St., Columbla Ave. and Palmarita Ave. I Clear i Cloudy Rain Subcontractor Wind Still i Moderate' High InspectorAnthony B. Allen (On duty 19h30 to 3h30) Humidity Low Moderate' High CONTROLLING ITEM I 4 Ruben Mendoza *-- - -- ----- .AM Temp 49 ' PM Temp 53 NUMBER WORK PERFORMED 3 ,Jesus V` Line Item # 2 -The Contractor set out the Traffic Control for Night work. (The cones had new reflectorised tape on as requested by the inspector) Line Item # 10 The Contractor excavated the trench for the 24" sewer line and uncovered a 30" concrete water pipe. This slowed operations. The Contractor continued excavation and uncovered a live 8" waterline. The plans showed the line in a different location - The Contractor decided not to excavate and undermine the 8" line for fear of a blow out where muddy water could enter the sewer. Line Item # 10 -The Contractor could only place 13 feet of 24" pipe from station 13+29 to 13+42. Together with the Inspector, it was determine That a maximum of 37 feet could possibly have being placed in this nights operation due to keeping open a 12' traffic lane with 5' safety area, the time restraints etc. The Contractor backfilled and compacted what could be done then placed steel bridging plates and wedged with temporary AC. Significant Conversation: - The -Inspector disaissed iMth F26ben Mendoza the Contractors request to have Iwo teams of night work operations. The Inspector informed him that It is a possibility it the Contractor could guarantee and would provide written documentation that an Inspector would be present at all times that controlling operations were in progress and that no un -authorized work would be undertaken. Visitors On Site: - Traffic signal were set to flashing all red in the intersections TRAFFIC CONTROL COMMENTS affected by operations in order to create a safer working errvironmenL EQUIP # DESCRIPTION 93 HOURS PERSONNEL BH 31 31 OD John Deer BackhoeC ,. - - t.AS,gIFI CATION H OURS L78 - i 544H John Deer Front End Loader i - 4 Ruben Mendoza *-- - -- ----- - - - Forema - 3 ,Jesus IX13 235 CAT Excavator i F... - - - - - -- 9 !a - - --- Laborer - _-1- 7.5 7.5 9817417 ;10 Wheeler Dump Trude E -- 81<59677 ;Crew Cab Pickup---- -•_5 IDavid Flores i 1 — - . --- Laborer 4ZO9112 `Flatbed Service Pickup -- ;Javier Torres 1 -- - - -- _... - taborer ! 0 - - - - - — [Adollb Pacheco 6X53434 Utility Pickup -- — perator 0- 'In Jesus Rodriquez - ---E - --- i - 487189 ersd-Rand ' —_Q _ Lightlnq Plant - -----------' 7.5 Laborer 7.5 - (Sernuel WT -06 Water Thick I - --Ptrcheco -- -- -- .... Lab er 0 _Ford - ---1--- =5 Ramon Bdsseno - 1 --- -- O ..'544E John Deer Front End Loader -- —_' --- 2 -Operator ` _ I 7.5 5,119884 ------ _ -- -- 10 Wheeler Dump Truck 1JaimePe a �� ! Laborer 7.5 - - -- - --- 5 B ;Rumorsrlseno CAT Expvator/Compactor `Jesus _ Laborer 7.5 Ordones -- Contr�ct r-- Weattrer Days Used Daus I Extra Work Days Remaining Days Laborer 5.5 :. Tata► _.. i- + f{---- I 11!612007 : 10:33 AM Nov.4 through Nov. 5 _ s h f � �+ c t y — •n c h T � T 1 h T f n 2 � r s s v J t -A y � a Y � `^ UI h A4 �1 o in J h C) Y )l1 ct •il v of o y 3 a 3 0 u = 6l r - i O Its - o l..l - � QJ s 0 0 . ` 4 Rf�C1-fl, f'A- I �. -� J I I f I �. c� _ � d N Y s I I I I 'I W O (y U \,P. k,"10 c>.; 1. 1 �-Io 1 P6-1 r �o _ � o I �V- 0- vlo 0 KV - 1>0 ly— tTl a a DQ zA C� o� o� N Z v _ M N ai o N t - 07 4 � �u7wX CITY OF RIVERSIDE DAILY Page t of t CONSTRUCTION REPORT Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Contractor Garcia Juarez Construction Location La Cadena Dr_, Spring Garden SL, Columbia Ave. and Paimarita Ave. Subcontractor Inspector Anthony B. Allen (On duty 19h30 to 5h00) CONTROLLING REM NUMBER WORK PERFORMED Line Item # 2 The Contractor set up their equipment in the jacking pit floor for the 24' steel casing Line Item # 12 The Contractor began setting out the traffic control at 8h00. 11/15/2007 ihrough iiii6/2007 Line Item # 10 :The Contractor removed the temporary AC. and excavated the trench for the 24" sewer line. After the shoring was placed four T and four 2' pipe joints were laid from station 13+24 to 13+60. 3/4 inch stone was placed and watered around the pipe and the trench was backfilled and compacted with native soils. Significant Conversation: - The Inspector questioned the Contractor as to their following weeks working plans. They were told to -notify" Inspector. The Contractor was instructed to pay particular attention to shoring of the newly excavated Trench in the areas of the old trench. The Contractor was reminded that certification was required by their surveyor for the jacked pipeline. dditional Equip. P+H Crane # 41852, Boring Machine, Welding Plant etc., 3 Lighting Plants, J/D Broom Tractor, 3 Pickups. TRAFFIC CONTROL COMMENM Traffic signals were set to flashing all red in the intersections affected by operations in order to create a safer woridng environment. EQUIP # Thursday and Friday Start 81100 Stop 5h00 .AM Traffic Light (Cloudy PM Traffic Light t WeatherClear 1 I Rain Wind - Still Moderate! High Humidity Low Moderate High .A. Temp 1 35 PM Temp 1 51 Line Item # 10 :The Contractor removed the temporary AC. and excavated the trench for the 24" sewer line. After the shoring was placed four T and four 2' pipe joints were laid from station 13+24 to 13+60. 3/4 inch stone was placed and watered around the pipe and the trench was backfilled and compacted with native soils. Significant Conversation: - The Inspector questioned the Contractor as to their following weeks working plans. They were told to -notify" Inspector. The Contractor was instructed to pay particular attention to shoring of the newly excavated Trench in the areas of the old trench. The Contractor was reminded that certification was required by their surveyor for the jacked pipeline. dditional Equip. P+H Crane # 41852, Boring Machine, Welding Plant etc., 3 Lighting Plants, J/D Broom Tractor, 3 Pickups. TRAFFIC CONTROL COMMENM Traffic signals were set to flashing all red in the intersections affected by operations in order to create a safer woridng environment. EQUIP # DESCRIPTION i _. HOURS _ BH 31 :310D John Deer Backhoe L16 i544H J/D Front End Plpe Loader 1 EX13 235 CAT Excavator — __. 9877417 i 10 Wheeler Dump—Truck—�.T 2 8K59677 Crew Cab Pickup — 4Z09112 _'Flatbed Service Pickup — (Utility 6X53434 Pickup -- 1 487189 _1[rersot R -Rand Lighting Plant g-- WT -06 — —. iFordWaterTnxk f 0 1544E John Deer Front End Loader I 4 - 5J19884 :10 Wheeler Dump Truck I 2 EX12 !235 CAT Excavates/Compactor I 2 t� CLAS-SIFICATION - HOURS ben Mendoza --_ --- --f-"-- ForernaNODeretOr i o Lopez Ascendo Flores ! Valdez _--- ! Pacheco --� Rtx1_gi uez _ i :1 Pucheco -- - -9 - Laborer- -- -. . Laborer g Opntor- Laborer- Laborer -Operator_ .._ -_ .. 9.. — Laborer g_ - — Laborer i g 11119/2007: 5.37 PM Nov. 15 through Nov. 16 CITY OF RIVERSIDE DAILY Page 1 of 1 CONSTRUCTIAN Dt:pnoi- iiii4/2007 through 11115/2007 Wednesday and Thursday Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Start AM TrafTiC �8hoo Stop 000 Contractor Garcia Juarez Construction Traffic signals Light t pM T�af cLight Location La Cadena Dr., Spring Garden SL, Columbia Ave. and Palmarita Ave. Weather Clear Cloudy Rain Subcontractor Wind Still Moderate] High Inspector Anthony B. Allen (On duty 19004h00) Humidity Low Moderate High coN1RaLLwc rrFat .to AM Temp 35 PM To ` 51 NUMBER I WORK P 544H J/D Frord End Plpe Loader - 1 " ERFORMED Line Item # 2 -The Contractor did the fine grading of the jacking pit floor for the 24" steel casing and placed the floor plates and boring machine. Line Item # 12 The Contractor began setting out the traffic control at 8h05. Line Item # 10 The Contractor broke the AC, removed the temp. AC and excavated_ the trench in the correct position. One 7' and two 2' pipe joints were laid from station 13+13 to 13+24.3/4 inch stone was placed and watered around the pipe and the trench was backfifled and compacted with native soils. The Contractor chose to place only these joints due to the position of the 30" water line, the traffic lane i to two 'P pipes when removing them from there incorrect positions. positions and the damage Significant Convematiow- The Inspector interviewed a new night worker and photographed him. Doug Buriow, The Contractor was instructed to pay particular attention to shoring of the new excavated trench in" e_ areas o_old trench. the .The Contractor was reminded that certification was required by their surveyor for ihe'acked i Gne. 11/19/2007: 5:39 PM Nov.14 through Nov. 15 ;Additional Equip. P+H Crane # 41852, Arrow USA Stamper Traffic signals TRAFFIC were set to flashing all red in the intersections # HJ1250R, 3 Lighting Plants, J/D Broom Tractor, 3 Pickups: CONTROL COMMENTS: affected by operations in order to create a safer working environment. EQUIP # __ _... DESCRIPTION HOURS 93 BH 31 �_.. -- - — - 310D John Deer Backhoe ---- i 2 z_-- _—.._.__PERSONNEL ..._. [Ruben Mendoza CLASSIFlCATION HOURS- L18 544H J/D Frord End Plpe Loader - 1 i Forem/Oenfor 8 • - t ------- - -.'-J-esus Lopez ---- - - - _EX13 9817417 ' =. 7--- -€-Jaime Ascendo- Labo-rer- - - - -- -- __ 10 Wheeler Du Tnidc '- + - - -- 2 8K59677- Craw Cab PtdctiP 1 David Flexes ' Laborer -' 8 4209112 - -- - — - `Flatbed Service 1 J urge Valdez [ - I Laborer 8 Adolfo Pacheco i 6X53434 -Utility Pldmp .-. I 1 !Jesus for e 487189 iingeT2pgand Lighting Plant_- -- 8 R uez f Laborer 0 WT 06 `Ford Water Truck ;Samuel Pucheco i Laborer - _-.--�._.___-- __.4 ___-.....-eRarnon-Brisserio--._ _ ____._ _____._I__. 8 LE John Deer Front Fled Loader FJesus _.. _ - - -- 5J19884 :10 Wheeler Dump Truck 2 Ordones i i 8 E)C12 — 1235 CAT Excavator/Gprri r 2 :EdyurdoRodriquez ! Laborer 8 Do B.urlow e - -- _ ? Corriract used weayw Dan Extra Work Days O erator g Remalr** Deva + l I 11/19/2007: 5:39 PM Nov.14 through Nov. 15 CITY OF RIVERSIDE DAILY Page 1 of 1 CONSTRUCTION REPORT 11113!2007 through 11114!2007 -------------- Tuesday and Wednesday Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Start 8h00 Stop 51100 Contractor Garcia Juarez Construction AM TraffiC�Light PM Traffic Light Weather t Clear .Cloudy Rain Subcontractor Location La Cadena Dr., Spring Garden SL, Columbia Ave. and Palmarita Ave. Wind Still Moderate High - ..- Humidity Inspector Anthony B. Allen (On duty 191100 to 5h00) Low Moderate - - I - - --- - g corarnouulc 11E11I AM Temp 40 PM Temp Hih 53 NUMBER WORK PERFORMED Line Item # 2 The Contractor excavated the last 1l3 of the jacking pit for the 24" steel casing and placed the second trench box in position. Line Item # 12 The Contractor began setting out the traffic control at 8h00. Line Item # 10 The Contractor removed the bridging plates and excavated the trench in the correct position- Progress was slow due to services. Four joints of 7' pipe were laid from station 12+57 to 13+13.3/4 inch stone was placed and watered around the pipe and the trench was backfilled and compacted with native soils. ,Significant Conversation: - The Inspector interviewed a new night worker and photographed him- Edyurdo Rodriquez _ The Contractor was notified to repair the traffic signal loop box that had being damaged. The Contractor was instructed to pay particular attention to shoring of the newly excavated trench in the areas of the old.trench.—" ;The Contractor was directed to make the jacking pit area safe for both motorist and pedestrians. Dan_ Simmons RE. did a site inspection and delivered updated plan. sheet 1013 --- --- - — !Additional Equip. P+H Crane # 41852, Arrow USA Stamper # HJ1250R, 3 Lighting Plants, J/D Broom Tractor, 3 Pickups. TRAFFIC CONTROL COMMENTS: Traffic signals were set to flashing all red in the intersections affected by operations in order to create a safer working environment. EQUIP #t DESCRIPTION _ BH 31 ;31013 John Deer Backhoe _ L16 l544H J/D Front End Pipe Lo EX13 '235 CAT Exmvator - _ - .B174117 10 Wheeler Dump Trude 81<59W 'Crew Cab Pickup - 4Z091-1-2=Flathed-Service-Pickup- 6X53434 — 487189 WT -06 -- 5J19884 EX12 :Utility Pickup--- Ford Water Truck 544E John Deer Front End Loader _ HOURS -:-- 2 2 I 1 I 1 4 2 2 93 PERSONNEL le Valdez_ ---- bfo Padr2co —-- rs Rodriguez -- - CLASSIFICATION HOURS Foreman/Operator 9 Laborer 9 11/14/2007: 9.55 AM Nov. 13 through Nov. 14 ' L borer 9 Laborer — g — Operator g Laborer 0 Laborer ig Laborer g -- ' Laborer I g 11/14/2007: 9.55 AM Nov. 13 through Nov. 14 Page 1 of 1 CITY OF RIVERSIDE DAILY CONSTRUCTION REPORT 11/12/2007 through 11/13/2007 Monday and Tuesday Start unknown Stop 4hOo Project #6522 SEINER PIPELINE CAPACITY IMPROVEMENTS AM Traffic Light PM Traffic!Light I Contractor Garcia Juarez Construction i Weather Clear !Cloudy i Rain Location La Cadena Dr., Spring Garden SL, Columbia Ave. and Palmarita Ave. Wind Still Moderate High Subcontractor - ---- -- 'Humidity Low Moderate' High Inspector Anthony B. Allen (On duty 19h15 to 4h30) AM Temp39 'PM Temp I 52 -. CONTROLLING ITEM . - - --- NUMBER WORK PERFORMED V V Line Item # 12 . When the Inspector arrived at 19h30 on site, the Contractor had already excavated, leveled and prepared an area for the tunnel boring operation at the intersection of Columbia and Chicago roads. This is unauthorized work as there was no inspector present during this operation and the Contractor had being instructed by the Engineer not to proceed during day time vvorkins hours_._ The Contractor excavated the first 2/3 of the jacking pit for the 24" steel casing and placed the first trench box in position. I Line Item # 2 'The Contractor began setting out their traffic control at 20h00. Line Item # 10 The Contractor broke the pavement along the coned trench line with a stamping machine at the intersection of Columbia Ave and E. La Cadena Dr. After re -excavating the correct trench and shoring the sides, the Contractor placed the 2_4" by T sewer pis. _ 4 Joints of T length were placed from station 12+57 to 12+85. 3/4" stone was placed around the pipe and the trench was back_ 'filled and compacted_ The top of the trench material was covered with tem ora AC :And steel ales. 'Significant Conversation:- -- --- — --- e nspector interviewed the three new night workers and photographed them. They are, Jorge Valdez Samuel Pacheco and Adolfo Pacheco. A fourth worker who had done the day time excavationwas leaving when the Inspector arrived on site. The Contractor was instructed to pay particular attention to shorir%of the newt rLexcavated_ trenih in the areas of the old trench. The Contractor was directed to make the jacking pit area safe for both motorist andpedestrians. :Additional Equip. P+H Crane # 41852, Arrow USA Stamper # HJ1250R, 3 Lighting Plants, J/D Broom Tractor, 3 Pickups. . TRAFFIC CONTROL COMMENTS: Traffic signals were set to flashing all red in the intersections affected by operations in order to create a safer working environment. EQUIP # j _ _ DESCRIPTION _ _ HOURS F93 PERSONNEL BH 31 -- - -- h310D John Deer Backhoe i 2 [ [Ruben Mendoza CLASSIFICATION i HOURS 1-18 544H J/D Front End PPi�Loa 1 ForemaNO for 8 - [X13 .der ,235 CAT Excavator . —_—I 5--JalmeAscerrcio Jesus L o�— -- ------ Laborer.. I e 9817417ItO WheelerDum Trude La — j — e 8K59677 jCrew Cab Pidcu �— 2 1 David Flores brga Valdez Laborer ! 4ZO9112 —. _ Ftatbed Service pickup 1 __ rAdolfo Laborer I 4i - 6X53434 `utility Pickup � Pacheco Operator l 4 487189�Irgersol Rand Ughting Plant 1 1 :Jesus Rodriquez ° Laborer 8 a [Samuel Pucheco I WT -06 - _ -- -- - ;Ford Water _ ; Laborer 4 __— -- - - -!544E John Deer Front End Loader ...-.__p.----------€RarrlorrBrisseno- 3 -- - [Jesus Ordones - - -- -- Operator L . B 5419884 i 10 Wheeler Dump Trude i 2 Laborer 8 _ .-- X235 CAT Excavator/Com - --DC12 -- Contract Weather Days Used . Days Extra Work Days Reith k ft Days Tod _ + Total - 11/14/2007: 9:53 AM Nov. 12 through Nov. 13 CITY OF RIVERSIDE DAILY Page 1 of 1 CONSTRUCTION REPORT 11120/2007 through 11121/2007 Tuesday and Wednesday Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Start 8h00 Slop 5h00 Contractor Garcia Juarez Construction AM TratgdLightQPM Traffic- Location La Cadena Dr., Spring Garden SL, Columbia Ave. and Palmanta Ave. Weather Clear .Cloudy Rain Subcontractor Wnd.. Still Moderate: High Inspector Anthony B. Allen (On duty 191100 to Shoo) Humidity Low {Moderate: High CONTROLLING ITEM I ;AM Temp 30 :PM Temp l 48 - NUMBER WORK PERFORMED y V Line Item # 2 The Contractor continued with the boring operation and the welding of the steel casing pipes. Two 20' joints of casing were placed. Line Item # 12 The Contractor began setting out the traffic control at 8h00. The freeway onramp was dosed at 21hoo and opened at 030. Line Item # 7 The Contractor removed the plates and temporary AC- and continued the excavation of the trench for the 18" sewer line from 'station 14+02 too 14+62 (eight joints of 7.5'). The Contractor made a real effort to obtain the correct compaction of the backfill. Line Item # The rings were placed into position for manhole # 3. The Contractor provided a letter of certification from the manufacturer. The Contractor placed a temporary cap the on manhole and compacted the backfill around it satisfactorily. The Contractor spent a great deal of the morning sweeping, re airin storm water catch basin rotection and making the site safe. -- p - g - - P..... ,Significant Conversation: -- -- _. _ . The Contractor had being asked the previous night forth we certification He was told that it would be rovided this event but it was not. The Contractor was issued a correction notice after the' Ins - --- _------ -n9 Inspector had spoken with Ruban, Jim Jackson and the RE ,Additional Equip. P+H Crane # 41652, Boring Machine, Welding Plant etc., 3 Lighting Plants, J/D Broom Tractor, 3 Pickups. TRAFFIC Traffic signals CONTROL COMMENTg. were set to flashing all red in the intersections affected by operations in order to create a safer working environmenL ��IP-# DESCRIPf10►�93 - _ BH 31 - --- _-._._.HOURS .-----PERSONNE_- - --- - IFICATION HOURS '310D John Deer Backhoe = 2 —_ -T -- -- i L16 - Ruben Mendoza i ForemaN rotor - I544H J/D Front End Pipe Loader Q FJesus L r 1 - `( -- ° 9 .. - EX13 1235 CAT Ercavator ------- --- t Laborer 4 =JaimeAscenclo g 9B77417 -_- Laborerruck 9 1 .David ==---!JorgaValdez 8)(59677 r Laborer 1 9 4ZO9112 `Flatbed Service Picku {------- - -- :Adolfo Pacheco 6X53434 lJtil Pkku erator - � P. - - - _--._ 1 `Rosendo Akbser and Ale' T Nunez L 9 487189 _Ingersol Rand Lighting plant -- ----- Laborer 7 =Samuel Pucheco 0 - WT -06 Ford Water Truck Laborer 0 - _---�- [Ramon Brisseno -g Operator 544E John Deer Front End Loader 2 -- 9 5J19884 {JesusOrdones T--- -- Laborer X10 Wheeler Dump Truck 1 9- EX12 ---- E- —-Edyurdo Rodriquez 235-CAT_Excavator/CompaClOr -- --�- Laborer g o 'Doug Burtow . Contrad--Day-- Operator s Used Weather Extra Work Days Rernabrbhg Days u — I d -- 9 Total - { 11/21/2007: 10:46 AM Nov.20 through NOV- 21 CITY OF RIVERSIDE DAILY Page 1 of 1 CONSTRUCTION REPORT Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Contractor Garcia Juarez Construction Location La Cadena Dr., Spring Garden St, Columbia Ave. and Palmarita Ave. Subcontractor Inspector Anthony B. Allen (On duty 19h00 to 5h00) CONTROWNG nEM I NUMBER WORK PERFORMED Line Item # 2 The Contractor continued with the boring operation on the correct alignment. Line Item # 12 The Contractor began selling out the traffic control at 8h05. 11119/2007 through 1112012007 Monday and Tuesday -Start 7h30 Stop 5h00 AM Tralfic Light PM Tra*Light Weather Clear •Cloudy Rain Wind __ Still Moderate j High Humidity Low ! Moderate. High AM Temp 32 'PM Temp 50 Line Item # 7 . The Contractor removed the plates and temporary AC. and continued the excavation of the trench for the 18" sewer line from man- hole # 3. This night work began at station 14+02. No pipe was laid due to the one inch copper live water fine being damaged. Line Item # 10 ,The end of the 24" pipeline was prepared to tie into manhole # 3 Line Item # 20 .The base of manhole #3 at 13+76.27 was prepared and poured. :Significant Conversation:- - --- -- -- ------------- - e Dan Simmons visits the site and did not accept the 24" pipe join being more than 1' outside the manhole. The Contractor was instructed accordingly. - he Inspector interviewed Rosendo Alcoser and Alejandro Nunez At approx. 10h30 the Contractor broke an one inch water line at station 14+32. The City Emergency Services were called out and all production work apart from the manhole concrete pour was hafted for the night _ Additional Equip. P+H Crane # 41852, Boring Machine, Welding Plant etc., 3 Lighting Plants, J/D Broom Tractor, 3 Pickups. TRAFFIC CONTROL COMMENTS: Traffic signals were set to flashing all red in the intersections affected by operations in order to create a safer working envirorunent BH 31 _ 31 OD John Deer Backhoe 2 L76 j5441-1 J/D Front End Pipe Loader - !r - 0 - EX13 - '2_35 CAT Excavator- )en Mendoza - 9B17417 X10 Wheeler Dump Truck ' 1 81<59677 !Crew Cab Pickup i 1 4ZO9112 Flatbed Service Pickup - 1 6X53434 Utility Pickup 1 487189 �Ingersol-Rand lighting Plant 7 -- - WT -06 --i 'Ford Water Truck I --- -- ---- 0 --- _ .544E John Deer Front End Loader 2 SJ198t)4 .10 Wheeler Dump Truck ------~- 1 EX12 `235 CAT Ex is Ordones 93 --.CUkSS)FFCAT10N--;`►�i�jR� )en Mendoza j ForemaryOperator t 7 us Lopez Laborer --- ne Asr endo I Laborer i - 7 rid Flores I Laborer 7 )e Valdez 1 Laborer j 7 - 00 Pacheco Operator 7 endo Alcoser and Alejandro Nunez Laborer j 5 nuel Pucheco Laborer wn Brisseno — _ i Operator 7 is Ordones Laborer 7 urdo Rod uez ----- Laborer 7 -- ---,---- cavatod_.ompador. 0 DougBurlow ! - pays Used De Total O erator 7 Extra Work Days Rerrutkdnp Days t 11/21/2007: 10:48 AM Nov. 19 through Nov. 20 CITY OF RIVERSIDE DAILY Page 1 of 1 CONSTRUCTION REPORT 1 111812007 through 11119/2007 Sunday and Monday Start 7h30 Stop shoo Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS AM_TiaffCiLight PM Traffic! Light Contractor Garcia Juarez Construction Weather i Clear Cloudy I Rain Location La Cadena Dr., Spring Garden SL, Columbia Ave. and Palmarita Ave. Wind Still Moderate High Subcontractor -- Humidity Low I Moderate High Inspector Anthony B. Allen (On duty 19h30 to 5h00) t AM Temp 1 32PM Temp 49 CONTROLLING ITEM . -.. NUMBER WORK PERFORMED Line Item # 2 The Contractor began setting up their equipment in the jacking pit floor at 7h25 and began the boring operation at approx 8h30_ Line Ilem # 12 The Contractor began setting out the traffic control at 8h00. Line Item # 10 The Contractor removed the temporary AC. and excavated the trench for the 24" sewer line. After the shoring was placed one T and two 2' pipe joints were laid from station 13+60 to 13+71. The base for the manhole was prepared and three 7'6"joints plus one 12" joint was placed. 3/4' stone was placed and watered arround the pipes and native soil was_ backfilled. and compacted. .Because the length of the I _- -'----- ------ _. n9 pipes resulted in a length of pipe 2'2" outside of the manhole, it was decided to extend the manhole foundation by 1'2" in order to support the 24" pipe. - The 24" boring casing, was removed after boring approx. 15' as it was approx_ 2" off the horizontal- The vertical was accurate - - - - Significant Conversation:- -- -- - - - --- --- -- -- The Inspector questioned the Contractor as to their followin4vreeks working plans_They weretold to nob the Ins ector. -- The Contractor was instructed to pa articular attention to short — X_P_. _. _ . . _- - — of the newly excavated trench in the areas of the old trench. The Contractor was reminded that certification was required for the pre -cast manhole rings. Additional Equip. P+H Crane # 41852, Boring Machine, Welding Plant eta, 3 lighting Plants, J/D Broom Tractor, 3 Pickups. TRAFFIC CONTROL COMMENTS: Traffic signals were set to flashing all red in the intersections affected by operations in order to create a safer working environment. - EQUIP # DESCRIPTION HOURS BFI 31 310D John Deer Backhoe i L Laborer ; 2 L181544H J/D Front End PI�e L oader �. - -. ( 1 EX73 - =235 CAT Excavator -}vator i 8 9817417 -10 Wheeler Dump Truck 2 BK59677 -Crew Cab Pickup 1 4ZO9112 ° Flatbed Service Pickup 1 6X53434 _UBllty Pickup 9 487189- _Ingersol-Rand Ughft Plant 9 WT -06 :Ford water Truck I 0 )rdones i 544E John Deer Front End Loader 3 5J19884 10 Wheeler Dump Truck 2 EX12 _1235 CAT Excavator/Compector 2 Remaining Days i Contract Days Used Weather Days — Extra Work �Ys -- --- I + Total 11/21/2007: 10:49 AM 93 PERSONNEL _ ----- - GtASSIFICATION . HOURS Mendoza Foreman/Operator _ 9 L Laborer ; 9 Ascencio r ab - lores Laborer I 9— g /aldez i — Laborer 9 Pacheco O for 9 2odriquez ---- i Laborer 1 0 IPucheoo Laborer 9 Brissero - Operator 9 )rdones i Laborer I -- g 3 RodriquezLaborer 9 - urlow Remaining Days i Nov -18 through Nov. 19 CITY OF RIVERSIDE DAILY Page t of T CONSTRUCTION REPORT 1/29 900710. 11/2912007 !h!'0*--9h 1-3012007 'Pro ect #8522 SEWER PIPELINE CAPACITY IMPROVEMENTS Thursday and Friday Start Bh00 . Stop Sh00 hoo Contractor Garcia Juarez Construction Location AM Tr8 Light PM T!S _ � Ligr/fC ht La Cadens Dr_, spring P Garden SL, Columbia Ave_ and Palmarita Ave. Subcontractor Weather Clear Cloudy Rain Inspector Anthony B. Allen (On duty 19h30 M_ Still Moderate High Numrd NY Low to 4h3)) corrrnotiwo mLar . Moderate! High - Ixa+eec I 4M Te -._mP 27 PM Temp I 49 WORK PERFORMED Line Item * 2 ; - ...... _ Line Item # 12 The Contractor began setting out the traffic control at 8h00. ; Thefreeway onramp was dosed this night. Traffic "owed9ood_ Line Item * 7 The Contractor removed the temporary AC- and placed a 10" along E. La Cadena Ave_ PVC temporary siphon to detour the 10" existing sewer 6ne along The Contractor placed the wrings of the manhole at 77+ 00 on E. La Cadena Ave. Significant Conversation:- . --- - - --------------------__ - - - - — Additional Equip. P+H Crane # 41852, Boring�� tOMTROLighting Plants, JID C B COMA room Tractor, Traffic signals were set to flashing all red in the intersegions - 3 Picku a ffe ted by operations in order to create a safer working environment EQUIP * DESCRIPTION 93 '- HOURS - BH 31 -310D John Deer gadrlloe -�- — — ' - =- - - PERSONNEL - ----- -- i 6 = -- - — 'Ruben CLASSIFICATION en Mendoza_ LTO S44H J/D Front End pt Lir r HOURS ForenlarVO _�-_ 0 (Jesus _ EX13 235 CAT Excavator — _. 9 t - . --- -- - - - ; D Palme Ascenco tx-e--leTn_ck-- -- - ---- -- �-- - --t0------- -- ----9B4741-7------ =r10- Laborer 9 -r--Dum 8K59677 newCabPldwP. -9 ---- -W _. 4Z09112 !FlatbedSe -------L-�— -J�y --- -b—ora-r t H -- —r ---- - --- 1 AdolfoPacheco 6X53434_TtJBlity Pickup Laborer ' 0 _ . . rOperator 487189E !hn.i� Rodriquez ' ,.-,--- �9e<sol-Rand Lightng.Ptant - r O ' t j .. WT 06 Ford WaterT —� 9 FSamuei pub - ----- 1 Laborer 0 . - --- - 0 €Ramon Brisseno - �544E John Deer Front End Loader -- — -- Laborer i 9 - - 2 Jesus Ordones —5J19884 10 Wheeler TruGc ¢ for i 0 !Laborer — 0 Rodriquez 9 1JJsus 12WO07.6:09 PM Nov' -29 through Nov. 30 CITY OF RIVERSIDE DAILY Page t of t CONSTRUCTION REPORT 11/28!2007 through 11!29/2007 1 118522 SEINER PIPELINE CAPACITY IMPROVEMENTS Wednesday and Thursday Project Start 8h00 - Stop 5h00 Contractor Garcia Juarez Construction AM Tra /6C Light PM Tia Light Location La Cadena Dr., Weef) Clear Cloudy Rain -Spring Garden SL, Columbia Ave. and Palmarita Ave. Subcontractor W Still Moderate! High Inspector Anthony B. Allen (On d 19h30 to 4h30) Humidity Low corrtAotLM[TBI i Moderate. High I AM___ __&! 28 PM Temp 50 M1tem WORK PERFORMED - Line Item :K 2 Line Item * 12 The Contractor began setting out the traffic control at 8ho0. The freeway onramp was closed Ibis night. Traffic _- fl owed good. Line Item 0 7 The Contractor removed the temporary P -ry and continued /tie excavation.of the trench for the .18"sewer Ane alon was E. La Cadena from station 17+00,5 too 17+40. The trenchnch covered with steel plates. - . _ The Contractor - --- -- - _ -- prepared the base of the manhole at 17+ - _ 00 for the foundation - - our and cast the co . gnificant Conversation:- ---------. . - ----- A Dai N Extra Work was p -e_ ewaxeerd- b - _. line an - e I or and ned by the- C�tractor for the tom- p=ry o_ n line to be placed under the existing t0" terracotta s --- ewer tine and the telephone ducts at station 17+ - -- -- -- 21. The a concrete bed that was in the wa of the new sewer tine. sx' line had being supe- - _, ;Additional Equip. P+H Crane iF 41852. Boring Machine, etc 3 Lighting -- - --- - --- ---- --- TRAFFIC CONTROL CC bng Plants, J/D Broom Tractor, 3 PiGcu `-- Traffic signals were set to Bashing all red in the int E1tiS: p' __..-.-. ......_. 9 exsections affected by operations in order to create a safer working environment EQUIP Ai _ - DESCRIP710N _ - - HOURS - - _- BH 37 310D John Deer Backhoe -..—_ — -PERSONNEL ' 2 CLASSIFICATION N HOURS . . L76 544H J/D Front End Pipe t pada' __ _ _� - ---------- i ForemaN 235 CAT Excavator. —� 1Jesus Looe' ' 9 — 0 WallneAscencio l _ Laborer __- 9B17417 i10 Wheeler Dura Truck 9 - eK59677 !CrewCab Cab Pkk 3 `D avid Flores _ _uP - 4ZO9112Flatbed Service Pldcu 1 ¢Jorge Valdez r B - -------_-. _,. - 1t LabP_acbecoorer - - �( Awa USrrty Fidcu _rt4�kl►[p___ -- --- -- - --------`----0 - — ---- v — --- 1 487 --r— g_ 189 _ 'I 'E rdo Rod --- �n9ersot Rarxf Lighting Plant; 9---------- N..r _ WT -06 - Ford Water Track _ i 1Sar CO 0 'Ramon BrisseripLaborer 9 ._._ .._ .-__-- 1544E John peer Front End Loader 4 tor - -- 5J19884 •10 Wheeler Dum Truck tJesus O donee 9 3 1-1931s R ez Laborer 9 Two DC12 '235 CAT Excavator/Com ter w I------------ 12r3/2007: S2l3l2007 : 6:07 PM NOV-28 through Nov. 29 CITY OF RIVERSIDE DAILY Page 1 of 7 CONSTRUCTION REPORT 71/27/2007 through 11/28/2007 Tuesday and Wednesday Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Start 8h00 Sto 4h30 Contractor Garcia Juarez Construction AM Tia Light PM T refffC Light Location La Cadena Dr., Spring Garden SL, Columbia Ave- and Palmarita Ave. leather Clear Cloudy Rain Subcontractor Wind Still l — :Moderate; High Inspector Anthony B. Allen (On duty 19h30 to 4h30j Hum Low Low Moderate' High Ca MOLLNG "EW I AM Temp 29 PM Temp 50 NtEA WORK PERFORMED Line Item # 2 The Contractor removed the shoring equipment from the pit and began the backfilling and compaction operation, including F/sand. Line Item # 12 The Contractor began setting out the traffic control at 8h00. The freeway onramp was not Dosed this night_ Traffic flowed ppd Line Item # 7 , The Contractor removed the temporary AC. and continued the excavation of the Ire _.. -- nch for the 18" s from station 16+49.5 loo 17+00.5 (six joints of 7.5' plus three joints of 2 . The trench was Dactcfilled and coeWer Fmpane ded iin layers.. La dena _ . ....- ...-._. ------ prepared the base -of the manhole ar l?+ ----- - - -- - - - ---- OOTor the significant Conversatlon: - - - ------ — ----- ;Additional Equip. P+H Crane # 41852 Boring Machine, et(-. 3 TRAFFIC CONTROL Lighting . J/D Broom Tractor, 3 Traffic signals were set to flashing all red in the intersections affected b Operations in order to create a safer Pickups. Y working environment. EQUIP # DESCRIPTION93 _ BH31--- �3f0E?Jotm Deer-Backhb —"- -- HOURS —i--- ------- L16 - J/D_Front End pipe Loader ' 2 [Ruben _t544H -- — EX13 f235 CAT -�--- -- [Jesus I F 9B774f7 '10 Wheeler DumpTrudc i Jaime) F -- 8K59677 1Crew Cab Pick David F r-- --- - -- 1 _4ZO9112 'Flatbed Service plqk 1 !Jorge V ,ly Pickup __ I --4871-8g.- IrxFersoi Rand �tin9 plant F 1Edyurdn --VVT-O6 IFord Water Truck i . t 10 CAT — 1 8 3 1 1 9 1 4 3 4 9 9 B — ' laborer O erator � g La borer g -- Laborer o NOV-27 12!3/2007 : 6:06 PM through Nov- 28 CITY OF RIVERSIDE DAILY Page ' of 1 CONSTRUCTION REPORT 11/2612007 through 11/27/2007 Monday and Tuesday Project 116522 SEWER PIPELINE CAPACITY IMPROVEMENTS Stag BhOD Stop 5h00 Contractor Garcia Juarez Construction AM TrstTr Light PM Tie Lol Location La Cadena Dr., Spring Garden St, Columbia Ave. and Palmarita Ave. bVB8thor Clear Clou dY Rain Subcontractor Wind Still Moderate � High Inspector Anthony B. Allen (On duty 19h30 to 5ho0) Humid' rty Low Moderates High C0011NG �+1 AM Temp 30 PM Temp NUR WORK PERFORMED SO Line Item # 2 The Contractor removed the boring equipment from the pit and welded another 30' of the steel casing pipe in position. Line Item # 12 ' The Contractor began setting out the traffic control at 8h00. The freeway onramp was not closed this night. Traffic flowed - -..good. Lint !tem # 7 ;The Contractor removed the temporary AC. and continued he excavation of the trench for the 18" sewer line along E. L a Cadena from station 15+52 too 16+49.5 (thirteen joints of 7.5' . The trench was backfilled and compacted in layers. - -- ---.. - The Contractor a - - -pi ted_tem . - - - -- ------------r-------- porary_AC,-and-steeFPlates-overthe-trencti: The Plateswere a sin anchored down at the comers. - ----- - -- - ga a .. _ Compaction tests were run on the trench ----. area that had being compacted. A test was also done on manhole #1 but failed. -- - -. . -- -- - Significant Conversation: - --------- - The Contractor Provided certification for the welder and fla men.but_i! a -- -- ppears-not to be that which is - - -- - wired. ;Additional Equip. P+ — —-------- H Crane # 41852, Boring MT AFFIchin WeldingONTPlantetc, Lighting - ---- - COW -Traffic signals were set to flashing all red in the intersections affected by operations in ENTS: g Plants, J/D groom Tractor, 3 Pickups. order to crease a safer worsting environment EQUIP * DESCRIPTION HOURS 93 € _- PERSONNEL L18 - � Front End Pi Loader l 2 1Ru� Mendoza — _ EX13_ _ 1235 CAT Excavators 1 Lopez (Jaime _ __?417417----- ! 1-�er Dum -Truth -- -- Ascencio 8K59677 'Crew Cab ( 3 -David Flores - 4Z09112 'Flatbed Service Pickup_ Valdez 6X5343:4 U " Pkku l - U p. 1 IAddfo Pacheco -- 487189 I end U9htin Plant t 15� Urtel Rosa ' .- ;Ford Water Truck i 9 !Samuel P�scheLn ' 544E John 1 **Ramon Brisseno - - Deer Front End Coadcr SJ19884 10 Wheeler Dump Tnrdt 4 3► !Jesus Ordones R - . DC12 235 CAT Excavator/rvm„�.,....Jtlsus uez - pays Used vvemw Eiremi ' Extra Work Days I R-mlrtinp pays 11127/2007: 9:34 AM Nov -26 through Nov. 27 9 - 9 CITY OF RIVERSIDE DAILY gage 1 of 1 CONSTRUCTION REPORT 11/2512007 through 11126/2007 Sunday and Monday Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Start 8h00 Stop 4h00 Contractor Garcia Juarez Construction AM Traffi Light PM TlefliCl Ligh Localion La Cadena Dr., Spring Garden SL, Columbia Ave. and Palmarita Ave. WOHther Clear Cloud Y Rain Subcontractor W1nd Still Moderate High Inspector Anthony B. Allen (On duty 19h30 to 4h00) Humidity Low Moderate High CONTROLLING I" AM Temp 32 PIN Temp.I 53 NuusEit WORK PERFORMED Line Item # 2 The Contractor continued with the boring operation and the welding of the steel casing pipes. 64.Of casing has beingI placed. Line Item # 12 The Contractor began setting out the traffic control at 8h00. The freeway onramp was not closed this night. Traffic flowed good. Line Item # 7 The Contractor removed the temporary AC. and continued the excavation of the trench for the 18- sewertin _ e a_ long E. La Cadens from station 14+62 too 15+52 (twelve joints of 7.5). The trench was backfilled and compacted in layers. The Contractor placed temporary AC_ and steel plates over the trench_ The plates were again anchored down at the comers. .Significant Conversation:- ._.... The Contractor had being asked the first evening of night work for their fl ao rs cerb P20on. but until date it had not bel Upon receipYthis night of a correction notice, the Contractor rod - ' --' -- n9 received. produced certification but the Paperwork was incomplete in that there was not a signature against each and every name of the flaggers used on the project. The Inspector interviewed the new welder Elvin Uriel Rosa who also provided his San Bernardino certification. --- --- . Additional Equip. P+H Crane # 41852, Boring Machine, Welding plant eta, 3 Lighting plants--- J!D Broom Tractor, 3 pickups. Traffic signals were set to flashing all red in the intersections atTected bTRAFFIC operations COMMENTS _-- Y in order to create a safer --- working environment EQUIP C DESCRIPTION O for a g - - -- -- Welder HOURS BH 31 '31 OD John Deer Backhoe o Laborer L76 i5"H J/D Front End Pipe Loader s - Laborer g .. '235 CAT Excavator __---9817417__ 1DWheelerDump Truck ---- - - 8K59677 'Crew Cab Pickup -- 1 4ZO9112 _ flatbed S d FlatbeService Pickup 1 __ �-----_-- - --- 6X53434 'utility pickup -_'- 487189 ---- ingersoi Rand Lighting Ptah ---' — 1 --- WT -06 Ford Water Truck 9 - --- ---` 93 CLASSIFICATION en Mendoza HOURS i is_m t Foreman/ 9._._ - — -- --- --- — _ 1---- --Laborer---__ d Flores I e Valdez Laborer i _9 Uriel _ 544E John Deer Front -End Loader 4 r -- --- 5J19884 tOWheelerDumpTruck ;Jesus C = EX12 _235 CAT Exgvator/Com�aLyor-- Contract---- 9 & Days Used Weather —De�y Extra Work Days ---_- Total 11/27/2007: 9.15 AM Rernabdng Days 9 Nov.25 through Nov 26 - O for a g - - -- -- Welder 9 b o Laborer g s - Laborer g Rernabdng Days 9 Nov.25 through Nov 26 mrJ CITY OF RIVERSIDE DAILY Page I of I CONSTRUCTION REPORT 1210612007 through 12J0712007 Thursday and Friday Project 96522 SEWER PIPELINE CAPACITY IMPROVEMENTS Start 20hr00 Stop 00h30 Contractor Garcia Juarez Construction AM TrafficlLight PM TraLight Location La Cadena Dr-, Spring Garden St., Columbia Ave. and Palmarita Ave. W99171iar Clear Cloudy Rain Subcontractor Still Moderates High : Inspector Anthony B. Allen (On duty 19h30 to 00h30) Humidity Low ModerateHigh CONTRM14GTTEM AM TOMPJ 48 PM T9 NOWWR 52 WORK PERFORMED Line item # 12 The Contractor began setting out The traffic control at 8h00_ The freeway onramp was closed this night- Traffic flowed good - Line Item # 6 The Contractor temporary backfilled and compacted and placed t�rnporaryAC.Jn the trench 211 Columbia Ave- re aration for the coming rains- Some temp. AC_ Patchwork was also required and completed . �v ;�s a _p _bYjl�e ntractor- pc Line Item # 17 The Contractor placed the formwork, steel and cast the manhole #6 at 17+66-54' _.qr1E. La Cadina Ave placed the steel la. p Line Item # 3 The Contractor opened all the stormwater inlets, clear" them and Prepared the site for the cqmmnq !?ins. -Significant Conversation: - .Additional Equip- J/D Broom Tractor (5'h). J/Deer 5100 Back "Ge Compactor (11h). 10 Wheeler Dump Truck Traffic signals were set to flashing all red in the int TRAFM COWROL Coh%WMM # 41 (71<98157) (0h) ersections affected by operations in order to create a safer working environment. EQUIP# DESCRIPTION HO URS - 93 ------- BH 31 31 OD John Deer Backhoe 5 HOURS LIB 544tfJ/D Front End Pipe Load., Ruben Mendoza 5 5 CATxcavator 0man/OperalOr 1 Jests Lo— Laborer !Wheeler Dump T1,k ::Jaime Ascencie Laborer 5 _ElK59677 _ L; 'Crew David Flores Laborer 5 - 4209112 'FlatbedLaborer Service Pickup Gorge Valdez i 5 6X53434------------ .__�UtWlity Pickup I ----- !Adolfo Pacheco Operator 0 5 487189 'IrQersoi_ Rand Lighting Plant' Laborer Ford Water Truck 5 :Samuel Pacheco Laborer 1544E John Deer Front End LoaderOperator 0 -*Ramon Bri,Aseno 5 —A!198,84 10 Wheeler Dump Truck k Rosendo Alcaser I 0 — ---- "12 '235 CAT Excavelor/Compad, 0 best, R24qquez Laborer 0 -'Doug Brlow 5 Darn DvpUsedl Da" E xtra Work Dep Operator Operator 0 D&A Signature 12f712007: 7:46 AM Dec -6 through Dec, 7 CITY OF RIVERSIDE DAILY Page 1 of t CONSTRUCTION REPORT 1217/2007 ' Frida Contractor Hrs.: No Show Stop Project # 6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Contractor AM Traffic Contractor Traffic Light : Garda Juarez Construction Light PM T, Location Spring Garden St Weather Rainy i Subcontractor Wind Calm I InspectorArt Hernandez Da Shift: (On du ro_ :0800 to 1000h) HUmrdrty t Low j CONTROLLING OEM AM Temp 48F I PM Temp 56F NUMBER WORK PERFORMED Scattered rain through out the day, Contractor did not work today. I showed up and no workers were around the job site, drove around to check SWPPP conditions and observed along the sides of the curb and into drain system water running without obstructions, sand bags were in place as well. j NOTE: later in the day 1 got a call from Anthony Allen to let me know that contractor would not be worktn the rn ht Shift. j - TRAFFIC CONTROL COMMENTS: All streets o - ... -- -- ... _..._.. _ ._... pen to traffic -.J".Wm ArtH Diary 12-07-07 Page 1 of 1 Project Contractor Location Subcontractor Inspector CITY OF RIVERSIDE DAILY CONSTRUCTION REPORT 12/8/2007 Thursday Contractor Hrs.: Start 0830hrs Stop 1530hrs # 6522 SEWER PIPELINE CAPACITY IMPROVEMENTS - -- AM Traffic Light �PM Traffic j Light — Garcia Garcia Juarez Construction "------ - - Weather i Clear i Spring Garden St - I (Wind Calm ! Humidi _ Low I I Art Hernandez Da Shift: (On du : 0830 to 1530hrs. AM Temp 52F t'PM Temp 72F CONTROLLING ITEM � - --- --. _.. _ r . _ ... ----- - - NUMBER WORK PERFORMED 10 (a) Contractor excavated at the existing 4'_ wide trench to a depth of 4'- (+/- elev. 864.0) from Sta.1.1+75 to .13+00, rework and com _acted the native soil and had it rea for com action test --------._.._ .-- -- - p----- 9-q_ — - ----- JorcO--p---- ----------------------..._... fib) After compaction_ test were made, contractor back fill and compacted the soil usingthe Cat325 w/Sheepfoot-Rubber .wheels attachment I robed the recom acted area 11+75 to 13+00 on succesive liftas initial check and seemed _ .... � probed _ ecce table. LOR Geotw to rform com acat 1100hrs. _' -- -- -ech. Will be here tomorro-------p-- tion test ---------- -. Cont------ placed tem ra AC and clean u the work area t 100hrs._ LOR Geotechnical performed compadion test as foAow: Sta 11+20 = 93 % elev. 864.0 - — -- -- _ Sta 13+00 = 97% elev. 862.0 Today test were acceptable per plan. NOTES: -- ---- Find here attached LOR Geo. Reports _Photos taken, in file j1500hrs_Meet with City E - Daniel Simmons at Public Work Offices - TRAFFIC CONTROL COMMENTS. 0830hrs. Set up ConstructioNDetoursigns, 1430hrs. Completed removal of Construction/Detour Signs I. Dan I -..,....— I Dave I txaa yWJM Dz;B I Rwrwir-&Q Days I ArtH-Diary 12-06-07 CITY OF RIVERSIDE DAILY Page 1 of t CONSTRUCTION REPORT 12/05/2007 through 12/06/2007 Wednesday and Thursday Project 96522 SEWER PIPELINE CAPACITY IMPROVEMENTS Start 20h00 Slop Sh00 AM Trani Light PM TiafT Light Contractor Garcia Juarez Construction Weather I Clear Cloudy Rain Location La Cadena Dr., Spring Garden SL, Columbia Ave, and Palmarita Ave- Wlr)d Still Moderate: High Subcontractor midity � Low Moderate! High -- - Inspector Anthony B. Allen (On duty 19hHu 30 to Sh00) - -- AM Temp 28 PM cORTROLi-M not Temp I 50 NUMBER WORK PERFORMED V V Line Item tt 12 The Contractor began setting out the traffic control at 8hOO. The freeway onramp was closed this night. Traffic flowed good. Line Item # 6 The Contractor again had to remove the temporary AC, and backfill materials over a section of the trench. This time on line C, Columbia Ave. The top part of the trench was compacted to 83% while the bottom part was compacted to 93"6 (Cecked by LOR) Line Item # 17 The Contractor placed the formwork and cast the footing of manhole #6 at 17+65.54 on E. La Cadina Ave.. Line Item # 6 The Contractor excavated, placed and compacted 19 joints of 6' length, 12" diameter online C, Columbia Road up to 12+51. ,Significant Conversation:- Additional onversation:Additional Equip. J/D Broom Tractor. J/Deer 51 OC Back Hoe Compactor. 10 Wheeler Dump Truck # 41 (7K98157) TRAFFIC CONTROL COMMENT& Traffic signals were set to flashing all red in the intersections affected by operations in order to create a safer working environment. EQUIP >r DESCRIPTION HOURS 93 a PERSONNEL Flatted Service Pickup BH 31 310D John Deer Backhoe -----`-----------_-__-- 487189 CLASSIFICATION HOURS - WT -06 -- - -- B Ruben Mendoza Foreman/pperator 9 L16 544H J/D Front End Pipe Loader 2 =Jess u i - - EX13 ._.... .._ 235 CAT Excavator - — -- 2 -�-- - — J_aimeA_scencio Laborer � 9 __...- -- Dao. --10 Wheeler Dump Truck „ 1 Laborer9B774t7 ;David Flores 8K59677 - Crew Cab Pickup 1 4ZO9112 Flatted Service Pickup 6X53434 Utility Pickup_ _ 487189 _I _jersol_ a lighting plard - g - WT -06 -- Ford Water Truck - -- - ----- - 0 544E John Deer Front End Loader D 5,119884 10 Wheeler Dump Truck 1 EX12 -235 CAT Excavator/Compaclor p Contract Dap U..d Dao. I Exlr. Work Day. Total Pacheco Burlow Rwn*lbv Dep e Laborer 9 9 8 -- 9 9 9 i 9 - 0 12/7/2007: 7:45 AM Dec.5 through Dec. 6 Page I of I CITY OF RIVERSIDE DAILY CONSTRUCTION REPORT 1215t2007 Wensday Contractor Hrs.: Start 0030hrs Stop 11430hra Project 1116522, SEWER PIPELINE CAPACITY IMPROVEMENTS AM Traffic . I — . Light PM Traffic I Contractor Garcia Juarez Construction I.. . I : Light Weather Clear Location Spring Garden St .1 Subcontractor -- I Wind Calm Humidify Low Inspector Art Hernandez Day Shift: (On duty: 0830 to 1530hra.) ----------- — !PM 76F ; M Tamp 52F TO -P -------------------- —JA._ CONTROLLING ITEM F— NUMBER WORK PERFORMED 10 .0845hrs: Contractor, excavated at the existing 4'- wide trench to a depth of 4'- from Sta. 10+50 to 11 +45, rework and compacted the native soil and had it ready for compaction test. 11100hrs.: LORGeotechnical:" - Re -test compaction at 3 locations with the followinq results: ;Sta 10+50 97 % RC, Sta 11+00 = 95% RC, Sta 11+45 93% - R I C Today test was - . acceptable --" er - plan :NOTE: This was a "re-test"WITI since --p qcq test yesterdav 1150hrs.. Contractor continue the back fill and Wfoot attachment nt ,Iprobed the reco t-3- - 2 -5S -- � - - -h—ee-p 0-0- t Rubberbber wheel Itach e mpacted area 10+50 to 11+45 on succesive lifts as initial checkrand seemed acceptable. ------------------- LOR Geotech. Will be here tomorrow to perform compaction test at 11 00hrs. :Contractor placed tempgrairy P& and -qk�an up the work area :NOTES: - -- --(Operator Gonzalo Tapia denied information and work stop for about ten minutes till His identity and classification was I stablis-h-ed- for the record. here attached LOR Geo. Reports !Photos taken, in file 11 500hrs. Meet with City Eng. Daniel Simmons at Public Work Offices TRAFFIC CONTROL COMMENTS. 0830hrs. Set up Construction/Detour signs, 1430hrs- Completed removal of Construction/Detour Signs 93 EQUIP 0 DESCRIPTION HOURS F3 .. 5 11 0 - PERSONNEL I CLASSIFICATION HOURS I ton phi 6R uqy Navarez C1500 4man/O 6 --- 314 ton p/u . . . 6 I $Jesus Ordones labor/o6 310SE J.Deer / Backhoe Turbo 4X4 1 !Gonzalo Tapia 54 4 E J -Deer I Front Loader ope, 6 325 Cat I Excavator 3 325 Cat / Excav w/SheepLoot aftach,3 i — !Jeremy Gonzales LOR Geo, Soils Tech 3 Wr-,06 'Water hick 6 Days UsedI I Extra Work D8Y3 , 'Da 7 Today Remaining Days tH—Diary 12-05-07 CITY OF RIVERSIDE DAILY Page 1 of 1 CONSTRUCTION REPORT 12/04/2007 through 12/05/2007 Tuesday and Wednesday Project Start 20h00 Stop 5h00 1 #5522 SEWER PIPELINE CAPACITY IMPROVEMENTS f Contractor Garcia Juarez Construction AM Tref . Light PM Ti8fric Light Location La Cadena Dr., Spring Garden St, Columbia Ave. and Palmarita Ave. Clear ICloudy Rain Subcontractor w Still Moderate: High InspectorAnthony B. Allen (On duty 19h30 to 5h00) Humid/fy Low Moderate! High CONTROL W, rrEir - AM Temp 26 PMTemp-I 50 _ -Ta Tp- I WORK PERFORMED� V� Line Item # 12 The Contractor began setting out the traffic control at 8h00. The freeway onramp was closed this night. Traffic flowed good. Line llem # 8 The Contractor removed the temporary AC. and backfill materials over a section of the trench that was failing due to incorrect compaction. This area was re -worked and compacted and new temporary AC_ was again placed. Line Item # 17 The Contractor completed the excavation for manhole #6 at 17+66.54 and prepared d for the concrete pour of the footing. Line Item # 6 The Contractor excavated, placed and compacted 13 joints of 6' length, 12" diameter online C, Columbia Road up to 11+35 Significant Conversation:- — - ---- - The Contractor was notified at 23h00 on the 4th Dec that the excavation for manhole #6 exceeded the standard limits and that a solution was to be obtained before 3h00 on the 51h Dec, or the excavation would be required to be backfilled and compacted for traffic safety by 5h00. The Contractors solution was double steel plating in order not to exceed limitations. This was a_"Srey area" and the Contractor was notified that they were totally responsible for the public safety and 24 hour monitoring was required. ;Additional Equip. J/D Broom Tractor. J/Deer 5100 BaTRAFck Hoe Compactor. 10 Wheeler Dump Truck # 41 (71098157) Traffic signals were set to flashing all red in the intersections affected Comma CO►�iT& --set - -rias --- by operations in order to create a safer working environment EQUIP # DESCRIPTION HOURS - .310D John Deer Backhoe ' 6 L76 _ 544H J/D Front End Pipe Load ---- - Loader 2 -EX13 --- - 235 CAT Excavator I - - 2 sB17417ip Wheeler Dump Truck Laborer 8K59677 -- __- Crew Cab Pickup ---- — - -- _..... --- 1 jZ09112 Flatbed Service Pidwp --- -- 6X53434 . Utility Pickup 1 487189 )ng e.fsoI-Rand Lighting Plant g Ford WaterTnicc- --- 0 544E JohnDeer Front End Loader 0 5J19884 _ 10 Wheeler Dump Truck -- ___—EX12 '235 CAT Contras jdy _---total-- --� 12t712007: 7:44 AM 0 Dsys Used I Dave I edra Wak D," 91 PERSONNEL CLASSIFICATION iben Meridora -- — - - - -- --- -- - HOURS_. Foreman/Operator 9 sus LopezLabor— — i --- ime Ascerxio - ----- ---�— 9 9 - vid Flores - D Nuhez Pucheco 3dsserw xlriquez rkrw 0 Days Xw 9 _ - Operator I 9 _ Laborer 9 Laborer 9 Opera laborer 9 Laborer i 9 Operator 0 Signature Der -4 through Dec. 5 CITY OF RIVERSIDE DAILY Page 1 of 1 CONSTRUCTION REPORT 12/4/2007 Tuesday Contractor Hrs.: Start 0830hra Stop Project # 6522 SEWER PIPELINE CAPACITY IMPROVEMENTS --� AM Traffic; Light 1430hra ;PM Traffic Contractor Garcia Juarez Construction Light Location Spring Weather Clear Garden St - - Subcontractor Wind Calm Hurn dill Low Inspector Art Hernandez Day Shift-, On duty: 0830 to. 1430hra. coNmauNcrr>:MIAM Tem I 1 P 52F IPM Temp 77F NUMBER WORK PERFORMED 10 11100 hrs: Contractor began excavating at the existing 4'- wide trench to a depth of 4'- at 3 locations: Sla.10+50 jSla 11+00 and 11+75 to check the compaction of the trench soil which requires 90% RC for co _.nformance with approved plans. ;1200hrs: LOR Geotechnical performed compaction test at the 3 locations described above with the following results: 'Sta 10+50 = 88 % RC, -Sta 11+00 = 87% RC, Sla 11+75 = 86% RC Based in the unacceptable condition of the soil Contractor will open up the trenchtomorrow and wiB rework the area to -ring it under compliance -- " ---------- - -- NOTES: - The above work is remedial work as explained b Ci E - - "- - -" - - -- -- y .. tY_, Daniel Simmons -- - --- - - -- - 'LOR Geotechnical witl be here tomorrow at 1200hrs to perfom► Compaction T_ est_. - [Find here attached LOR Geo. Reports - - Photos taken, in file- • 1100hrs. City Eng. Daniel Simmons on site ----- - ---------------- TRAFFIC CONTROL COMMENTS: 0830hrs. Set up ConstructiorUDetour signs, 1430hrs. Completed removal of Construdion/Detour Signs EQUIP A DESCRIPTION I HOURS 93 t PERSONNEL -- - -- -->-- -- CLASSIFICATION I HOURS 8.5 'Rudy --- Navarro C1500 1314 torr p/u 4maN Ord— 6.5 -- _LJesus 3105E- -1 J, / g Turbo 4X4 lab _ 2 8.5 J. Deer Front Loader I _--------___--_-- Shwan Budrhome ILOR Geo. I --- 1 I Contract Days Used Weatt>ar r Extra Work Days Remaining Days _ _Today I Total r 12/4/2007: 7:42 PM ArtH-Diary 12-04_12-07-07 CITY OF RIVERSIDE DAILY Page 1 of 1 CONSTRUCTION REPORT 12/03/2007 through 1210412007 Monday and Tuesday Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Start 20h00 Stop�5h0-0 -- Contractor Garcia Juarez Construction AM T16, Light �PMTfaffr , LighCl t — Location la Cadens Dr., Spring Garden St, Columbia Ave WeSt/)9f 1 Clear Cloudy Rain and Palmarfta Ave. Vt9r)d Subcontractor _ still Moderate; High Inspector Anthony B -Allen (On duty 19h30 to Sh00) HIJTdity Low Moderate High CONTROLLM nu I AM Temr 25 l PM Te -41 45 NlA1BBt WORK PERFORMED ' �y Line Item # 12 ' The Contractor began setting out the traffic control at 8h00. The freeway onramp was closed this nigh. Traffic flowed good_ . Line Item # B The Contractor removed the temporary AC. and plates along E_ La Cadena Ave. and continued the excavation_ for the 18" line. The Contractor placed a 18' section plus two 2' sections of 18" diameter DIP Cs 1 sewer pipe up to 17 +64 Line Item # 17 The Contractor excavated for manhole 96 at 17+66,54 - Line Item # 6 The Contractor escavated, placed and compacted 7 joints of 6' length, 12" diameter on line C, Columbia Road. Significant Conversation:- - ----- ---- Jim Jackson had phoned the Inspector the previous afternoon trying to get him too sign for apparent extra worst done. The Inspector refered him tth o e contract that all apparent extra work undertaken by the Contractor without the approval of the City. was, is and will be unauthorized work. . The Inspector interviewed Se Valdez, Sergio .. z o Aerator ._ -- -- -- -- Additional Equip. J/D Broom Tractor. J/Deer 51 DC Bads Hoe Compactor. 10 Wheeler Dump Truck # 41 (7K98157) Traffic signals were set to flashing all red in the intersections affected FIC �� COn or _NTS: -----_—.-- by operations in order to create a safer working environment EQUIP # DESCRIPTION HOURS 93 BH 31 _...-- 310D John Deer Backhoe — 9 PERSONNEL - `.--- - -- - ---------_ `Ruben -CLASSIFICATION HOURS Mendoza -- L76 ! 44H J/D Front End Pipe Loader -* - F 9 - - - - - -- - - - -- -- LJesus Lopez -- EX13 -235 CAT Excavator 2 _ — baimeAscencio Laborer ; -- 9.. ------�— - - --j- - __ 9817417 10 Wheeler pump Truck - C David Flores 9 - 8K59677 --r-- -- Cab Pic k � 1 Laborer i 9 4Z09112 -- — Flatbed Service Pickup--- 1 -' — - ---- `Adolfo ' Laborer t 9 6X53434 ' lltiGty PIckup -- Pacheco - - --Operator ------- ------- 1 :Sergio Valdez - 487189 _ -- -' Inoersal Rangy Legnn g plant 9 Operator-- 9 -- WT 06 Ford Water Trude - _ISSamueb Pucheco Laborer - - --_-- D Ramon Brisseno - - _ .544E John DeerFront'End Loader 0 — motor 9 --- 5J19884 ;10 Wheeler pip Trkx;tk i (Jesus Ordones �borerI - -- E 35 CExa 10 `Jesus Rodriquez — Labor _.. ------2 D 9 121712007: 7.42 AM Dec -3 through Dec. 4 CITY OF RIVERSIDE DAILY Page 1 of 1 CONSTRUCTION REPORT 12/02/2007 through 1 210 312 0 0 7 Sunday and Monda Start 20ho0 y Project #8522 SEWER PIPELINE CAPACITY IMPROVEMENTS Stop 5h00 Contractor Garcia Juarez Construction `�M Tom. Lig' ht PM T!e/hClLigh�— Location La Cadena Dr., Spring Garden St, Columbia Ave. and Palmarita Ave. WBefher Clear Cloudy f Rain Subcontractor W;nd Stilt ,Moderate High Inspector Anthony B. Allen On d Humldity Low Moderate!- High duty 19h30 to Sh00) CONTROLLING rtnt I AM Temp 25 , PM- - . Tempa 45 WORK PERFORMED . - At approx. 7h00 the Contractor began replacing and repairing temporary AC on the project that was in poor condition_ Line Item # 12 -The Contractor began setting out the traffic control at 8h00. The freeway onramp was closed this night. Traffic flowed good The Contractor removed the temporaryAC_ and plates along E. La Cadena Ave: They then concrete under the telephone ducts. Proceeded to break and remove the The Contractor exposed a 6"steel water pipe crossing the trench diagonally 9 from station 17+42 too station 17+ 51. Line Item # 8 The Contractor placed two 18' lengths of 18' C diameter DIP s 1 sewer i fr - Pe om station 17+04 too station 17+40. 'Significant Conversation:- - --- The Contractor was issued a correction noticeto famish an -- - a roved traffic control plan for conditions had being changed. - _._ _.----- E. La Cadina Ave. as the site ;Additional Equip.J/D Broom Tractor. J/Deer 510C - - - ------ Back Hoe Compactor_------- __ Traffic signals were set to flashingall red in the int TRAFF� CONTROL COMMENTS ersections affected by operations in order to create a safer wonting environment EQUIP # - DESCRIPTION93 HOURS € BH 31 ;310D John Deer Backhoe - - -- PERSONNEL -_ ......_...-------- ----- � g ` ---- CLASSIF ICATION HOURS €Ruben Mendoza L16 t544H J/D Front End Pipe t oader ForemaN 2 EX13 - i235 CAT Excavator ' —'--L Laborer I 9 2 ;JaimeAscencio 9B17417 E 10 wheeler Dump TruckDavid La er bor g BK59677 Crew Cab Pidcu 1 Flores Laborer 4 12 Flatbed Service Pickup .Jorge Valdez _- ..-1_ lgdodo I Laborer I - 1 PacheOD -_ 6X53434 Utility Pickup-- 1 Operator D -- 487189 I i EdMdo Rodriquez -- -.-. --. _.. _ngersol-Rarid Lighting Plant q @ I taborer _ i SoTk e; F1rpleoo -- Vlrf 06 Fad Water Truck + Laborer D 0 - ---- onBrisseno €Ram 9 544E John Deer Front End Loader - - I 0 `Jesus !10 Operator ---.. 0 Ordones — SJ19884 Wheeler Dump Trude1 Laborer - X235 CAT Excavator/Corn 'Jesus Rod ' ez 0 I LaMxer I g - 9 Doug BurtetyOperator COrr6iaGt Days Used Extra Wyk Qsys0 RenMkft pet's — Slgnahrre 121712007: 7:41 AM Deal through Dec 3 CITY OF RIVERSIDE DAILY Page 1 °� 1 CONSTRUCTION REPORT 1213/2007 Contractor Hrs.: Monde Project # 6622 SEWER PIPELINE CAPACITY IMPROVEMENTS No Show Stop�— Contractor Garcia Juarez construction �AMTraffic ; Light PM Traffic - Light Location Spring Garden St Weather i Clear Subcontractor LMnd I j Calm I - Inspector Art Hernandez Day Shift: 0800 to 1000hrs.) Humidity ! Low I CONTROLLING ITEM I 'AM Temp 54F PM Temp 72F NUMBER WORK PERFORMED �0800hrs.: Met Anthony Allen with Caltrop and Daniel Simmon with City of Riverside Public Work Allen and Simmon filled me in with information regarding the work ahead, Simmon wilt ive me a set of laps b tommorrow (Contractor did not show up today, Allen met with the workers earlier and H+orlters said to him that the and was too mudd – plans y- tom morrow move equipment (Rain have occurred through the weekend) 1- - I TRAFFIC CONTROL COMMENT& EQUIP # DESCRIPTION 93 IO --- -- --- HOURS -- 12/10/2007: 8:21 PM Arti-_Dlary 12-03-07 5 Page t of CITY OF RIVERSIDE DAILY 1 CONSTRUCTION REPORT Project 416522 SEWER PIPELINE CAP AC" Contractor TY INiPRO� EMENTS Garcia Juarez Construction Location La Cadenza Dr. Spring Garden St, Columbia Ave. and Palma Subcontractor Rita Ave. Inspector Anthony B- Allen (On duty 19h30 to 0000) coNluatwc r1Etr: NUMBER WORK PERFORMED 1211312007 through 12114!20.7 Thursday and Friday Start 20h00 Stop 05h00 AM Traffic,Light PA/ Traffic Ligh�— Wseth_ er Clear Cloudy Rain W)nd -.-j j Still Moderate High Humidity Low Moderate - AM Temp I 39 High PM Temp j 42 2121 Line Item # 12 The Contractor began setting out the traffic control at 8h00. Line Item # 6 The Contractor excavated and Placed 9 joints of 12" pipe from 13+92 too ed 14+qg in Colum ' compacted and caped with temporary AC_ .- . ... ". _ bia Ave. The trench was backfilled and Line Item # 15 The Contractor stacked the n P9Sckfilled and compacted arround the manhole at stahon'11+ _. 0D - -- -- Columbia Ave. - - .The Contractor laid down water Burin _ 9 sweeping operations and kept dust to a - - - - minimum. ----- -- Significant Conversation:----.... --._ The Contractor" directed-- eP a dust to a minimun Buri -' the required limitations, the Contra-----�9 sweeping oPPerations_ If this n' Contractor was directed to replace the m - - —its - _ . ectfanical - - _ dust were not kept within _ _ _ b --- --.- - _ _ _...._ room with one that would_ Additional E ui -------.._. " -- 9 D J/D Broom Tractor (1h). J/Deer 510C Ba --"--""" -- --- Back Hoe Compactor ------- Traffic signals we (1h). 10 Wheeler Du _ 9 re set to flashing all red in the intersections affected tf COtriROl CO P Truck # 41 (7K9B1 0h) by operations in order to create a safer working environment EQUIP # -_ ... - DESCRIPTION93 ---__-_- HOURS BH 31 —iiiD Jon- Deer Backhoe - - Lt6 _544H J/D Front End Pipe Loader 0 `Ruben Mendoza -- CLASSIFICATION HOURS EX13 _235 CAT Excavates ---------0 = — `Jesus t Forema t 8 lain* Trck - _ Wheeler - Laborer 8 8K59677 --- Crew Cab PidkuP _ - - - - ---- - ---� 1 I�rge Valdez 4Z09112 Flatbed Service pupi borer 6X53434_ _ U61i PlrJku 1 jAddro Pacheco - Laborer 0 -- 487189 _tn %Ue'undro Nuhez 9ersol Rarfd�hong Plant perator B 9 WT -06 -Ford Water TrurJc iSamuel pub Laborer 0 —�_- —544EJohn Deer Front End Loader i — U Amon Brisse.o -- �_ B _-_ b 119884 1 D Wtfee►er pwfp Tnigk 2IRosendo tor e IX72 235 CAT Excavators 4 'Jesus R uez ' Latxxer �- - 0 9udow Lah?rer B Days Days Used I WeatKw D»yExtra Work s Sys �--- - _ forRemakfing Dap i Total -'—'-----_- + 12120/2007: 11:34 AM Dec, 13 through Dec_ 14.)ds CITY OF RIVERSIDE DAILY Page of CONSTRUCTION REPORT -4 Stop Stop Contractor I-Im Start la SI Project 6522, SEWER PIPELINE CAPACITY IMPROVEMENTSS Contractor AM Trma ffixc LL4(- i. I �phMf \rraff -rra: Ic .1 Location Garcia Juarez Construction ol Weather Subcontractor Wind Inspector Art HornandazHumidity Day Shift: 1 � �rC) CONTROLLM ITEM AM Temp IpM TaTp-'� NUMBER I WORK PERFORMED C_J 4-0 5 coo (-A (—NQ C-7 Cot 4—� Ta k All -I lyl- ( .77 t:-4�\ V7-c�C5T ---- ------ TRAFFIC CONTROL COMMENTS: EQUIP# DESCRIPTION i 93 HOURS I-Jk PERSONNEL CLASSIFICATION NJ -Z I HOURS' LJ� . .... Lf I -- L ;V-\Yj/ ncs" r> r,n Iry I Used Extra Work Days 1 Ren* uft Days - Today --------- !+ AnHDi,ry Line Item # 12 The Contractor began setting out the traffic control at 81100- .. ---- Line Item # 6 -The Contractor excavated and placed 3 joints of 12" pipe from 13+74 too 13+92 in Columbia Ave. T compacted and caped with temporary AC. Work --he.treneh w was slow das backfilled and ue to th-ree fiber optic and one normal cable ducts in the trench area. Line Item # 15 The Contractor cast the footing for the manhole at station 11+00 Columbia Ave_ Significant Conversation: -- e Contractor alleged a changed conditions for working around the o tical fiber cables on _ _ -p ---... -- ... _Columbia Ave_. Station 13+ 14+00. The Contractor has not met the conditions of the contract section 3 3.3, 3 4 80 too �vortc in terns of the contract section 3-5. _ 3 5 and 3 6 and is therefore unauthorized - _3-6 and 3-7_ � The __-- Contractor was issued a correction notice for trench shoringand _.. truck bed coverin of --- g -_-excavated materials loaded. Additional Equip. J/D Broom Tractor (1h)- J/Deer 51 DC Back Hoe Compactor (11 h). 10 Wheeler - Traffic signals were set to flashing all red in the ince TRAFFIC CONTROL COMMENTS �p T� # 41 (7K98157) (Dh) -- -- ---_-.--- rsections affected by operations in order to create a safer world environment nvironment. EQUIP # BH 31 CITY OF RIVERSIDE DAILY LID Page t of 1 CONSTRUCTION REPORT EX13 235 CAT Excavator 0.5 - _ -- 9817417iD 1 211 212 0 0 7 through 12/13/2007 Protect #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Wednesday and Thursday Start 20h^ 0- p Stop 041100 Contractor Garcia Juarez Construction All TraffiCLight PM T I'H/)-1C Light Location La Cadenza Dr., Spring Garden SL, Columbia Ave. and Palma W"th Clear - Cloudy Rain Subcontractor Rita Ave. wnd Still Moderate High Inspector Anthony B. Allen (On duty 19h30 to 04h00) HumrddY- I Low Moderate Nigh CORTROILING ITEM I NUMBER -544E John Deer Front End Loader AAI Temp 40 1 Tern- PM p ( 50 _10 WheelerDump Truck_ WORK PERFORMED ...._.. DC12 - - . �.. Line Item # 12 The Contractor began setting out the traffic control at 81100- .. ---- Line Item # 6 -The Contractor excavated and placed 3 joints of 12" pipe from 13+74 too 13+92 in Columbia Ave. T compacted and caped with temporary AC. Work --he.treneh w was slow das backfilled and ue to th-ree fiber optic and one normal cable ducts in the trench area. Line Item # 15 The Contractor cast the footing for the manhole at station 11+00 Columbia Ave_ Significant Conversation: -- e Contractor alleged a changed conditions for working around the o tical fiber cables on _ _ -p ---... -- ... _Columbia Ave_. Station 13+ 14+00. The Contractor has not met the conditions of the contract section 3 3.3, 3 4 80 too �vortc in terns of the contract section 3-5. _ 3 5 and 3 6 and is therefore unauthorized - _3-6 and 3-7_ � The __-- Contractor was issued a correction notice for trench shoringand _.. truck bed coverin of --- g -_-excavated materials loaded. Additional Equip. J/D Broom Tractor (1h)- J/Deer 51 DC Back Hoe Compactor (11 h). 10 Wheeler - Traffic signals were set to flashing all red in the ince TRAFFIC CONTROL COMMENTS �p T� # 41 (7K98157) (Dh) -- -- ---_-.--- rsections affected by operations in order to create a safer world environment nvironment. EQUIP # BH 31 - - 310D John Deer Backhoe LID `544H J1D Front End Pipe Loader i EX13 235 CAT Excavator 0.5 - _ -- 9817417iD ._.. --- - Wt.--tefpu Tom_ 0 i 8K59677 Craw Cab Pickup - - TFlatbed �- 4 ' 1 4ZO9112 - - Service Pick_ UD - --- --- 1 - 487189 In9ersol Rand Ling O WT-06 — - Ford WaterTnlec 9 - - 0 -- -544E John Deer Front End Loader SJ19884 _10 WheelerDump Truck_ 2 ...._.. DC12 - - 235 CAT Excavator/Compactor - —_— Reye Used ( tN►r'lher -- Days Exna Wbrk flays + 1 2 /2012 0 07: 11:32 AM 93 Remakft Days �ntc CLASSIFICATION HOURS F � 8 Laborer 8 - Laborer � 8 rLabm k a Laborer o Laborer a Operator 8 Laborer -0 - - Laborer i - e _ _ Operator ' 0 — 2-i" Signahrre Der -12 through Dec. 13 -xis CITY OF RIVERSIDE DAILY Page of CONSTRUCTION REPORT Project # 6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Start G Stop 13G Contractor Garcia Juarez Conatruetlon AM Traffic (_� <--- • '-pM TrafTie Ly.[li_T Location La Cadena Dr. Spring Garden 8L Columbla Ave. and Palmarita Ave, WaaMer �- Subcontractor Wind C r_- ,_l Inspector Art Hemandez Day Shift: 0890 to 1530hrs. OT: NUMBER Humidity i—(�{ CONTROLLING nFM- AM Temp WORK PERFORMED Tem P / , I► r -:4 _ ' N,1 VA-Cccr- -- -- -- r -----�_- '� �-tet(—�`•.� � �'i � F k,�__ � - n TRAFFIC CONTROL COMMENTS: EQu1Rit DF�Fa��rx�u 93 .TAT Contract --W eaftw Dae Days used ° Extra Work — ---- - D 's Exba � : Remainim Days -- .._.---------- Total--- 12Ia/2007 : 8:D3 PM luo Artt-i_Dailyl2-407 CITY OF RIVERSIDE DAILY Page t of , CONSTRUCTION REPORT 12/11/2007 through 12/12/2007 Tuesday and Wednesday Project 16522 SEWER PIPELINE CAPACITY IMPROVEMENTS Start 20h00 rte__ - Slop 05h00 Contraclor Garcia Juarez Construction AM TiefhCLight PM Tf e� Light Location La Ca [Iona Dr., Spring Garden SL, Columbia Ave. and Palmarita Ave. weal r Clear Cloudy Rain Subcontractor YVlnd Still Moderate High Inspector Anthony B. Allen (On duty 19h30 to 05h00)Humid �Y Low Moderate: High coNmata+c riErr l AM TemP1 40 PM 50 Temp ( NUUBrIt j WORK PERFORMED Line Item # 12 The Contractor began setting Out the traffic control at 81,00. - ' Line Item # 6 The Contractor excavated- and- placed joints of 12" i -- P Pe from 13+50 too 13+74 in Cohxnbia Ave. The trench was backfilled and compacted and caped with temporary AC. Line --- Item # 15 The Contractor excavated for the manhole at station 11+ 00 Columbia Ave. --- Signifcant Conversation:- The Contractor was asked to provide theene_grne.9 drawings to show --- - - _ --- - that the ales s snot - - -_vas engineering sound and safe. - - - -P the..exeavatton at station 11+00 . _. The Contractor could not provide such drav togs and was therefore to immediately make the site safe. ' - - -- ontiissued a correction notice .Additional Equip. J/D Broom Tractor (5h). JlDeer 510C Bade HCompactor- — - -- - Traffic signals were set to flash' TRAFF)e CONTROL CS: . 10 Wheeler Dump _-.._ . .. - flashing all red in the intersecpons a P TNS # 41 (7K98157) (5h) - affected by operations in order to create a safer working environment. EQUIP # DESCRIPTnu 93 - _ BH 31 .310D John peer 13adch g---- ---544! J/D Front End Pik _ DC13 235 CAT Excavator - 9817417 _ '10 Wheeler Dump Truc _ 8K59677- _Crew Cab Jk!Lr - - 4209112 - Flatbed Service Pidru ---15343' -- -UWit PiPickup - - - 487189 - ingersol Rand Lighting F -WT-06 -Ford WaterTrudr :Samuel Pucheco 544E John Deer Front Ei --5J19884 10 Wheeler Dum.+Truck -- _IX12 235 CAT &(H!! tor/Com _ . _., Day& Used ! TT - - --- - 12/20/2007: 11:31 AM !Jesus -0 i Forernary for g---- :`JaimeAscencio Laborer 9 € David Flares taborer 9 Gorge Valdez Laborer - - 9- - 'Ad°tr° Pacheco taborer (Alejandro Nuhez motor 9 :Samuel Pucheco Lebow _-- 0 -- :`RamonBrLsserm Laborer 9 'RosendoAlcaser O for 9 - `Jesus Rodiquez 0 1thug Burton Laborer -�-9 -- I Rwrraininp p� { Operator n - Der11 through Dec. 12x1s CITY OF RIVERSIDE DAILY CONSTRUCTION REPORT 12/12f2007 Wensda Project Contractor Hrs.: Start 0830hrs q 6522, SEWER PIPELINE CAPACITY IMPROVEMENTS Stop 1530hrs Contractor AM Traffic_ g Garcia Juarez Construction - _ Light PM Traffic Light Location Spring Garden St f La Cadena Weather AM Clear Subcontractor Weather i PM Clear Inspector Art Hernandez Day Shift: (On duty_ 0830 to 1530hrs.) Humidify I Low I CONTROLLING ITEM AM Tamp 48F PM Temp ! 64F NUMBER WORK PERFORMED 10 La Cadena a) Contractor set Up signs and have two man doing flagging r b) Contractor excavated the trench between 11+50 to 12+56, Eft down to +/- elev. I probbed the next few lifts as the back fill went up and fo864.57 and began recompacting, und the compaction consistent with previous work. Contractor placed.. temp AC to cover the trench and clean up around the work area (Contractor laced tem AC to cover the trench and clean u around the work area P p _. - - - - NOTES: ---- ---- - 12-Photos taken, in file - 13 1400hrs_ Daniel Sim mon Liv. PW Eng, on site, I informed Daniel of the work in progress. 4-Learned from Anthony Alen that concrete sections for Man Holes need_ t_o_be.dated_for November 2007 (and onwards) :to be accepted, Sections dated before November are not acceptable — TRFit�rn ROC eonnwty7s;'- 0830hrs. Set up Construction/Detour signs, 1515hrs. Completed removal of Construction/Detour Signs ------------ - -EQUIP it ' DESCRIPTION 93 - - - HOURS iPERSONNEL - F350 1 ton plu ¢ CLASSIFICATIONH.URS - 7 Rudy Navarez --- r C1500 314 ton p/u ' _ 4mallope I 7 7 €Jesus Ordones - 3105E J.Deer / Backhoe Turbo 4X4 t--- -- i lab - 2 Cesar Ulises - _-- . IJ.Deer/Front Loader 2 _ ope. I 7 ' IAIe'andro Nunez f 235 Cat/ Excavator € -- -- _. lab - - - - _ 2 Cat/ —Excav_ySheepfoot attach, S 2 - - - --- _-- , ----- -- --- -- - ---- WT-06 Water truck -- -- .. _ -_----------- \I Days Used WeRier - Days II Da Exira Work DaysD _�-_'-- --- -- i Rtemainf Signature � ArtH_Diary 12-12-07xis Page Project Contractor Location Subcontractor CITY OF RIVERSIDE DAILY 101`1 --- CONSTRUCTION REPORT 12111/2007 Contractor Hrs.: Tuoada # 6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Start 0830hra Stop 1530hrs AM Tra/fic i Light TralTic Light Garcla Juarez Construction pring Garden St / La Cadena �WBather Weather Inspector Art Hernandez Da Shift: On du Humidify Day ( : 0830 to 1530hrs.) CONTROLLING ITEM I AM Temp NUMBER ; WORK PERFORMED 10 �La Cadena AM Partly Clouded PM Clear Low I 46F !PM Tamp I 50F Contractor excavated the trench between 10+50 to 11+50 down to +/_ elev. 863.90 and began recompacting I probbed the next few lifts as the back fill went up. LOR geo tech Performed a compaction test aL' Pe .- - 10+75 = >90% elev_ 865.75 (which was acceptable.) P - ISPrIng Garden St - LOR geo tech performed a compaction test at 90% elev. 867.59 (which was acceptable ) Contractor placed te mp AC to cover the trench and clean u around the work area - ----- NOTES: -- ---------...-___-------- 11-Find -----1 Find here attached LOR - -- 12 Photos taken, in file --- - - -`- 3 1400hrs. Daniel Simmon (R. PW En on site, 1 informed Daniel of -"work in Drogress. -_..- - �4 Learned from Anthon Allen that concrete sections for Man Holes need to be dated for November 2007 (and onwards) ----- – --- ------ -- ito be accepted, Sections dated before November are not acceptable - — --_--- -- -- TRAFFIC CONTROL COMMENTS: 0830hrs. Set up Construction/ Detour signs, 1515hrs- Completed removal of Construction/Detc ur Signs DESCRIPTION 93 F350 I HOURS t PERSONNEL I CLASSIFICATION I HOURS —__ __ , 1 ton!u —_ C1500 314 ton tR Navarez 7 Jesus Ordones 4man/o 7 310SE J.Deer! Backhoe Turbo 4X4 2 labor/o T r Cesar Ulises 544E J -Deer / Front Loader 2 0 T _ 235 Cat / Excavator 2 !Sbwan Buckhome/ LOR GeolecA_ ---- 235 _ i Cat / Excav w/Sh fold attach, 2 ( Sona Tech 1.5 --�-� lWatertrudc ; . ArtH_Diary 12-11-07 Page 1 of 1 CITY OF RIVERSIDE DAILY CONSTRUCTION REPORT Project 96522 SEWER PIPELINE CAPACITY IMPROVEMENTS Contractor Garcia Juarez Construction Location La Cadena Dr_, Spring Garden SL, Columbia Ave. and Palmarita Ave. Subcontractor Inspector Anthony B. Allen (On duty 19h30 to 05h00) coNNOLLNc nFN I Nuu9ER WORK PERFORMED 12/1012007 through 12/11/2007 Monday and Tuesday Start 20h00 Stop 05h00 AM Traffic_ Light PM TrafficLight Weather ; Clear Cloudy Rain Wind f Still Moderate High Humidity Low Moderate High AM Tempi 42 PM. Temp 52 Line Item # 12 The Contractor began setting out the traffic control at 8h00. The freeway onramp was not closed this night. Traffic flowed good_ Line Item # 6 The Contractor excavated and Placed 16 joints of 12" pipe from 12+51 too 13+50 in Columbia Ave. The trench was backfilled and compacted and caped with temporary AC_ - - - ---- - Line Item # 17 The Contractor removed part of the formwork and backfilled the manhole #6 at 17+66.54 on E. La Cadina Ave_ Line Item # 3 The Contractor re-sel the storm water inlets. Significant Conversation:- --_ - ----- -- - e Contractor was reminded to work very - careful arround the fibre-optic tine in Columbia Ave_ - - - -- - - -- --- - - - - . .Additional Equip. JID Broom Tractor (5h). JlDeer 510C Back Hoe Compactor (th)_ 10 Wheeler Dump Truck # 41 (7)(98157) (5h TRAFFIC CONTROL COM,AENT& ) Traffic signals were set to flashing all red in the intersections affected by operations in order to create a safer working environment EQUIP At _ _ - _- DESCRIPTION HOURS 93 — BH 31 31 OD John Deer Backhoe 3 :'Ru - L16 544H JID Front End Pipe Loader ------- -3 -_ iJesus - EX13 235 CAT Excavator — 5 r !Jaime _9617417 '10 Wheeler Dump Tnxh 5 ! David 8K59677 CrewCab Pickup- 1 r ':Gorge - 4ZO9112 : Flatbed SeNce Pickup 1 Adolfo - 6X53434 Utility Pickup 1 iql _ — 487189 Ingersol-Rand Lighting Plant 9 `Sam -- WT -06 -- Ford water Tnrck 0 Rm aon _-- _ - 544E John Deer Fnxrt End Loader 5 ;Rosend --5J19884 10 Wheeler Dump Truk 5 9 — IX12 ,235 CAT Exp vator/Compactor 5 —!Jesus `Do Laborer .. D8y6 (139d ! (a i -- --- --Mum -- T --L - !+ + _ Total _- PERSONNEL-- ben eprndro uelPucheco Burlow CLASSIFICATION HOURS Mendoza Forema g Ascencio 9 ' Laborer g Flores Laborer 9 Valdez -- — -_ Laborer a Pacheco - Operafor 9 Nubez LaDorar - 0 Laborer 9 Brisseno Operator 9 o Al aser Laborer 0 Rodriquez - Laborer9 -- -- Operator p -- RernaWng Des ___1 - 12120/2007: 11:30 AM Dec -10 through Dec 11 xis CITY OF RIVERSIDE DAILY Page ' °r' CONSTRUCTION REPORT 1211012007 Monde Contractor Hrs.: Project # 6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Start 0830hra Stop 1510hr: Contractor Garcia JuarezConstnrctlon AM Traffic I Light PM TralBc Light Location Spring Garden St weather Clear wind Subcontractor Calm I Inspector Art Hernandez Da Shift: (On duty: 0830 to 1530hra.) Humidity Low CONTROLLING ITEM rnSAM Temp I 48F IPM Temp 58F I NUMBER I WORK PERFORMED � 10 ;a) Contractor opened the existing 4'- wide trench to a depth of 4'- ( +/_ elev. 864-0) from Sta.14+00 to 115+38 and recompacted the soil +/_ 2ft above the 24" VCP, Also opened up the trench at 13+10 to test the last lift Irequiring90 /° com action, After compaction test were made the trench was backfill and recompacted, I probed th P .. _. ifew lifts, LOR Geotech will be here tomorrow to -- - _ perform Com action test e ne Contractor placed temporary AC and clean up the work area LOR Geotechnical rformed compaction test as follow pe performed -- - - f4+$0 = 92°% elev_ 864.0 13+10 = 93% elev. 866.0 14+10 = 97% elev. 865.0 This test was rformed 2ft East of existin Gas line-------- - ------ - - -- — ---- ----- - --) - -- NOTES: - ._. here attached LOR Geo: Repo ----- ----------------rts - _ Photos taken, in file - -- ---- ----- 0830hrs. Set up Consb-- TRAFFIC CONTROL_ COMMENTS: - yction/Detour signs 1510hrs_ Completed removal of Construction/Detour Signs --- -- ArtH Diary 12-10-07 CITY OF RIVERSIDE DAILY Page 1 of 1 CONSTRUCTION REPORT 12J09/2007 through 12/1012007 Sunday and Monday Project A6522 SEWER PIPELINE CAPACITY IMPROVEMENTS __. Start'19M5 — Stop 20hr 30 — Contractor Garcia Juarez Construction AMT 11!q;Light- PM Tr8/fic:Light Location La Cadena Dr., Spring Garden St, Columbia Ave. and Palmarita Ave. Weser Clear Cloudy Rain Subcontractor Wind Still Moderate: High Inspector Anthony B- Allen (On duty 19h30 to 20h30) Hum�drty ._ Low Moderate; High cc«laouNcrlF►rl AM_Temp �— 48__ PM Tempi rrur52 DER WORK PERFORMED - - The Contractor came on site and requested a rain d --- - - - - .__._..... ----- -ay _ue to mud conditionds- - Significant Conversation:- - The Ins or acini !aged the conditions but told the Contractor that the :neer would make the final decision. -- — A rain day was granted. - - - --- EQUIP * -- DESCRIPTION — BH 31 310D John Deer Backhoe -- L16 _ 54gH J/D Front End Pipe Loader EX13 --- 235 CAT Excavator 912117417 1D WheeleLDump_T[uck__ i BK59677 Crew Cab Pickup i• _ 4Z09112 Flatbed Service yup 6X53434 Utifity Pickup 487189 lrgersot.Rand Lighting Plant WT -06 :Foch WaOerTllk - 544E John Deer Front End t.oader - 5J19884 10 Wheeler Dump Truck 0X12 235 CAT Excavator/Compactor Dancontract Day. Used 12/20/2007: 11:28 AM TRAFFIC CONTROL COMMENTS. - 93 1 `Gorge Valdez 0 ta.+.dfn.,. -- 0 0 `Jesus Rodriquez --_-Doug Burlow Extra Work p Rem � 1 0 O 0--- 0 0 0 0- 0 0 0 Signature Dec -9 through Dec, 10.x1s age 1 of CITY OF RIVERSIDE DAILY P 1 CONSTRUCTION REPORT 1212012007 through 12/21f2007 Project 06522 SEWER PIPELINE CAPACITY IMPROVEMENTS Thursday and Friday Contractor Start 20h00 Garcia Juarez Construction Stop 02hpp AM TrafyC,1U ht Location La Cadenza Dr_ S t. g PM TrB/i5� Light pring Garden SL, Columbia Ave_ and Palma Rita Ave. "DfAer I Clear Cloud Subcontractor _. y Rain ��______ Still Moderate Inspector Anthony B. Allen (On duty 19h30 to 02h00) High HumidJty Low Moderate. coNlNotcx+o nt-st I High NuueFlt AM Temp 35 PM Temp! 39 WORK PERFORMED Line Item # 12 The Contractor began setting out [be traffic control at 8h0o Line Item # 6 The Contractor excavated for one 6' joint of Pipe and stacked the manhole at trench P station 15+10 in Columbia Ave. The manhole and was backfilled, compacted and caped with temp- AC. During the excavation the Contractor uncovered a and Placing2" steel duct that was not on the Plans a more pipe. The rain was affecting the trench work also as it b P � chose not to continue excavation became heavier around 23h00. Significant Conversation: - The Contractor wanted the Inspector to direct their operation as pertaining to the 2" steel duct - Additional Equip. J/D Broom Tract 11r�:OL ctor (1 h). J/peer 51 - OC Back Hoe Com pastor (1h). 10 Wheeler _.._._ Traffic signals were set to Bashi an TRAFFIC CO -` Bashing red in the intersections affected b COMMENTS. Dump Truck * 41 (7K98157) (Oh) _ y operations in order to create a safer working environment. EQUIP # DESCRIPTION 93 - HOURS BH 31 - --. e 310D John Deer Backhoe - :------_--- PERSONNEL - -- -- CLASSIFICATION Lis 544H J/D Front End Pipe Loader --- B --- --. HOURS €Ruben Mendoza - EX13 235 CAT Excavator �- -.-- `esus Lopez Foreman/ - g 9817417 (Jai--mA�encio Laborer - - - 70 Wheeler D1rm -- - g ...- - -- - - - -- -- - - ---- - - Laborer 8K59677 --- _ `David Flores crew Cab Pkkup _�� - - -- - - ab 4409112 -- - �Gerge•4ektez - _- Flatbed Service Pickup --'' - - _ B 6X53434 Utlrdy Pidcu - Adotfo Pacheco -- -_- -p _ 487189 �n9e+" Rand - -1 uIOr L ghbng Plant N- -8 WT O6 _Ford Water Trude - --_-6- (Sa.W Pacheco Laborer 0 - -- _.RamonBrls Laborer 544E John Deer Front End -- O ---Loader. 5J198t34 10 Wheeler Dump Track 1 glcase -235 CA-- T-Exca�ratodCompactor -' � Jesus_..-- Rodriguez _ --� i Labprer o - Gontract�T-- - --_ 0 €g Bud6w ' Laborer D ! 0.ys UW I 1Meatlrer I O 8 - Days - ... _ - -_-_Days I Extra Wort Days r �a �► 0 v i ---TMS ---- -- --- -- - 12121/2007: 9:43 AM Def -20 through Der- 21.rds Line Item # 12 The Contractor began setting out the traffic control at 81100. Line Item # 6 The Contractor excavated, shaped and placed the footing for the manhole at station 15+10 in Columbia Ave. _ The Contractor worked on the erosion control, drop inlets etc. in preparation for rain_ Significant Conversation: - Additional Equip. J/D Broom Tractor (1h). J/Deer 5100------ - Back Hoe Compactor (Oh). 10 Wheeler Dump Truck # 41 (7K981 Traffic signals were set to flashing all red -in the intersections affected CONTROL CORS, NTS 57) (Oh)-- - - ------ — _ ___ Nected by operations in order to create a safer working environment. EQUIP # CITY OF RIVERSIDE DAILY - _ BH 31 Page t or , CONSTRUCTION REPORT L18--- �544H J/D Front End Piee Loader_.- 6- -- _. - EX13 12/1912007 through 12/20/2007 Project #6522 S EWER PIPELINE CAPACITY IMPROVEMENTS Wednesday and Thursday Start 20h 00 Slop 02h0o Contractor Garcia Juarez Construction AM Traffic' Li ht7 9 - PM Traffic Light Location Subcontractor La Cadenza Dr., Spring Garden SL, Columbia Ave. and Palma Rita Ave. weather Clear _Cloudy Rain Inspector Anthony B. Allen (On duty 19h3o to 05h00) Wind Stilt Hu I LOW Moderate High Moderate, COHmDu� ITE' r+uueEa _.... WT O6 AM To To I 35 High PM Temp 40 mon-Brieaen�- WORK PERFORMED _ SJ19884- Line Item # 12 The Contractor began setting out the traffic control at 81100. Line Item # 6 The Contractor excavated, shaped and placed the footing for the manhole at station 15+10 in Columbia Ave. _ The Contractor worked on the erosion control, drop inlets etc. in preparation for rain_ Significant Conversation: - Additional Equip. J/D Broom Tractor (1h). J/Deer 5100------ - Back Hoe Compactor (Oh). 10 Wheeler Dump Truck # 41 (7K981 Traffic signals were set to flashing all red -in the intersections affected CONTROL CORS, NTS 57) (Oh)-- - - ------ — _ ___ Nected by operations in order to create a safer working environment. EQUIP # DESCRIPTION - _ BH 31 _ 310D John peer g�W HOURS - -- - L18--- �544H J/D Front End Piee Loader_.- 6- -- _. - EX13 _ 235 CAT Excavator_ _ - _ _.. �-- - - • - _ 9817417 10-- —Wheeler Dump 0 _ 8K59677 -Truck - _ Crew Cab 8 4Z09112 - _FIa - thed Service pickup --- 6X53434. -Utility P"----__-�_.--- 0 487189 LightirxJ Pint- 6— -0 -- _.... WT O6 --- Ford `Nater Tr.* - -- -- - mon-Brieaen�- 544EJohn Deer Front End---- Loader _ SJ19884- ------ 10 Wheeler Du-pn Truck .. _ IX12 _ 235 CAT E-avator/Comnarsry 0 _ -- TOW 12/20/2007: 11:50 AM t)eys "62' -- Extra Werk Ddyo Usd- I -- - Ab 93 - _._. PERSONNEL _ . "-- - uben Mendoza CLASSIFICAT)ON HS OUR _ sk>aLopez Fo _erator e e Ascencio taborerIm - -- ' rvid-Flores-- Laborer __--------- 8 xge-'rlatdpi Laborer- PachecoLaborer 0 qundro-Nuhea- ratio - 8 _ - Prrrheco-- Laborer F 0 mon-Brieaen�- - - - rerWaAkaser Operator - 0 - Laborer 0 Laborer - e _ tDr 0 RSD nW, i Dec- 18 through Dec. 19 rev..xjs CITY O RIVER31DE DAILY Page 1 of 1 CONSTRUCTION REPORT SP►Ing Gardens St. 14 a) Contractor installed Manhole # 4 backfill and recompacted ib) Backfill and recompacted Manhole # 3 14 E. La Cadena - (Backfill and recompacted Manhole # 2 i .. NOTES: - 11- Steel plates were removed from the intersection of E. La Cadena and Spring Garden St 2- 1445hrs. D. Simmons (Riv. PW En on site, we talked about the upcoming N test for the Sewer Line 3 Photos taken in file ........... WPPP Drove around and checked condition of Drain inlets and found in corn liance at this time. - - - - -- - Contractor was asked to rovide better u kee of the work area, field foreman stated He'll do his best --- --- 0800hrs Installed - TRAFFIC CONTROL COMMENTS — ---- construction signs, 1530hrs- Construction signs were removed - ---------- EQUIP S _. _' DESCRIPTION k 93 - --^ ----.--: --HOURS 7 --� -- 0 -3/4 ton/amu— :RAN' 7 Jesus C Deer/ Backhoe Turbo 4X4 - -1— _.. - --- 544E—Cesar U !J -Deer/ Front Loader - ' Cat / Excavator —` i 235 Cat / Excav w/S foot attach, - - ----- WT -06 Water truck -- -- -----NOTE_---- --- tract Dan Days Used : DWem"IffExtra Work Days - - - - — - - —= - --- Remalni;V Days Total - - + _ + - 4mardo ---7 - -lab - 12/20/2007 Project Contractor Contractor Hrs.: # 6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Thursda Start 0800hrs. Stop 1530hrs. Garcia Juarez Construction Traffic Normal Location Subcontractor S tin Garden St. E. La Cadena Weather AM: Light drizzle - Cloudy Inspector Art Hernandez Day Shift: (On duty: 0700 to Weather Humidity PM_ Cloudy Low coRTRarn+crr�i NUMBER 1530hrs_) AM Temp qgF 'PM Temp , 64F WORK PERFORMED SP►Ing Gardens St. 14 a) Contractor installed Manhole # 4 backfill and recompacted ib) Backfill and recompacted Manhole # 3 14 E. La Cadena - (Backfill and recompacted Manhole # 2 i .. NOTES: - 11- Steel plates were removed from the intersection of E. La Cadena and Spring Garden St 2- 1445hrs. D. Simmons (Riv. PW En on site, we talked about the upcoming N test for the Sewer Line 3 Photos taken in file ........... WPPP Drove around and checked condition of Drain inlets and found in corn liance at this time. - - - - -- - Contractor was asked to rovide better u kee of the work area, field foreman stated He'll do his best --- --- 0800hrs Installed - TRAFFIC CONTROL COMMENTS — ---- construction signs, 1530hrs- Construction signs were removed - ---------- EQUIP S _. _' DESCRIPTION k 93 - --^ ----.--: --HOURS 7 --� -- 0 -3/4 ton/amu— :RAN' 7 Jesus C Deer/ Backhoe Turbo 4X4 - -1— _.. - --- 544E—Cesar U !J -Deer/ Front Loader - ' Cat / Excavator —` i 235 Cat / Excav w/S foot attach, - - ----- WT -06 Water truck -- -- -----NOTE_---- --- tract Dan Days Used : DWem"IffExtra Work Days - - - - — - - —= - --- Remalni;V Days Total - - + _ + - 4mardo ---7 - -lab - 1 --7 -- -------------- 7 _ SignaWre AI_Diary 12-20-07 CITY OF RIVERSIDE WAILY Page 1 of 1 CONSTRUCTION REPORT 12/18/2007 through 12/19/2007 Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Tuesday and Wednesday Start 20h00 -�- Stop 21h00 Contractor Garcia Juarez Construction AM T/81fi Light PM Tib IfiC. Light Location Subcontractor La Cadenza Dr_, Spring Garden St ,Columbia Ave. and Palma Rita Ave. we8a1B! Clear Cloudy Rain Inspector Anthony B_ Allen (On duty 19h30 to 21 h00) Wind_ I Still Humidity I Low Moderate _ High � Moderate. Cc"TRM"ID'' I _.. _ _ p - -- AM Temp I 40 High Nt>yBEA 9617417 1D -- WheelerDum T 0 ---- - ---.-- - PM Temp 1 45 - Laborer ° WORK PERFORMED -:David _8K59677 CrewCaDPickup. ------�-- The Contractor was granted a rain night_ Significant Conversation: - Additional Equip. J1D Broom Tractor (1h)- J/Deer 5100 Back Hoe Compactor (0h). 10 Wheeler Dump Truck t 41 (7K9815 Oh TRAFFIC CONTROL COMMENrg 7) ( ) EQUIP S DESCRIPTION 93 BH 31PERSONNEL 31 OD John Deer Backhoe HOURS IF►CATK)N-`HORS - --- _. L18 544H J/D Front End Pipe Loader ---- - '- - :Ruben- r. __. -- ----- - — ---F - EX13 235 CAT Excavator _.. _ _ p - -- _.- €Jesus Lopez - --�- - 9617417 1D -- WheelerDum T 0 ---- - ---.-- - _'JaimeAscena0----------- --- _ - Laborer ° 0- -:David _8K59677 CrewCaDPickup. ------�-- __- Flores -_.. __ ___ _ borer -=_------�-- �_,_----- 4ZO9112 Flatbed Service pick -- - - - - 1 - `Go a Valdez -..!9 Laborer 0 - --- --- 6X53434 - Utility Pickup --- _--- = --- - jgdolfo Pacheco ----- - Laborer —�._-D _ . 487189 IngersW {Z�d -. -- - 0 �Atejundro Nuhez Operator 0 - ---- . Ford Water Truck ----- -, __- SamuelPurheco = - -- -- laborer -�-- _0-- - -- .. - --- 544E John Deer Front End Loader U - -- `Ramon Brisseno --- Later 0 5J19884 -.. 10 Wheeler Dump Truk D - --_ ---- Roserxlu-Algser- - - -- --------- Operator 0 -- -- _ IX12 -- 235 CAT Excavator/Compac2pr-- - U -- -- tJesus R - i - °��------- Laborer t 0 --- Dan 1 Days Used Weattker DougBurtow--------- -�_------ Laborer - Operator U -mss_ - _ Extra Watk Daysk ---_ 0 -- T Tom_`_—i-----------; 12120/2007: 11-58 AM Dada through Dec. 19-4s CITY OF RIVERSIDE DAILY Mage 1 of 1 CONSTRUCTION REPORT 12119/2007 Wensda Project I Contra ff 6522 SEWER PIPELINE CAPACITY IMPROVEMENTS ctor Hrs.: Start Stop Contractor Garcia Juarez Construction Traffic Normal Location Weather spring Garden St. AM Drizelled, Cloudy Subcontractor Weather PM Partly Cloudy Inspector Art Hernandez Day Shift: (On duty: 0700 to 1000hrs.) Humidity Low CONTROLLING ITEM - AMTemp 48F -PM Temp 64F NUMBER WORK PERFORMED Spring Gardena SL Rained Off F0700hrs. Met field personal at the job site The yard and alley way were very muddied, contractor had concerns in accesing equipment and dirty the streets Contractor will request time off for this day- SWPPP ..... .. Drove around and checked condition of Drain inlets and found in compliance at this time. NOTES: - -... .. - 0830hrs_ Reported my findings to D: Simmons (Riv. PW En on a phone conversation. p -- -...._ . rsati n. - 2- Weather report pronostics art clearingthru the da time and p -. y_ .._ PQsslble rain the I t _ _thN evenin .3- Worked on reports and labeling of photos 9' I — TRAFFIC CONTROL COMMENTS EQUIP* ! DESCRIPTION 1 93 - �... _ ...._ . -. - HOURS F350 - r --- —__ i ton p/u - - — PERI On Site `R Navarez _ _.Ct 3/4 ton u -_r___ --� --- _ On Site . — '•' _w_n+c rwpp-4704 . ___ : _. ___---_._- - - 544E J.Deer/ Front Loader235 — i Cat /Excavator i 235 -f Cat / Excav w/Shee�foot attach, - .._ - - ..WT -06 Vater truck _ F Trudc_— F - - --NOTE- Days- ---- - Yyeamer -- Used DaysExtWork Days I Remaining Days _-----ME Total - -- -- -- - :' - i CLA3SDCATION ` HOUR_S 4mant F On She _- --� -- lab -,_ rJn-S On Site Art►i_Diary 12-19-07 CITY OF RIVERSIDE DAILY Page 1 of ' CONSTRUCTION REPORT Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Contractor Garcia Juarez Construction Location La Cadenza Dr. Spring P g Garden St, Columbia Ave, and Palma Rita Ave. Subcontractor Inspector Anthony B. Allen (On duty 19h30 to 04hOo) CCNTROLLNG rrry I NUMBER WORK PERFORMEDThe Contractor repaired the damaged lateral Line Ilem # 12 The Contractor began setting out the traffic control at 8hO0. 1 2/1 712 00 7 through 1 211 812 00 7 --------------- Monday and Tuesday Start 20ho0 Stop 04h00 AM Traffic. Light PM Traffic Light Weather Clear Cloudy Rain Klnd Still Moderate;g High Humidity Low Moderate - High AM Temp 40 PM Temp I 45 Line Item # 6 The Contractor excavated and placed 2 joints of 12" pipe from 14+98 too 15+ 09 in compacted and caped with temporary AC- The Contractor prepared for the coming mo Columbia Ave. The trench was backfilled and The Contractor excavated for the manhole at station 15+10 The Contractor laid down some water during the sweeping operations and tried to keep dust to a minimum while attempting -to - Significant Conversation: Additional Equip. J/D Broom Tractor 1h . J - . - !Deer 510C eadr H - - - - - -- - oe Compactor (Oh). 10 Wheeler Dump -- - Traffic signals were set to flashing eft red in the in TRAFFIC CONTROL COMMENTS- - P Truck # 41 (7)(98157) (oh) ►sections affected by operations in order to create a safer working environment EQUIP # DESCRIPTION 93 -------- BH 31 _31DD John Deer Backhoe ---HOURS -- 1-18 _ �544H J/D-Front End Pi - - pe Loader t2 DC13 _ 235 CAT Excavator - 1 9B17417_-.--_ —10Wheeler Dump Truck _-- —0 8)(59677..: —-- - - Crew Cab PkJcup 0 4Z09112 Flatbed Service Pickup _--- 1 GX534341 _ Utility,p►ckup 487189 ----------- --- Rand Lighting Plant 1 WT -06 - --,_ ord— Water Truck 8 _ 544E John Deer F -- -- root End Loader U --= 5,119884 _ _10 Wheeler Dum' T- ck - - — 2 e IX12 -- 235 CAT Excavator/Compactor 0 Days L (' " emw 1 t-------'--� ExtrA 1111ork Days 1 12/2012007: 11:37 AM �•�.�Vnnl_L - - - CLASSIFICATION HOURS en Mendoza Is Lopez - — _ F.oremaNOpera— r g ,eAscencio _.-_borer a dEbres- - - Laborer e yR+ec_ 3checo - --�_- I ----- -Laborer-----"-- T 0 r Nuhez Operat�8 ucheco—_-_—_. "borer -� 0 -------_---- Laborer _--- e - Operator 0 Laborer _ _ �q DW Laborer B --- ___ Remainlrp Days Operator 0 - Dec 17 through Dem 18 rev. CITY 01F RIVERSIDE DAILY Page 1 of 1 CONSTRUCTION REPORT 12/1812007 Tuesday Project Contractor Hrs.: Start 0830hrs # 6522 SEWER PIPELINE CAPACITY IMPROVEMENTS — Stop 1530hrs Contractor Traffic Li ht Garcia Juarez Construction - — - ----- ---- 9 ----- Location Weather AM Cloud Spring Wee Garden St _-. _--..._�---- Subcontractor Mer _...._. Inspector Art Hernandez Day Shift: (On duty: 0700 to 1530hrs.) Humidity_ _ - —Low CONTROLLING ITEM; AM Temp 48F PM Temp B4F NUMBER I WORK PERFORMED --' _Spring Gardens St- a) La) Contractor placed 2.5 C ds- of concrete mix # 56063250 for the base of Manhole # 4 b Placed back the steel plates and cleanup the work area. -REWORK ,Excavated and recon acted for Manhole # 1 at Sta. 10+00 4hrs. _I robbed the succesive lifts and found sistency with Drevious work °Contractor Yet to provide Compaction Test for this work i 'NOTES: a) Find here attached the layout of steel plates installed at the intersection -----_---- a Photos of activities in file on of E. La Cadena and SPrinq_Gardens S— L TRAFFIC CONMOL COMMENTS 0830: Set up Construction/Detour signs. 1530: Removed Construction/Detour Signs . -- -vaya — uya i Retrlairilpg DByg I --- signature ArtH Diary 12-18-07 CITY OF RIVERSIDE DAILYPage 1 °f 1 CONSTRUCTION REPORT 12t1612007 through 1211712007 Sunday and Monday Project 46522 SEWER PIPELINE CAPACITY IMPROVEMENTS Stait 20h00 Contractor Stop 04h00 Garcia Juarez Construction AM Trarfhc Light Location PM Tr&MC. Light La Cadenza Dr., Spring Garden SL, Columbia Ave. and Palma Rita Avg. weather Clear Cloudy Rain Subcontractor h30 to �� ` Still Moderate. _. -- - I High Inspector Anthony B. Allen (On duty 19OSh00) F-lu/711d ' CONMOLLMG ITEYI -- _ _ hY_ I Low Moderate High NUWXR AM Temp I39 PM Temp 45 WORK PERFORMED Line Item # 12 The Contractor began setting out the traffic control at 8h0O. The setting out was not according required to be rectified. The plan the Contractor had on hand was not a stamped a ovedla t. the, traffic control plan and was Line Item # 6 The Contractor excavated and placed 8 joints of 12" i approved plan. - p pe from 14+49 too 14+98 in Columbia Ave_ The trench compacted and caped with tem Porary AC. The Ins was backfilled and Inspector queried the bean _ _broken lateral - - - sewer fine and ng capacity of the temporary plastic One placed in the _ .._ ._ _requested the Contractor for its design specifications_ None could be provided. to patch the fine inserti - - bY ... ng the plastic line into the clay fine and fill it with a slu - - - rry grout mix around the joint. Th - eContractor tried e ontractOf laid down some water during the prevent a mud s'p- °Perotions ".tried to - -muddy condition - . keep dust to a minimum while an tin to Signit3cant Conversation:- - ----- - ` -- - The Con -- trado- was directed to kee the roadwa free of dust and mud _ The Conti --- ---- - -- ---------Y--...--- ------ - -_�' conditions-._...---- actorwas issued a correction notice to use correct The dump....._ - . - _ ss - trucks were also to be - x e9 cc n pu f►agmen when cro Ing a roadway open to the public - --- -- _ _ _covered correctly when travelin on ,The Contractor was is ---- - ---- _ -9 Publi - - - ued a correction notice to come P c roads. -- _ s - follow the co �Y repa, alatera-- . r fine broken during excavation opera - - - meet Br Procedure in order to prevent contamination. (Not a 4" thin wap a Additional Equip - — -- --- tior>s and to q P J/D Broom Tractor (1h). J/Deer 5100 Bade Hoe Com - -- - - - corrugated plastic drain�pe)_ Traffic signals were set to flashingall red in the inTRAFFIC Factor (0h). 10 Wheeler pump Tructc # 41 tersections affected CONTROL CLIENTS: (7)(98157) (0h) by operations in order to create a safer working environment. EQUIP # DESC - - - -- -- - - RIPTION 93HOURS ' BH 31 - ---- 31DD John Deer -----PERSONNEL. L78BarJchoe 0 'Ruben Me - _ --CLASSIFICATION _HOURS . _544H J1DFW End Loader IXt3 CqT Excavator—�--- ------------ Lopez LL°�Foreman/p�-e 9817417 --- - -- _Jafrne q—scendg - ���_ 8 - 1 D WAeeler DumpTruck 4 Laborer 8)(59677 Crew Cab Picku - _`David Flores -- - P _ 1 Laborer 4209112 _Flatbed Service Pickup i iyt --Laborer 8 6X53434, pip IAdolfo Pacheco - ?borer -! - 0 487189 - In�erso► R Ughting Plant WT os _- Operator 9 �ct 1'uche� taborer Ford Water Tnx;k ---_- 0_ - 0IRamon Bdsseno _ borer 544E John Deer From End Loader 5J19884 1D Wheeler Dum�Truck 2 Rfcaser �l-tor---------- _ B EX12 235 CAT t xcavatar/Com -- 4 -` RO�'Q -_ Lamer 0. Pactur 0 -`DougBurb,�r- --- Laborer 8 :- Daye Used I 11VBatilBf -- -- E*a i4brk Days R®rrtaln6tg Days O -. oda Total 12J2M007 : 11:35 AM Signature DeG16 through Det; 17 rev. -)ds CITY OF RIVERSIDE ©"ILY Page 1 of 1 CONSTRUCTION REPORT 1211712007 Monday Project Contractor Hrs.- # 6522, SEWER PIPELINE CAPACITY IMPROVEMENTS Start 0800 r Stop 1530hrs Contractor AM Tra ffic Light Garcia Juarez Construction Localion Spring Garden St / La Cadena Weather AM Clear Subcontractor Weather PM Clear Inspector Art Hernandez Day Shift: (On duty: 0700 to 1530hrs.) i Humidity Low CONTROLLING ITEM AM Tamp 48F ,PM Temp 64F NUMBER WORK PERFORMED 10 Spring Garden SL a) Contractor excavated at Sta. 15+38.89 for the installation of the 48" MH # 4 down placed a section of the 8" VCP and to +/- Elev. 863.98 prep -up to pour the base of the MH by tomorrow !Observed the placement of Jacks to protect the excavabon .b) Replaced steel plates and clean up the area i NOTES: :1 -Photos taken, in file `2--1430hrs. Informed Daniel Simmon Riv. PW Eng. of the work in progress. TRAFFIC CONTROL COMMENTS 0800hrs. Began to set up Construction/Detour signs, 1510hrs. Completed removal of COnstructioNDetour Signs EQUIP * j DESCRIPTION 93 F350 _ HOURS __ .. - - - RERSUNN L ' 1 ton p/u. 7 ¢ __ 'CLASSIFICATION I HOURS ----- C1500 _ _ — -.- - _ - ---_ - s Rudy Navarez 314 ton p/u - _ � 7 r - - €Jesus Ordones - -- — 4man/ope ! 7 310SE Q.Deer 1 Backhoe Turbo 4X4 T 7 - - - — - — - ' -- lab 7 544E - - - --=- €Cesar Ulises UDeer I Front Loader - __ 235 Cat / Excavator I 235 Cat l Excav w/Sheepfoot attach, - -- - W`r� --- --- — - 'Water _ - ------ Dump trticic ------ -- ! - -- - ------ r Contract �'--- - —� Wea--- --- Days Used i D I Ex6e Wbrk D ----- --1--O-aYs _ ---.—.. ari I Rer"au,m9 Days t _TotalJ— Signature ArtH Diary 12-17-07 4 .� v W'Z V n. r . �1°i-W Q p -01 ,y U 1 M V O W W r .dam s -W - Q:O - f o W � ° Y a z ' _o a'a Its Z-� W < S Y wya • Hca T W v W { W J O CITY OF RIVERSIDE DAILY Page 1 of t CONSTRUCTION REPORT Project 06522 SEWER PIPELINE CAPACITY IMPROVEMENTS Contractor Garcia Juarez Construction Location La Cadenza Dr., Spring Garden SL, Columbia Ave- and Palma Rita Ave_ Subcontractor Inspector Anthony B. Allen (Not on duty) carrR0I-L Wo rrEW I NUMBER WORK PERFORMED The Contractor requested a non -working day - Significant Conversation: - Additional Equip_ J/D Broom Tractor (0h). J/Deer 510C Back Hoe Compactor (Oh). 10 Wheeler Dump Truck # 41 (71(gg 157) (0b). Trench whacker (0h)_ - _- - TRAFF)C CONTROL COMMENTS: EQUIP 0 12130/2007 through 12/31/2007 HOURS Sunday and Monday Start-�� Stop AM Tr'afBc Light PM Trafiia Light Weather Clear Cloudy Rain Wind Still Moderate High Hurnb* Low Moderate` High ;AM Temp : 41 IPM Temp : 4$ Significant Conversation: - Additional Equip_ J/D Broom Tractor (0h). J/Deer 510C Back Hoe Compactor (Oh). 10 Wheeler Dump Truck # 41 (71(gg 157) (0b). Trench whacker (0h)_ - _- - TRAFF)C CONTROL COMMENTS: EQUIP 0 DESCRIPTION - - HOURS 93 ' BH 31 3t OD John Deer Backhoe _... __-- - - - - - PERSONNEL - -- ------ L1ti 544H J/D Front End P Loader -- - - Ruben Mendoza -- ---CLASSIFICATION—_IiOURS 13 !Pe _.. 2. CAT Excavator --- - - --- --- (J psusLopez- - __--- Foremaryp�W 0 ..- -- - 17417 . -- --- • ---....__-_-- 10 Wheeler Dum p Truck - - --- - - - D -- - -- ---- -- JaimeAscenk5o _ _ - - •-- `Davkt - -Laborer Laborer 0 BK59677 - -- Crew Cab, Pickup --- -- p -- -- - - Flores Laborer o - 4Z09112 ' _._...___-- ... Flatbed Service pickup 0—_GorgeVatdez -- ..-- --- -- = . 0 53434 - -_ - - --------------- Utility Pickup ° ---- Pacheco __.._— -_—�-- ` ----i--0 - 487189 IngersW Rand Lighting plats p - �_- Laborer - _ WT -06 - Ford Water Truck ------ —_€SamuelPucbeco ---�- - .. --- - 544E John Deer Front End Loader p )tamor� Brrsseno Laborer - -- 5J19884 - to Wheeler Dump Truck p Rosendo Akaser O for Laborer 0 - - _... IX72 --- - -. ------- 235 CAT ExcavatodCom 0 !Jesus Rodriquez 0 - --�--_ ---- --° Doug Burlow laborer- 0 coDrro-aaDew Used E T I - Operator 0 -Toted drn Wbrk Dep i I _ 1/712008: 9:27 AM Dec -30 through Dec. 31 -)ds CITY OF RIVERSIDE DAILY Page 1 °f 1 CONSTRUCTION REPORT Project #8522 SEWER PIPELINE CAPACITY IMPROVEMENTS Contractor Garcia Juarez Construction Location La Cadenza Dr. Spring P g Garden SL, Columbia Ave. and Palma Rites Ave Subcontractor Inspector Anthony B. Allen (On duty 191150 to 04h30) corrmaurrc ITEM I NUMER WORK PERFORMEp The Contractor set out traffic control and continued from the previous night where they had ended the excavation of the top of the trench. They then backfilled the trench with CMD and compacted with a trench whacker with the aim of obtaining the required compaction of 95%. The nights operation was from station 13+76 too 15+90 12/27/2007 through 12/28!2007 Thursday and Friday Start 20^hpp Stop 04hpp AM Trat Light PM Traffic Ligh Wðer Clear Cloudy Rain Wind Still Moderate High Humidityi Low AM Temp 40 Moderate High ; PM Temp 45 The Contractor air tested the line on E. La Cadena. The South side of Columbia Ave. held its pressure but when the North side was tested, the compressor failed_ This area will be tested the following week. Significant Conversation: - The Contractor handed the Inspector a follow up D.E.W.D. to the previous night. The Inspector added his comments a rxf signed it- _. dditional Equip: J/D Broom Tractor (1 h). J/Deer 51 UC Back Hoe Compactor (Oh)- 1 p Wheeler Dump Truck # 41 (7K98 157) (2h). Trench whacker (7h). -- Traffic signals were set 10 flashing all red in the intersections affected � � C -Y operations in order to create a safer -- -------------------_.- working environment EOU1P A DESCRIPTION HO93 - URS -- PERSONNEL i 1/7/2008. 929 AM . Dec.27 through Dec. 28.x1s roriCErii1 Pipe Loader --- ` -- � qt V IF)CATION HOURS 13 _.. 235 CAT ExcavatorLaborer -_ Jesus Lo Forema --=---r 8 9B17417 10 - ...... Wheel Dump Tnx�c _ ...__.--- iJaima Ascencio '_ - -- --- - ---- ' -..- -—'- 8K59677 .- ------ --- Crew Cab Pickup --- Did Flores -�- Laborer --�-- 8 4209112 Flatbed Service Pickup 1 . L Valdez __--- --Laborer ---�-_8 - 6X53434UtilityeP Pacheco 487189 .. -_----IrgersW_Rand _.. _....-----...—..-------- Lighting Plant -1— --- 'Alelundro Nunez �-"------�_-- e W17-068 _._ WT 06 — --- Ford Water Truck 8 --`-Samuel Pucheco Laborer taborer -.- --0 -- --- --= - ------ -544E John Deer Front End Loader U lRarrwrr Brlsseno - ----- a e ---- --4 tO Operator -Operatr5J19884 - 8 EX12 _ --- -- ----1- 235 CAT Excavator/Co_mpactor ;Jesus Rodriquez Laborer 0 -- _ -- -- Doug Burow Laborer e "�li Extra Mit - -- k Work Days i�eiator - �- 0 - i 1/7/2008. 929 AM . Dec.27 through Dec. 28.x1s CITY OF RIVERSIDE DAILY Page 1 of 1 CONSTRUCTION REPORT Project # 6522 Contractor Location Subcontractor Inspector Art Hernandez CONTROLLING ITEM NUMBER SEWER PIPELINE CAPACITY IMP Garcia Juarez Construction Spring Garden St. spring Gardens St. 25 IODened un th. r ---k Shift: 1s/sal2oo7 Friday Contractor Hrs.: Start 0700hrs Stop 1630hrs ENTS Traffic _ Normal -- --- Weather __ Clear H1111II& Low 0700 to 1630hrs. Temp AM 33F Temp PAA 52F I WORK PERFORMED ......11.l 1 I Tall aryl l till Compaction test for this Contractor observing res NOTES. 1- 1000hrs iuires 95°x, test at this time 111 Pluvitl$- S to Sean in file - ted and backfill with +/- 12" of base material and recompacted at this time — on a TRAFFIC CONTROL COMMENTS: AM Placed construction signs PM Removed Construction signs EQUIP DESCRIPTION ---- F350 "OURS PER30NNEL 1 ton u _ _ CLASSIFICATION t3 _ i Rudv Navarez_ -- - _HOURS --C1500 3/4 ton _ u 4man/o e a `:Jesus.Ordones -_ e-- __8 _ -_ 310SE J. Deer / Backhoe Turbo 4X4 lab _ - g - _ - -- -- - Cesar ulises ---- -- - 544E J. Deer/Front Loader -- ---- - 9 -------- ----- -- - -.-- -- - -- I ---- --- ab4 043KW _------------- ---=-- ------ - -- -----.-_-- KWlDumpTrucks------------- 8 - - - -- Day, Used � a �-� wont Days R .. 1 --- -- -- --�- -- - - - - — ------ - °m°fnrnp Days ____-oda Total.J+ + _ ' S18rwture ArtH--Diary All CITY OF RIVERSIDE DAILY Page 1 of t CONSTRUCTION REPORT 12126/2007 through 12/27/2007 Wednesday and Thursday Protect 16522 SEWER PIPELINE CAPACITY IMPROVEMENTS Start 20h00 Stop 04h00 Contractor Garcia Juarez Construction AM Traffic Light PM Traffic Light Location La Cadenza Dr., Spring Garden SL, Columbia Ave. and Palma Rita Ave. Weather Clear Cloudy Rain Subcontractor Wind Stili Moderate High Inspector Anthony 8. Allen (On duty 20h50 to 04h30) FfUm/drty Low Moderate High CONTROUNG gyp AM Temp! 38 PM Temp 42 NUMER WORK PERFORMED The Contractor set out traffic control and continued where the day crew had ended the excavation of the top of the trench_ They then backfilled the trench with CMD and compacted with a trench whacker with the aim of obtaining the required compaction of 95%. The nights operation was from station 12+57 too 13+76. :Significant Conversation: - The Contractor wanted the Inspector to sign a print of a D.E.W_D. The Inspector required him to fib out the co then added his comments and signed the form. rrect forms and he Additional Equip. J/D Broom Tractor (1h)- J/Deer 510C Back Hoe Compactor (Oh). 10 Wheeler Du 157) (2h). Trench whacker (7h). mp Truck # 41 (71<98 Traffic signals were set to flashing a8 red in the intersections affected CONTROL COMMENTS: - .- .--- --_— by operations in order to create a safer working environment EQUIP # - DESCRIPTION HOURS BH 31 310D Jotm peer Backhoe HOURS tuben Mendoza - -'- --- L16 544" J/D Front End Pipe Loader p esus Lopez EX13235 CAT Excavator --- -- Laborer 0 9877417 10 Wheeler Dump Tnrcic - -1 --- 8K59677 Crew Cab Pickup 1 4ZO9112 Flatbed Service Pickup -- -- 1 6X53434 -- utility Pickup --� d_olto -.-- - 487189 Ingersol Rand Lighting Plant ---- ---- - - 8 WT -06 Ford Water Truck --8 �muel Pacheco ---- ---_-- - -- 0 544E John Deer Front End Loader - 4 5J19884 _tO Wheeler Dump Tmck --�-- _- . _ EX 12235 CAT Excavata/Com�actor _ _ - - - - - 0 Mendo A caser COnfra� Days Usad-- j—WeaMwr— T — Da s --- half_ _ Extra Work Days ;.... _ . -- -- - — --�--------- - !t Total sus Rodriquez 1/7/2008: 9:30 AM 93 _PERSONNEL CLASSIFICATION HOURS tuben Mendoza - -'- --- 8 esus Lopez —_-_._---- ' aime Ascenao Laborer i 0 -- Laborer g 'avid Flores -.. . -. ----- Laborer 8 age Valdez - ----_ i Laborer d_olto OPemta ejurdro Nuhez --8 �muel Pacheco ---- - Laborer p Laborer g anon Brisseno � _- . _ -- ----motor Mendo A caser Laborer 0 sus Rodriquez Laborer 8 L19 Burlow -- --- Operator 0 Rernainln0 Days Signature -- Dec.26 through Dec. 27.x1s CITY OF RIVERSIDE DAILY Page 1 of 1 CONSTRUCTION REPORT 12/27/2007 Thursda Protect # 6522 SEWER, PIPELINE CAPACITY IMPROVEMENTSContr Hrs.: — Start 0700hrs Stop 1530hrs Project Contractor TratTic Normal Garcia Juarez Construction Location Weather Clear _ Spring Garden St. t-- Subcontractor Windy strong at times rrrInspector Art Hemandez Da Shift: (On duty: 0700 to 1530hrs.) Humldit Low coaaurrc ITEM AM Temp 35F PM Temp i 54F NUMBER WORK PERFORMED ---_-__ Spring Gardens St. 10_-__. a Contractor -pe rmed presure test of the 24" tine between MH -1 and MH -2 and Between MH -2 and MH -3 pressure test was acceptable as per section 306-1.4.4 of the Std. Specs. 2006 Edition. --25 'b Opened up the trench between 10+00 to 11+50 excavated and backfill with +/- 12" of base material and recom acted, Com action test for this work requires 95°x, test pending at this time LOR Geotechnical (For Contractor) On site, performed compaction test as follow .MH -1, 10+00. ELEV..862 = 93% Retest MH -2, 11+50, ELEV..864 = 91% QC Test __ MH -3,15+23. ELEV..868 = 90% OC Test Picked up samples of the "Crushed Aggregate Base" for required test — ---- NOTES: ---------- ---- -- 1- 1100hrs. Re Wed the work in p lress to Sean Gill (Riv. Public Works on a phone conversation. 2- Photos taken today, in file. TRAFFIC CONTROL COMMENTS EQUIP p DESCRIPTION Iii HOURS i PERSONNEL F350 1 ton /u CLAS81E"TION HOURS_ 8 iRud Navarez ---91500 3/4 ton u 8 4man/ope _g 310SE J.Deer/ Backhoe Turbo 4X4 `Jesu.0 Ordones -- ---- lab g 8 (Cesar Ulises _ 544E- J. Deer/ Front Loader __ope. -_- - g 8 'Jesus Lopez n5 Cat (Excavator -- ---�_ tab g 043 KW / Dum Trucks ----- --- -- I 0 'In -OR Geo./ Tony Gillard - 46 KW / Durr, Trucks 4 € _ .� Tech. 2 ----- Contract ------- - ------------ .__..._. . ---- - '---------- -`- Ds Days Used Days - Ewa Work Days Rernak*V Dys -- —oda _ --- - ------ --- -- + + Total = - 0wtwe ArtH Diary All CITY OF RIVERSIDE DAILY Page 1 of 1 CONSTRUCTION REPORT 12/25/2007 through 12/26/2007 Tuesday and Wednesday Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Start —Q Stop Contractor Garcia Juarez Construction AM Traft Light PM T /&fiC Light Location La Cadenza Dr., Spring Garden SL, Columbia Ave. and Palma Rita Ave_ Wt3athBr Clear Cloudy Rain Subcontractor Wind _ . Still Moderate High Inspector Anthony B. Allen (Not on duty)HUMid I Y Low Moderate High �T0 CL11NGiTEMi NUMBER AMTemp 40 'PM Temp` 50 6 WORK PERFORMED Contractor requested and was granted a non -working day. Significant Conversation: - Additional Equip_ J/D Broom Tractor (Oh). J/Deer 510C Back Hoe Com actor( Dh . 10 TRAFFIC CONTROL COWAENTS) Wheeler Dump Truck # 41 (7)(98157) (Oh) EQUIP # DESCRIPTION93 HOURS - PERSONNEL _ BH 31 310D John Deer Backhoe - - ` _ 'Ruben Mendoza - ---- ----- _— ----- _ CLASS-CATK)N IFI U L16 544H J/D Front End RPe Loader -- - - f GremM rator �0 RS 'Jesus Lopez EX13 .235 CAT Excavator - Laborer _-Jaime Asncio 9817417 _70 WheeW Dump TnLck -- " ' - Laborer 0 --- —__0 4David Flores 8K59677 Crnw Cab Pick up - - - -- --- 0 Laborer 0 -----=- --- 'Gorge Valdez -0. 4Z09112 Flatbed Service Pickup 0 --- - - - Laborer - - _ 6X53434 Utility Pickup Operator - - --- ---� -- 0 487189 t19 Nuhez -- ersol-Rand Lighting Plant 0 --- �� 0 --- Samuel Pacheco -- -- - - - WT -06 Ford Water Truck ------`---- -- Laborer 0 :Ramon Brisseno - - _ -544E John Deer FrorN End Loader--�------ ---- Operator --. 0 `Rosendo Alcaser ---- -- -- - 517 9884 `01Nheeler Dump Truck € Laborer 0 --- _Jesus Rodriquez EX12 235_CAT Fxcavator/Compactor _ _ - Laborer Contract T----,—weamei j 0 Q_Burlaw-- ---�- °� 0 ---- Dan tDays Used i Extra Work --- Days .� - ' Today --- --_„n Total Signature 117/2008: 9:31 AM Dec.25 through Dec. 26.x1, CITY OF RIVERSIDE DAILY Page 1 of 1 CONSTRUCTION REPORT Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Contractor Garcia Juarez Construction Location La Cadenza Dr., Spring Garden SL, Columbia Ave. and Palma Rita Ave. Subcontractor Inspector Anthony B. Allen (Not on duty) CONMOLING rTF,1,r I NSR : WORK PERFORMED Contractor requested and was granted a non -working day. Significant Conversation: - Additional Equip. J/D Broom Tractor (0h). J/Deer 510C Back Hoe Compa TRAFFIC CONTRQI COMAAENctor (Oh). 10 Wheeler Dump Truck T3 # 41 (7K98157) (Oh) EQUIP # 12/23/2007 through 12/24/2007 Sunday and Monday Start Stop AM TiatTic Ligh _ PM Traffic Light Weather Clear Cloudy Rain Wind Still Moderate High hhumidtty : Low Moderate' High AM Temp 40PM Temp: 50 Additional Equip. J/D Broom Tractor (0h). J/Deer 510C Back Hoe Compa TRAFFIC CONTRQI COMAAENctor (Oh). 10 Wheeler Dump Truck T3 # 41 (7K98157) (Oh) EQUIP # DESCRIPTION 93 BH 31 - 310D John Deer Backhoe HOURS 0 _--- CLASS►FlCATION L78 544H J/D Front End Pipe Loader _i Ruben Mendoza - - HOURS EX13 - 235 CAT Excavator _ esus Lo - -- Lopez - .. ..__.--- foremarVO rotor 0 -- 9817417 - :10 Wheeler Dump Truck 0 -o `JaimeA - ' -- -Laborer ---' - - _ 8K59677 - ... _ Crew Cab Pickup -- '-'---=_—Flores ------ David Laborer -- ----- --- --- EGorge Valdez Laborer ' `— 0 4209112 Flatbed Service Pickup - 0 --- --- - -- — Laborer 6X53434 -- - Utility Pickup - — LAdolb Pacheco ----_U_ _ _ 4871890 Rand Li9ntirg Plant ---- — 0 --AI�U�ro Nuhez Opp 0 -- WT -06 - Ford WaterTnrcc- _- `Samuel Pacheco Laborer 0 - - - -- - ... _ 544E John Deer. Front End Loader Ramon Brisseno �- — Labrer- 0 5J19884..- - - -- ---_ 0 :R a osendo Akaser Operator 0 _- -10 yyhEe� Dump Truck Laborer -. D(12 - _ - 235 CAT Excavator/Compactor `Jesus Rodriquez 0 0 -------� :Doug Rwr... Laborer 0 Contract I Dayta Used I Wesow T--- Ex►ro Work Days T� --- i--- 1/7/2008: 9:34 AM Rerr>ainbp Days y+� Signature Dec -23 through Dec. 24s.xls CITY OF RIVERSIDE DAILY Page 1 of t CONSTRUCTION REPORT HOURS 93 BH 37 12/24!2007 through 12/25/2007 0 PERSONNEL Monday and Tuesday Project 86522 SEWER PIPELINE CAPACITY IMPROVEMENTS Start Stop -^PM Contractor Garcia Juarez Construction AM Tr ef►- Light Traffic Light Location La Cadenza Dr., Spring Garden SL, Columbia Ave. and Palma Rita Ave_ W9eth� : Clear Cloudy Rain Subcontractor 10 Wheeler Dump Truck Mnd Still Moderate. High Inspector Anthony B. Allen (Not on duty) Humidify Low Moderate. High CONTROLLING ITEM I AM T9mp: 40 PM Temp 50 NUMBFA WORK PERFORMED 0 .. Laborer Contractor requested and was granted a non -working day. 6X53434 utility Pickup0 i Significant Conversation:- --- - - . Additional Equip. J/D Broom Tractor (0h)_ J/Deer 5100 Back Hoe Compactor (Oh). 10 Wheeler Dump Truck 11141 pK98157) (Oh) TRAFFIC CONTROL COMMENTS: - - EQUIP # - DESCRIPTION HOURS 93 BH 37 31 OD John Deer Backhoe _.. 0 PERSONNEL HOURS L18 - — 44-H - -5J/D Front End Pipe Loader -- - `Ruben Mendoza . Fo[emarVOperator - p EX13 - - 235 CAT Excavator 0Jesus Lopez t -- --- ' 0 91311174117 10 Wheeler Dump Truck 0 Jaime Ascencio --- -- _. _--- Laborer — 0 8K59677 Crew Crew Cab Pickup - 0 --David 0 Flores ----- iGorge Valdez Laborer - 0 4ZO9112 Flatbed Service Pidmp 0 - -' - ---- •`Adolfo Pacheco Laborer 0 6X53434 utility Pickup0 ------ Operator p _ 487189 _-- .---- In 9ersot Rand _...------------Ughtirg Plant :'Alejundro Nuhez " — -- ----- 0 WT -08 - Ford Water Trude -- Samuel Pudleco - `- ----- `Laborer Laborer - 0 €Ramon Brisseno - - - - - End Loaderp - Operator 5J19884 - - -- ----.. 10 Wheeler Dump Truck -.---- `Ro_s_endo Alcaser - Laborer 0 EX12 ------- 235 CAT Excavator/Com ----- 0 -- 'Jesus Rodriquez --- - : laborer - 0 _ Doug Burlow _. . i Days Used I �"^ ----� 1 Extra Vypk I per. . --�—�m 1 ..... mW*V DYys .--�_Do ..-� 1172008: 9:33 AM Dec.24 through Dec_ 25.xis Page 1 of 1 CITY OF RIVERSIDE DAILY CONSTRUCTION REPORT Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Contractor Garcia Juarez Construction Location La Cadenza Dr., Spring Garden SL, Columbia Ave. and Palma Rita Ave. Subcontractor Inspector Anthony B. Allen (On duty 20h50 to 04h30) CONTROLLING ITEM' NUMBER WORK PERFORMED 01103/2008 through 01/04/2008 Thursday and Friday Start 201100 Stop 05h00 AM Traffic Light PM Traft Light Weather Clear Cloudy Rain Mnd Still Moderate High Humidity - Low 'Moderate High AM Temp 38 ' PM Temp ' 45 The Contractor set out traffic control and started on Columbia Ave. to remove the materials from the top of the trench. They then backfilled the trench with CMD and compacted with a trench whacker with the aim of obtaining the required compaction of 95%. The area worked on was Station 10+00 too 13+86 The Contractor prepared the catch basins, stockpiles and general site for rain. /0P/-/ Significant Conversation: - 117/2008: 9:24 AM Jan.03 through Jan.D4.)ds Additional Equip. J/D Broom Tractor (1h). J/Deer 510C Back Hoe Compactor (0h). 10 Wheeler Dump 157) (2h). Trench whacker (8h). Truck # 41 (7K98 - --- ---- -- Traffic signals were set to flashing all red in the intersections TRAFFIC CONTROL COMMEMM- affected by operations in order to create a safer working environment EQUIP# . DESCRIPTION 93 HOURS PERSONNEL BH 31 31DD John Deer Backhoe - . -- - - - - - -- D CLASSIFICATION -_ URS LIB 544H J/DFront End Pipe Loader Ruben Mendoza - - -- - ---- - - FoTTan/Operator 8 .. 0 Jesus Lopez EX13 '23.5 CAT Excavator ------ -- 0 b aime Ascertcio ---- -- - -- - — 0 9877417 10 Wheeler Dump Truck -_ -- - - 2 s David Flores --Laborer B•, BK59677 ---- Crew Cab pickup - -- - --- --- 1 `Gorge Valdez `- e Laborer g - - 4ZO9112 ----- Flatbed Service Pickup - — --- ----- Laborer -- p - . 6X53434 Utility Pickup Pacheco - 487189 Inge-rsoLRand Lighting Plant 8 `Samuel Pacheco - . VrlT 06 Fcti! ::otiar T - ----- ---- 0 Laborer —e - -... 544E John Deer Front End Loader _�___Ramongrisscylo 4 I Rosendo Akaser - ---- — 5J19884 -_ 1D Wheeler Dump Trude -- 0 `Jesus Rodriquez - Laborer 0- DC12 235 CAT Expvator/Compador 0 :Doug NWow ��e 8 Cmba—c! '- W E Days Used I Extra 0- , Work Days RemeWft Dar. -- Today - - -- - `+ - -- —+---- _ -- TOW - ------- - -- - - / S-_ 117/2008: 9:24 AM Jan.03 through Jan.D4.)ds CITY OF RIVERSIDE DAILY Page 1 of 2 CONSTRUCTION REPORT 1!412006 Friday Project # 6522 SEWER PIPELINE CAPACITY IMPROV Contractor Hrs.: Start 0700hrs Stop 1530hrs Contractor Traffic Garcia Juarez Construction Normal Location --- � S rip Garden St. Weather Partly cloudy i Subcontractor -- Inspector Art Hemandez Da Shift: 0700 to 1530hrs.) Humldi _-- Low coNlRauNcilEM1Temp AM 44F ---� NUMBER Temp PM 66F I WORK PERFORMED ___ Spring Gardens St. a Contractor installed saddles to the new 24" main line and made lateral connections at 4 location see here attached a record of lateral connections for more detailed information s on the South side b Backfilled and compacted lateral trenches and cover with te C Clean u street mPOrary AC NOTES: 1- 0930hrs. Re rted the work in ro ress to Sean Gill Riv.Public Works on a hone conversation. 2- Contractor was strop 1 reminded to follow uideline SWPPPs for the installation of Steel Plates, field foreman said H e mply- _ _ .3- Re aced damecf �e_ Qravel bags at drain lnlets -- --------------- TRAFFIC CONTROL COMMENTS- . Placed construction signs PM Remov EQUIP. * . _ ed Construction signs -------- DESCRIPTION --- _ .. F350 HOURS f 1 ton - PERSONNEL CLASSIFICATION C15p0 3/4 t 8 ,Rud Navarez HOURs - on u — 8 :`Jesus Ordones 4marvo e 0 _--_ 310SE J. Deer /Backhoe Turbo 4X4 8 [ -- - --- :Cesar Ulises lab B 544E J.Deer/Front Loader — 8 ;Jesus Lopez o e. t3 - —�6 KW / Du Trucks -- - - — 8 `Jw a Vaklez lab - _._8 Contract Days Used Weather -- --- _ - __Do Extra Work Days - -- - - --- -- -- -- --- Remaintnp Days - - -..._Total----� ---- +- --- � ----- _----------�— - — \���`-- -- Signator@ ArtH Diwy 01-04-M CITY OF RIVERSIDE DAILY Page 1 of 1 CONSTRUCTION REPORT 1/3/2008 Thursday Project # 6522 SEWER PIPELINE CAPACITY IMPROVEMENTSactor Hrs.: Start 07DOhrs Stop 1530hrs Contractor Garcia Juarez ConstructionTraffic Normal ------- Location Clear Spring Garden St. Weather Subcontractor Inspector ArtHernandez Day Shift: 0700 to 1530hrs. Humid" Low CONTROWNG ITEM Temp AM 44F Temp PMNUMBER 66F WORK PERFORMED Spring Gardens St. 22 Excavated trenches for laterals at So 12+26 and S0.12+75 and covered with 1" late, no connections were made here. b O en trench,.bored holes in the 24" main line and installed "Saddles" at: 10+85 and 11+30 E x resin used for saddles: WYN-STICK b PTMBW Industries (boring bit broke down at 0900hrs. continued boring at 1145hrs. NOTES: — 1- 11o0hrs. Reported the work in p Iress to Sean Gill Riv. Public Works)on ijDhone conversation. 2- Photos taken today, in file. SWPPP In view of possible rain I asked field foreman to dress.up the storm drains TRAFFIC CONTROL COMMENTS: --- AM Placed construction signs PM Removed Constr u-tin., ArtH_DiarY 01-0308 CITY OF RIVERSIDE DAILY Page t °f 1 CONSTRUCTION REPORT 01/0212008 through 01/03/2008 Wednesday and Thursday Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Start 20h�. Slop 0000 Contractor Garcia Juarez Construction AM Traft. Light PM Tr8ffiC Light Location La Cadenza Dr., Spring we.athw. Clear Cloudy Rain p g Garden SL, Columbia Ave. and Palma Rita Ave. Subcontractor Wind Still Moderate High Inspector Anthony B. Allen (On duty 20h50 to 04h30) Humfdi(y-' Low Moderate: High cOkIAR011UNG ITEM AM Temp: 41 �PM Temp; 46 MBER WORK PERFORMED The Contractor set out traffic control and continued from the previous work night where they had ended the excavation of the top of the trench. They then backfilled The trench with CMD and compacted with a trench whacker with the aim of obtaining the .required compaction of 95%. Station 15+90 loo 17+68. Significant Conversation: - The Contractor told the Inspector that there is possibly a damaged pipe and therefore the fine isnot obtaining cornPrt scion - -- _ Additional Equip. J/D groomTractor (1h). J/Deer 5100 Back Hoe Compact 157) (2h)- Trench whacker (7h). or (Oh). 10 Wheeler Dump Truck #41 71<98 _ ...... . ONT ROL Traffic signals were set to flashing all red in the intersections afffectted bCCOMMENTS._-. _.-- ._---- ------ ---------y—peratio in order to create a saferworking environment. EQUIP [ DESCRIPTION PERSONNEL - - HOURS .131-131 -- 310D John Deer Backhoe _ - - L16, .. 544H J/D Front End Pipe Loader - --- 0 EX113 -------- __�---- 235 CAT Excavator i - 0 -- -- - -- 9B17417 - -- _ 10 Wheeler Dump Tnx9c - - -- - --- 8K59677 - Crew Cab Pickup 2 4ZO9112 Flattred —'— ... 0 _ 6x53434ut; — — - ----- _ 487189 _ - - -- - - - kkgersd-Rand Lightln9 Plant ---- --- - �7T LYi dad `Jloivi Tn/cik ---- 7 0 544E John Deer Front End Loader 4 _ 5JI9884- - 10 Wheeler Dump Truck —�---- 0 1=X12-235CAT Excavator/Corn actor 0 r,,���� Dsy—a � Weetherr r---- - Exka W4x* Days •t -edgy _ -- --------------- �- 117/2008: 925 AM 93 PERSONNEL - - rben Mendoza CLASSIFICATION -_ HOURS _ sus Lopez �---- Foreman/Ooerator g _ _ --- -- me Ascencio ' Later —=--__ 0 ---------taborer vid Flores 7 rga Valdez - ! Laborer t 7 - - •- ----------- NPacheco Laborerfo 0 _ tundra Nuhez Operator nuel Purheco ` 0 non Brisserro Laborer - 7 _ endo Icaw is Rodriquez Laborer D 9 Burlow Laborer 7 _ Rern *ft D&^ 0 Jan -02 Uttough-Jan.03.xis Page 1 of 1 Project 6522 Contractor Location Subcontractor Inspector Art Hernandez CONTROLUNGITEMI NUMBER CITY OF RIVERSIDE DAILY CONSTRUCTION REPORT 112/200B Wensda Contractor Hrs.: Start 0700hrs SEWER PIPELINE CAPACITY IMPROVEMENTS Stop 1530hrs Traffic ' Nor Garcia Juarez Construction j - mal- --- — _ Spring Garden St. Weather I i Day Shift: (On dut : 0700 to 1530hrs. Humidi EEE Low Temp AM 44F Temp pM 74F 'Jpn—ng _Gardens St. a) Excavated trenches for lateralsa-- t S0.1 1+30 and So.11+g2na d covered with 1" late, no connections we Conirador demaged existing line at 11+82 and tem rarl reconnect with 4" flex re made. b Contractor flushed the new 24" sewer line between MH -1 and MH -3. — NOTES: 1- 0100hrs. Re w the work in r rens to Sean Gill Riv. Public Works on a hone conversation- 2- Photos taken toda , in file. SWPPP Contractor observing regulations at this time -------------- TRAFFIC CONTROL COMMENTS: - - - AM, Placed construction signs PM Removed Construction signs ---- --- EQUIP # DESCRIPTION 93 — HOURS PERSONNEL __F350 1 ton U EL 3!4 ton u :RCLASSIFlCAT)ON _ S Ru Navarez N HOURS _-_C1500 4ma 8 _ !Jesus Ordones -- --,_ __- 8 - 310SE J.Deer / Backhoe Turbo 4X4 lab B 544E J. Deer /Front Loader 8 --- `Cesar Ulises_ - - - — - -- €Jesus Lo ez -'-- 8 --------- ----- --- 046 - MN/lh:... Trucks -------- - - -� -------- lab_ ------043 KW /Dump Trucks � --------- - II ----- {---- I ' --- .------ Water truck ------_ - --- -- r- - -- - - - - L - -----_- - --- -- - - CorWact_--- - ... - ------ --- -I I Days Used WeaUter Da pa-� 6ttrs Work Days Remsfn Days I' - Toch _ Total - l _ , Signature AFtH-Diary All CITY OF RIVERSIDE DAILY Page t of t CONSTRUCTION REPORT 12/31/2007 Monde Project # 6522 SEWER PIPELINE CAPACITY IMPROV Contractor Hrs., Start 0700hrs Stop 1530hrs Contractor Traffic Garcia Juarez Construction Normal , Location spring Garden St_ / E. La Cadena Weather Ctear Subcontractor --------�--.� Inspector Art Hernandez Humld" `-- Da Shift: On duty: 0700 t0 1530hrs.) Low i ��� irEMl Temp AM 44F NUMBER Temp PI6f 70F WORK PERFORMED ------ -- Spring Gardens St - -.__._-14-__- a Excavated and backfill with +/- 1'- of base material and recon acted around MH -3 Com action test for this work re uires 95%, test endin at this time _ ---_--- . MH -4 --- -- 33 b Ud'usted Manhole Covers to existing rade at MH -3. M1-1-4 22 c Be an trenching for installation of 2 lateral lines at So. 10+00 E. La Cadens 14 Excavated and backfill with +/- 1- of base material and recon acted around MH -1 33 Com action test for this work requires 95%, test pending at this time b Ud'usted Manhole Covers to existing rade at MH -1 NOTES: 1- 0900hrs. Reported the work in progress to Sean Gill Div. Public Works one hone conversation. _ 2- Photos taken today, in file. - WPPP Contractor observi regulations at this time - -------------- TRAFFIC CONTROL COMM S: AM.Placed constructlon signs PM Removed Construction signs ---- -_ EQUIP ■ -__ DESCRIPTION._....-__ _-- 93 F350 1 ton u 8 PERSONNEL - -- - - ----- CLASSIFICATION --!q1500 3/4 toms `Rud Navarez ►i0UR3 - "-__-310SE J_Deer /Backhoe 8 €Jesus Ordones 4man/-off Turbo 4X4 -- 8 Cesar Ulises lab _6 J,Deer / Front Loader- - --- —. --_ (Jesus Lopez - 8 ope_ ---- 5 _Cat /Excavator - --- r-- - - ----- ...... 43 KW / pun Trucks. - 046------------ _ .' - .-- - KW r Trucks --- --• - - - - - -- Days UseJ Extra Wak payn- Ramainlnp paYB " offal --- _ . ----- ------' -- --- --- - --- -------- - ._ Signahire ---. °rt! !_DEarr A,1 9 CITY OF RIVERSIDE vAILY Page tot 1 CONSTRUCTION REPORT 1/1112008 Frida Protect # 6522 SEWER PIPELINE CAPACIT77UiE! contractor Hrs.: Start 0:00 Stop 0:00 Contractor Garcia Juarez ConstruNormal Location rin Garden St _ Part! cloudySubcontractorInspector Art Hernandez Day Shift: (1 hr) ___ Low coNTROuINGITEMfT NUMBER - I emp PM 66F WORK PERFORMED ii3pring Gardens St. iContractor did not work today,No activities observed. -. NCTE3: - ---- -- - -------------- - - -- — — - ..._.... revised correspondence and forwarded e- re ce' eq -receied copy of the approved submital �! 2�m made a copy for` -- - j - --- ---- -- — —.—.— ---- � - TRAFFIC CONTROL COMMENTS: ArtH_Diary 01-11-08 Page of CITY OF RIVERSIDE DAILY 1 t CONSTRUCTION REPORT 01!10/2008 through 01/11/X008 Protect i/fi522 SEWER PIPELINE CAPACI Thursday and Friday Contractor Garcia Juarez Construction TY IMPROVEMENTS Start 20h00 -�- Stop 05h00 Location AM Traft-Li ht -- La Cadenza Dr., Spring Garden S g pM Traffic. Light Subcontractor L, Columbia Ave. an I' "th"I Clear Cloud d Palma Rita Ave. Cloudy Still Moderate Rain Inspector Anthony B. Allen (On duty 20h50 to OSh00) ' High CONTROLLING ITEM Humidity LowNUMBModerate: High WORAM Temp 38 .pM Temp 42 The Contractor set out traffic control after a late start due ►° an accident PERFORMED D intersection yy The Contractor continued with the road Crossingat of Columbia and E. La Cadena Roads. the temporary five sewer crossingi Station 15+11.06 on Columbia pipes. Ave. by placing the rings for the manhole and The Contractor backfilled and compacted around the manhole and placed temporary AC Significant Conversation: - The Inspector and the Contractor disaissed the placing of the laterals on Spring Garden and the fute ur . terals to he placed. 1/14)2()08 : 11:26 AM Jan -10 through Jan.1 l.xls Additional Equip. J/D Broom Tractor (0hg JfDeer .5�oc-Back Hoe 157) (Oh). Trench whacker (Oh). Comact P or (2h). 10 Wheeler Traffic signals were set to flashing all red in the intersections TRAFFIC; CONTROL �WENI'3: Dump Truck # 41 (71(98 a Netted by operations in order to create EQUIP # a -----^ronment. safer world DESCRIPnoN_ 93 BH 31 3tOD JoAn _._.._.t)eerBackAoe ___. -_ HOURS € _ -- PERSONNEL Lie Sq tH J/D FrorN End loader --- ----.-_-€- `- -'- 6 Ruben Mendoza --CLASSIFlCAT►ON -._-- -- ---.-- _-- HOURS EX13 - - 235 CAT Excavator . - - ----. eJ�Lopez ----- ForemaryO -96}7497-- 9CF -- -------�-DumpTrOck---... ------------- - ---0 `Jaime --- - - - -- Ascencp -- - -- -- Laborer 8K59677 Crey� - - Wb Pickup - r�Fb--- --__,-_ —__- Flatbed Service Picku .. p 1 - .. Valdez i -- - - - -- _- —�- 33434 - - - - - - - Ub - - 1rtyPkikii -�-- - 1 ----- �-_Lahore'-- n 487189 tnge►s Rand Lighting plant --_- _ _ __.. __ _ _ .. _- - nd ro Nuhee _ _ - - ___---- - . _ _= Operator - WT 06 Ford Water Tnick fa�N . - --'- $--_-S-I*1 P 1Iec. -- 544E John Deer Front End Loader 0 -lR Brissenp --- -- -- SJ 19884 - t 0 yyneeler Dump Truck -- -1 HOnOdO ROperator - - _— E)(12- 235 CAT Excava-- ---� tor/CwnPactor _ 0 i Jew 1!1R laborer cimbact oeUsetll weatfbr--� ys --0 - 'EduardoR Laborer�� 8 a -_-- - --'g -----pays ExtraWftDaYm R _ DY+ Laborer. ° low - -- ---�� ---'-'. _ �� ice' �• 1/14)2()08 : 11:26 AM Jan -10 through Jan.1 l.xls CITY OF RIVERSIDE DAILY Page 1101`1 CONSTRUCTION REPORT 1 /10/2008 Thursday Project Contr# 6522 SEWER PIPELINE CAPACITY IMPROVEMENT actor Hrs.: Start 0;00 Contractor -"- - - Stop 0;00 Garcia Juarez Construction �Treltic Normal Location---------_.�-- S rin Garden St. Weather Partly cloudy Subcontractor ---- Inspector Art. Hemande2 Da Shift: ( 0700 ;o 1000hrs. _ Num/d/f Low CnrrTROLLIN(31TEM � - --- NUMBErt Temp AM qqF Temp PM 66F WORK PERFORMED - Spring Gardens 3t. 22 a) No activities observed---_-_- ----------- tv:.TES: --- --- Conlra 0835hrs. received a did not w_-- ork today, I had aPhone conversation with J. Jackson of GJC, Jackson ex lained that _ has not received a royals et and will wait until found out what the cit want him to do. He I called Public Works En D.Simmons to let him know. Simmons ex lained to me ihat the a _ delivere_ d lacy ni hg t - n-__—_ - - - royals were hand 2-1300hrs_ J. Jac- - kson returned the call I m 5hrs. and told me the are not Goingback to work until He fi _ _with the city how to make the lateral connections, Jackson said He will let me know In advance. _ 3- 1 revised cofres ondence and forwarded e-mails fin out - - - - - -p-- ---- - DESCRIPTION TRAFFIC CONTROL COMMENTS: ArtH Diary of -10-08 CITY OF RIVERSIDE DAILY Page 1 °f 1 CONSTRUCTION REPORT 01/09/2008 through 01/10/2008 Project 06522 SEWER PIPELINE CAPACITY IMPROVEMENTS Wednesday and Thursday Start 20h�_ . Stop Contractor Garcia Juarez Construction AM Tia tfiC Light 05h00 �- Location Subcontractor La Cadenza Dr„ S g prin Garden SL, Columbia Ave- and Palma Rita Weetht3f Clear PM Traflk Light Cloudy Rain Inspector Avo• Wind Still Moderate High 8-G59077 Anthony B- Allen (On duty 20h50 to 05h00) 'Hum#id' Y Low Moderate cowlaoux+cnt;tt ""'"'ER : 'AMTemp! 36 High ' PM Ternp • ----- WORK PERFORMED The Contractor set _ Q ..Rand Lighting Plant 40 WT -U6- out traffic control. — -544E John Deer Front End Loader The Contractor continued with the road crossing SJ19884 10 Wheeler Dump Tnrdr - ---1 -_ at Station 15+11.06 on Columbia Ave. the mankole in the centre of the road. by excavating and casting the ; _ 0 footi n9 for The Contractor set double plates, pegged them down and placed temp. AC wedging over the excavation. The Inspector checked on the plates during the next day and all was well. Significant Conversation: The Contractor was issued a correction notice for catch basins that were not in conformanceand for not sub enter each significan! rain. - miffing impact reports Additional Equip, J/D Broom Tractor (0h). J/Deer 51 CC Back Hoe Compactor (Oh), 10 Wheeler Dump Truck # 4 157) (ph). Trench whacker (0b). . - -... 1 (�_ K98 Traffic signals were set to flashing an red in the inte TRAFFIC CONTROL Cp�fiT S. ------...- ,- �10ns affected by operations in order to create a safer working environment EQUIP it DESCRIPTION -s BH 31 31 OD John Deer Backhoe HOURS L16 .544H J/D Front End Pipe Loader- e EX13 .235 CAT Excavator 0 _. - - ......Wheeler -Dump -Trude--- --------------- - -3 ---- 8-G59077 Crew Cab Pickup -- - - - - -- -- - 4Z09112 Fla - _ tbed Service Pickup - - - -- 6X534:+4 -- unity Pickup ----- 487189. _ Q ..Rand Lighting Plant 0 WT -U6- - ;Ford Water Tnick--- — -544E John Deer Front End Loader -- SJ19884 10 Wheeler Dump Tnrdr - ---1 -_ EX12 235 CAT Excavator/Com cwt ; _ _ Contract T_-.�----_-_—_-----c 0 - Days Used i � -1—�� a=-- �-- ��L_ Extra Wk Days ureirt�y=Fi= 1/14/2008: 11:29 AM 93 _ _ _ PERSONNEL- CLASSIFICgTjpN rDen Mendoza- - - -- - -- HOURS Lopez -s aime A_ sce_ncio Laborer ---- - 0 ----- ----- Laborer Tye Valdez Laborer - ----------- � 8 1000 Pacheco — -- LabO•"� -- 0 - - .— ejundro Nuhez tor =-- --�_ g _ e must Pu ---- _ Laborer 0 - anon Brisseno _Laborer_' 8 norio R O for -�-- 0 - an Rodriquez -- -- borer _8 R -alining Days Jan.09 through Jan.10_xls CITY OF RIVERSIDE DAILY Page t of t CONSTRUCTION REPORT 1!4/2008 Wensda Project # 6522 SEWER PIPELINE CAPACITY IMPROVEMENTSactor Hrs.:I Start 0:00Stop 0:00 Contractor Garcia Juarez Construction TrattSc Normal Location Subcontractor S ring Garden St. Weather _ Partly cloudy Inspector Art Hernandez Day Shift: 0700 to 1100hrs.) Humidlt Low CONTROLLING ITEM Tempqu 44F-" - NUMBER Temp PM 66F WORK PERFORMED -- Spring Gardens St. —--------- 22 ia1 No activities observed --- - --- -- ------ NGTES: _ — -- 1- Contractor did not work today, l hada Phone conversation with J. Jackson of GJC, Jackson said H care of all a rovals toda and continue with the work tomorrow I e was oin to lake Latter in the da I met Simmons we went over the the a called Public Works Eng- D.Simmons to let him know. vols and the rocedures of installation ------------- ------------- TRAFFIC CONTROL COMMENTS: AftH Diary 01-08-08 CITY OF RIVERSIDE DAILY Page 1 °f ' CONSTRUCTION REPORT 01!0812008 through 01/09/2008 Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Tuesday and Wednesday Start 20hSlop Contractor Garcia Juarez Construction _p0 — 05h00 AM Trefric Light — Location La Cadenza Dr., Spring Garden SL, Columbia pti{ Traffic " - ' -- fbC Light WeB�� Clear Ave. and Palma Rita Ave_ Subcontractor Cloudy Rain lend Inspector Anthony B. Allen (On duty 20h50 to 05h00) _ Still Moderate High HrJmidiiy Low Moderate' corrmottu�rlryl r+uueER High SAM Temp 35 WORK PERFORMED PA4 Tamp 45 The Contractor took a while to set out traffic control as they were V working in two locations_ The Contractor continued with the road crossing at Station 15+11.06 on Columbia Ave. from Three jo�ds were placed one 2' and two 6', backfilled and compacted. - the centre tine to the pavement e_ doe. and temporary AC. placed as a cap. The Contractor pressure tested the 12" line on Columbia Ave and both legs of the line passed. -- '-- ;The Contractor removed and replaced a two foot section of pipe_ on East La Cadena Ave. The Contractor re p sure tested the fine and it - ---- - passed. Significant Conversation:- - Additional Equip: J%D groom Tractor (1 h)- J/Deer 510C Back Hoe Compactor 157) (0h). Trench whacker (0h). — -(2h). 10 Wheeler Dump Truck # 41 (7K98 Traffic signals 9 were set to flashing all red in the intersections �� C5` ' a�� -- - -- - -- _ -___ affected by operations in order to — ---�-- create a safer working environment- nvironmentEQUIP EQUIP# DESCRIPTION 93 HOUg BRS H 31 310D John Deer Backhoe - -- RS PERSONNEL --- --- -- L16 : S34H J!D FrorK End Pi _g — u� za Pipe Loader HOURS CI HOUR EX13 _235 CAT Excavator - t ---Jesus Lopez Faema B - 9817417 0 Jaime Ascenci--' _ 10 Wheeler Dump Truck - --------- Laborer 0 - 8K59677 ---- ___— _ .. _ 3 David Flores Crew Cab Pickup Laborer o 4ZO9112 Fla - - _ - - -- (Gorge Valdez -- Ibed Serv" Pickup _ _ -- --_.. 6X53434 _ _ Laborer g Laborer _1.. _- do t_ Paeheoo- - [Jhldy Picku - __ _ _... P... - _ _ -. .. -. ... - - - - -• -- t — 487189 _,►nger;o1-Rend Lighting Plant -- ---€ undro Nuhez - = Operator 8 Laborer - ----- iSarrrueFPk Vi(T 06.._ Water g - _... - ---- - - -- nLoader - ---0 -- B 5EJohn Deer —-i Laborer g - ._.. -- - - - 5 H 5J1 imxxb R _ 9884 to Wheeler Dump Tnrdk O rator g DC12 235 CAT ------- - -- Jesus Rodriquez Excavator/Com Laborer 0 0 'Eduardo Eduardo RDays IDaYs Used i Laborer g s Wbrk Days r D" - - -- T - -- --- rc - l/ S)gnature 1/14/2008: 11:30 AM Jan.08 through Jan.09_xds CITY OF RIVERSIDE iYAILY P.190 t -- z CONSTRUCTION REPORT Contractor Hrs.: Project # 6522, SEWER PIPELINE CAPACITY IMPROVEMENTS Start 0700hrs Stop 1530hr Contractor Garcia Juarez Construction Traffic Normal Location------��- 5 rin Garden St. Weather Partly cloudy Subcontractor __. - - Inspector Art Hernandez Day Shift: (0700 to 1530hrs.) Humidi -- CONTROLLING ITEM Low NUMBER Temp AM 44F Temp PM 66F Spring Gardens St. WORK PERFORMED 22 a) Contractor excavated -- R14+66 and RI 83, bored 6" holes in the new 24" main line for the installation of s _. saddle were not installed and no connections were made toda . . -.._.or -- - -- ---- - -_ ..._ __.- ---- i - - ----- --_ addles, 'tor More detailed information -------- See here attached a record of lateral connections - - b) Covered the trenches with i" steel plates and covered the edges with AC ------- b) - - - -- C) Clean up street- -- -- - - - - - NOTES: - _-------- -- ------- —_ .. 1- 0945 r' - Received a co of submital # 27 from GJC and found that the submital has not been Public Works, This includes all materials for the installation of 'Lateral Connections" which was oved b I was adviced b�Public Works En . D Simmons to slo the work in violation until a rovals are obt -- - --- s m ro ress. I informed Jim Smith with GJC and field foreman Ru alned b G,IC _- given to GJ_C for the record Navarez of the situation, in addition a Correction Notices was 2- Co_n_tractor was given various Correction Notices todayas follow: _— - - .- a) Su_bmttal # 27 not approved at this time, Relates for all materials used for lateral connections. r -- b Need a rovals for materials integrated on Roadway work, s ecificall at this time CBA c Im ro er work hours, GJC has shown LIto work after ask in for time off. c Contractor has used Band Seals Rubber Couplers) for lateral and havR hog., TRAFFIC CONTRUI" COMMENTS: AM Placed construction signs AnH Diary 01-08-08 PM Removed Construction EQUIP # DESCRIPTION x ..:_ - signs - - HOURS _ F350 1 ton u t PERSONNEL F :!-;.z C15003/4 ton u g •`R Navarez CLASSIFICATION HOURS 3105E J.Deer / Backhoe Turbo 4X4 8 `Jesus Ordones 4man/0 8 544E8 J.Deer/ Front Loader !Cesar Ulises lab 8 04 046o _ . .... _ . KW / Dum Trucks e. . - 8 lab — 8 AnH Diary 01-08-08 CITY OF RIVERSIDE DAILY Page 1 of 1 CONSTRUCTION REPORT Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Contractor Garcia Juarez Construction Location La Cadenza Dr., Spring P g Garden St, Columbia Ave. and Palma Rita Ave Subcontractor Inspector Anthony B. Allen (On duty 20h50 to 05hOD) CONrROUNG rUM I . NUMBER The Contractor set out traffic control. WORK PERFORMED 01!0712008 through 01108/2008 Monday and Tuesday Start 20h00-- Stop 05h00 AM Traffic Light PM Tra/fK Light Weather Clear Cloudy Rain Wind Still Moderate High Humidity. Low trod®rate High AM Temp 38 PM Temp' 46 The Contractor continued with the road crossing at Station 15+11.06 from the left side ry ACu Three jnints were placed, backfilled and compacted and temporaP to the centre line. P . placed as a cap. The Contractor pressure tested the 12" fine on Columbia Ave and both legs of the line passed_ Signifreant Conversation: - The Contractors representative and the Inspector agreed that there is a st-I duct in the trench. Equipment and Possible extra work of 0.5 ho _.__... Personal Urs due to an unmarked 2' were agreed upon. _. Additional Equip: J/D groom Tractor (1 h)_ J/Doer 510C B 157) (ph). Trench whacker (Oh). ack Hoe Com actor 2h . (_ ) 10 Wheeler Dump Truck # 41 (7K98 Traffic Signals were set to flashing all red in the interne TRAFFIC CAROL COMMENM - _ .- -------- _ coons affected by operations in order to create a safer working environment. EQUIP # 111412008: 11:31 AM 93 ._.-_- PERSONNEL DESCRIPTION - en Mendoza BH 31HOURS OD John Deer Backhoe is Lopez . _--_- = e_ 544H J/D ---- rord End Pipe Loader oLift31 Rut E)(13 235 CAT Excavator -- ---iJest est Laborer Truck_-.-_-- --- - 6Pecheco LabOf� --`-- -- -T_ BK59677 --e Crew Cab Pickup , 4ZO9112 - Flatbed S ----' _erwcePidcup 1 ` - - 6X53434 ------- --------� _} Utility pickup _ .. do Ak aser —�- ---- _ ;Adod iAlqu 487189 - ---- -- --- 2Frsc4-Rand L!?hIlg Plant -- - _1 - I WT -06 Laborer 8 _ _ :544E John Deer Front End Loader -�O �`Ranx 5J19884- - _1D Wheeler Dump Trude 4 ----`- `R -- _ EX12 -- 235 CAT Excav - ator/Compactor - 0 Contract- r -- 0 "DoU9I Davei ter. used I -Daus 1 1Mprk Days tToday 111412008: 11:31 AM 93 ._.-_- PERSONNEL - en Mendoza CLASSIFICATION -- ---. _ HOURS is Lopez . _--_- Forerna pilerator ----- e_ ieAscencio - - - - -Labor r _ -0 �---- -- d Flores --__e - e Valdez Laborer - g - --- - 6Pecheco LabOf� --`-- -- -T_ 0 '_Mro Nuhez - - -Operator �el --- 0 n Brisseno Laborer e -- do Ak aser —�- ---- _ Operator 0 Rodriquez ------ Laborer 0_ ludo" -_---- Laborer a Jan.07 through Jan -08.b, CITY OF RIVERSIDE DAILY Page 1 of 2 CONSTRUCTION REPORT 1/712008 Monde Project # 6522 SEWER PIPELINE CAPACITY IMPROVEMENT Contractor Hrs.: Start 0700hrs Contractor -" - Stop 1530hrs Garcia Juarez Construction Traffic Normal Location .Subcontractor Spring Garden St. Weather Pa 11Y cloud Inspector Art Hemandez Day Shift: ( 0700 to 1530hrs,) Humldit Low �+TrauNc fTEh► NUMBER Temp AM 44F Spring Gardens St. Temp PM 66F WORK PERFORMED _. _.._.__.._ =a Contractor Ii sn tailed sa— s to the new 24" main line and made lateral tonne ' —r Z—.—_ - d dle -___,see here attached a record Of lateral connections for more detailed information ctlons at 4 locations on the Ri ht side _ ——'Backfilled lateral trenches with +/ 3 of Gravel for beddin , fill u the trench in lifts with CB with tem ra--- — _ ry AC tom acted and cove c Clean up street NOTES: -- 11- 0830hrs. Asked contractor to etch u I2- 1130nrs. Reported the work in of holes on the Ter !3- Called,l Smith with Garcia -Juarez and ro Duested con a so. Smith said will send the co ies with the field foreman by tomo ums D Simmons on site observed some of the work in QAC at t E__La PW Eng.) on I gaved Simmons hard copies of diaries. TRAFFIC CONTROL COMMENTS: AM Placed construction signs PM Removed Con EQUIP O �"OURS __...---- ..0Onst ucll0n signs DESCRIPTION 331t1C F350 �tnn = PERSONNEL f - C1500 3iRudY Navare7 CLA =wc 'J. Deer /Backhoe Turbo 4X4 =-cous vrcones-8------ 8 `Cesar Ulises 8 544E J Deer /Front Loader lab 046 Jesus—Lopez o Trcks e = Vakrez .. ..._ ._. _ - [ O 8 f , ArtH Diary 01-07-08 CITY OF RIVERSIDE DAILY Page t of 1 CONSTRUCTION REPORT 01!06/2008 through 0110712008 Pr°lett Thursday and Friday #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Start 20h00 -_^ Stop 05h00 Contractor Garcia Juarez Construction AM Traffic Light PM Traffic Light Location La Cadenza Dr., Spring Garden St, Columbia Ave_ and Palma Rita Ave. Weather Clear Cloudy Rain Subcontractor Wind Still Moderate High Inspector Anthony B. AllenOn du Humidity Low Moderate OLL1NG tfEA/! ( duty 20h50 to 04h30) - Me t _ _ High C�NrR NUMBER 'AM Temp 38 PMTemP 45 WORK PERFORMED • •- The Contractor requested and was granted a rain day. 1/14/2008: 11.32 AM Jan -06 through Jan.07.)ds ;Significant Conversation:- -- .. .. Additional Equip. J/D groom Tractor (Oh)_ J/Deer 510C Back Hoe Comp 157) (0h). Trench whr (0h). acke ... -- (Oh). 10 Wheeler Dump Truck # 41 (7 K98 Traffic signals were set to Bashi all _. n9 red in the intersections TRIC CONTROL COMMENTS: . affected by operations in=der 10create a_- safer environment. working EQUIP tr DESCRIPTION 93 - BH 31 _ 3100 John Deer Backhoe' __ -------- HOURS PERSONNEL - - _ - - -- -- --- L16 544H J/D Front End pi Loader-- €Ruben Mendoza --- ---- ----- _ _ICATK)N ForernaNOperator __..._. HOURS EX13 235 CAT Excavator ---- - —_Jesus Lopez - ---- 0 �--- 9817417 -_- 10 Wheeler Dura__ --- --- -- 0 :Jaime o -- Laborer - - ---- - -- _ U BK59677 -PSrurJ�-----_--_--O-�FDavidFbres Crew Cab Pickup - p '--- ___------Lat_wrer-------- - 0 -- 4ZD9112 Service Prdku Valdez Laborer -0 _6X53434 - _Flatbed ---� -- Llblity Pickup _ �---,-{Addfo Pacheco .... borer ---------- ` -- 0 487189 - - - - - - - €AleLurWro Nuhez - 0 WT 06 _�n9e!solRandLf�h" Plant ----- Ford Water Truck - 0 i --_-__._----- Samuel..P_ucheco. _ Laborer _ — 0 - - - -- 544E John Deer F nt_End_Loadec 0 Ramon Brisseno - -- -- - - _Laborer-- 0 SJ19884 _ - D . .Roserxb - 10 Wheeler Dump Trude - - - --- = --fir -_ -- ' EX12 235 CAT E _ xcavator/Compactor ----- 0Jesus Rodrigw•� - --- - �bo�-__--0- _ 7--- �— COntract I Days , WeaUret 0 `Doug Burlow Operator ._ Used r Exba W -*Days 0 Remain" Daysda -- - - - ... -- - - / ✓� Oma/ 1/14/2008: 11.32 AM Jan -06 through Jan.07.)ds r .J qq A > ^ ; IONS a z N ur O u (; N O •N O u 1.0 -.1- .. O N 'O - N O CIO CIQ z v✓ o s G ' > N r it �V* A-1. -23 _ s► o T o � M� �e Ar y V _ N -� Q N s in is N N . O ASl . A .� • �' ' • - - � .. Le. .. � APs � • —S �—P ��,�.1i'v r�►Y� 1.\�� „(�elly ��`�v �,tiv '� A1��11�� `.• ,o � �� Page Project CITY OF RIVERSIDE DAILY 1 of 1 CONSTRUCTION REPORT x6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Contractor Garcia Juarez Construction Location La Cadenza Dr., Spring P g Garden SL, Columbia Ave. and Palma Rita Ave. Subcontractor Inspector Anthony B. Allen (On duty 20h50 to 05h00) CONIMLLWGITEm; . . NU►IBErt _ WORK PERFORMED The Contractor set out traffic control. 01/17/2008 through 0-111812008 Thursday and Friday Start 2 D0 Stop 05h00 _Pn� AM Trafl;c Light Traffic Light WeaUler- I Clear Cloudy Rain Wind -. Still Moderate High Humidity : Low Moderate; High AM Temp 40 .PM Temp 42 The Contractor removed the temporary AC and the top six to seven inches of base and re -compacted the remaining base Slone in the remaining trench area of E. La Cadena Road r4r-rthwards and SOuthwrds. The Contractor placed varying depths of six too seven inches of permanent AC and compacted it - Temperatures of road surface and materials were acceptable and work proceeded well. The Contractor paced a total of 81.89 tons between stations 17+25 too 17+70 and 10+20 and 13+40 E. La Cadina Roads. Significant Conversation:- Contractor onversation: Contractor was reminded again to keepthe operation Gose as temperatures -ire low_ The Contractorworked speedly with each load. Additional Equip- J/D Broom Tractor RB -3 (1h). J/Deer 51 OC B (7K98157) (Oh). Trench whack41 ck aHoe Compactor (ph), 10 Wheeler Dum Truck _ �er (Oh). Mikasa trench compactor #98186 (8h). CAT 910 Front End Loader Traffic signals were -set to flashing an red in the inter COlfTRtX COfkMENTS: --- _ - - - intersections affected by operations in order to create a safer world ng environmenL EQUIP # DESCRIPTION e BH 31 319D John Deer Backhoe _ HOURS Lis _544H J/D Front End Pipe Loader . --- - EX13 235-- CAT Excavator -- 3 _ -- -- - - - ----- o Pacheco laborer - OK59677 C.ew Cab Pickup ---- -- 4Z(Y 112 'Flatbed Service Pickup— "X34 UbOty Pickup - . 487189 k!9ersot Rand -------- -----WT-06. WT-06. -- Ford Water Truclk----- -- -- - 1 514EJohnpeerFron4End Loader 5,119884 _ 1D Wheeler pump Tnxic — IX12 _ 235 -_ -_3 CAT Excavatodcom 2 D vveamer Days Used Days ` Extra Work Days T -- 1/22/2008 :11:35 AM 83 —PERSONNEL - CLASSIFICA-nON ben Mendoza =-- HOURS Fon arvo Rarnakft Day, Laborer B Laborer B ------------ Laborer ---Laborer r� i Sigrrdture Jan. 17 through Jan. I8AS � e - Laborer - - 0 - --Laborer -- - -- - -- 1 -Foxes --- --- ----------- e Valdez Laborer 8- -- -- - - - ----- o Pacheco laborer 0 Operat. 9 - -- let Ptrcheco - ----- Laborer_. - -- —i-0 Rarnakft Day, Laborer B Laborer B ------------ Laborer ---Laborer r� i Sigrrdture Jan. 17 through Jan. I8AS CITY OF RIVERSIDE DAILY P-)ge 1 of 2 CONSTRUCTION REPORT 1/18/2008 Frida Project Contractor Contractor Hrs.: tt 6522, SEWER PIPELINE CAPACITY IMPROVEMENTS Start - Traffic 0:00 Stop 0:00 Garcia Juarez Construction a Normal -- ---- --- Location Spring Garden St. weather _ ----.-Clear — Subcontractor Inspector Art Hernandez Day Shift- (1hr) Humld/t Low COHrnowPlG ITEM Temp AM 42F—j Temp PM 60F NUMBER WORK PERFORMED — -- Spring Gardens St. Contractor didnot work today,No activities observed. -- -- - - - -- — -- ,NOTES: _ -- -- - --- - - ----------------- ----- - ---- 1- Field conditions remain as before 27Revised correspondence and forwarded e-mails I3- Stop at Riverside CPublic Works Office and bring hard copies of diaries for D.Simmons. —_ ---- ----------------- L— TRAFFIC CONTROL COMMENTS_ a —ywwue ArtH Diary01-18-08 CITY OF RIVERSIDE DAILY 1 of I CONSTRUCTION REPORT 01r16/2008 through 01r1712008 Project 96522 SEWER PIPELINE CAPACITY IMPROVEMENTS Wednesday and Thursday Start 20h00 Stop 05h00 Conlruclor Garcia Juarez Construction AM TralYG Light PM Traffic Light Location La Cadenza Dr., Spring Garden St., Columbia Ave- and Palma Weather • Clear Cloudy Rain Suhconlrarlor Rita Ave- Wind Still Moderate High Inspector Anthony B. Allen (On duty 20h50 to 05h00) Humidity i Low Moderate- High h CONTITEM HOURS Foreman/ Operator AM TemPINUMBER 42 PM e mp_ 44 - - WORK PERFORMED -- - 0 -- -- :Jai 70 Wheeler me Ascencio - - - _ ' �- BK59677 rhe Contractor set out traffic control. - 4209112 rhe Contractor removed the temporary AC and the top six to seven inches of base and re -compacted the remaining base_ stone in the remaining trench area of Columbia Ave. and the intersection Of Columbia and E. la Cadena Roads. The Contractor placed varying depths of six too seven inches of permanent AC and compacted it from station 11+07100 15+30 on Columbia Ave_ Temperatures of road surface and materials were acceptable. Significant Conversation: - 2/112008: 10:43 AM Signature Jan 16 through Jan 17.xis :Additions! Equip_ J/D Broom Tractor RB -3 0 h). J/Deer 510C Back Hoe Compactor (0h). 10 Wheeler Dump Truck # 41 !(7K98157) (0h). Trench whacker (oh)_ Mikasa trench compactor #98186 (8h) CAT 910 Front End Loader Traffic signals were set to Dashing COMMENTS:-' all red in the intersections affected d bCoM� ---_ -.__ Y in order to create a safer working -Aerations environmenL EQUIP 9 I DESCRIPTION 93 _ BH 31 _ _-- ----HOURS PERSONNEL ,310D John Deer Backhoe "- '.- CLASSIFICATION _ L16 -- =Ruben Mendoza ;544H J/D Front End Pipe Loader — — _ - - - - --- HOURS Foreman/ Operator _ EX13 - _ .. _ _ -- - -- .235 CAT Excavator 3 'Jesus Lopez ' - - - 967717 -- - 0 -- -- :Jai 70 Wheeler me Ascencio - - - _ tatstsr�r--------8--- -- BK59677 - - - -----r 2 iDavid Flexes — - (Crew Cab Pickup -- ` -- - - 4209112 - (Flatbed Saborer - ' --• --- I 1 - ;Gorge Valdez ervice Pickup € - - -- -- . _ - 8 Laborer - - 6X53434 . _ - - --- 1 `-Adolfo Pacheco -~ "Utility Pickup----- - _ ------�0_.. 487189 _ -----' 1 --_- `! Ie dro Nuhez Ingersol-Rand Lighting Plant -'-'--''- - Aerator 8 - - WT 06 8 ;Samuel Pucheco - ---._..._ Ford Water Truck i - - - � --r- 0 _ . ---- 1 '-RanwnBrisseno - 544E John Deer Front End LoaderLaborer - --- -- _ _ - -- -- 5J19884 - - 0 `Honono R - .10 Wheeler Dump Truk - - - - - ---- --�- - 0 EX12 - 2 ^Jesus Rodriquez - 235 CAT ExcavatodCompador -; - - - Laborer 8 Laborer_ -- - Contract-_._�_•r 0 _Jose Luis Vusquez - j Weather D Days Used L Days Extra Work Days--) -- - R_ . - - - - emalnkng Days __ 6 Laborer - -- ---- e Today- I + ----- - Total.7 2/112008: 10:43 AM Signature Jan 16 through Jan 17.xis CITY OF RIVERSIDE DAILY Page 1 of 2 CONSTRUCTION REPORT 1/17/2008 Thursday Project# 6522 SEWER PIPELINE CAPACITY IMPROVEMENTSContractor Hrs.: Start 0:00 Stop 0:00 ContractorTraffic Garcia Juarez Construction Normal Location Spring Garden St. weather Clear Subcontractor Inspector Art.Hemandez Day Shift: (1hr) Num/dl Low ContaoWN0 1TE�d� Temp AM 42F Temp PM 60F NUMBER WORK PERFORMED Spring Gardens St. Contractor did not work today, No activities observed. NOTES- i1- Field conditions remain as before _ 2- Revised correspondence and forwarded e-mails 3- Find here attached a letter on the installation of Lateral Connections addresed to D. Simmons TRAFFIC CONTROL COMMENTS: An)- Diary 01-17-08 CITY OF RIVERSIDE DAILY Page , of 1 CONSTRUCTION REPORT Project *6522 SEWER PIPELINE CAPACITY IMPROV E•-•ENTS Contractor Garcia Juarez Construction Location La Cadenza Dr_, Spring Garden St, Columbia Ave. and Palma Rita Ave. Subcontractor Inspector Anthony B. Allen (On duty 19h50 to 05hoo) CoirrROUWG Marl NUUWR The Contractor set out traffic control. WORK PERFORMED 01/15/2008 through 0111612008 Tuesday and Wednesday Start 20h— o- p IAM Stop 04h30 Trafflc.Light PM Traffic Light Weather Clear Cloudy Rain Wind _ Still Moderate High 'Humidity._ Low Moderate, High AM TemP- 43 IPM Temp ; 46 The Contractor removed the temporary AC and the top six to seven inches of base and re -compacted the remaining base stone_ The density of the base was tested and obtained 97% The Contractor placed varying depths of six too seven inches of permanent AC and compacted it from station 11+ Columbia Ave. Temperatures of road surface and materials were acceptable. p 07 too 15+30 on .Significant Conversation:- Additional onversation:Additional Equip. J/D Broom Tractor RB -3 (1h). J/Deer 510C B - - -- — — -`- _ (7K9815 Back Hoe Compactor (0h). 10 Wheeler Dump Tract # 41 T). (Oh). Trench whacker (Dh). Mihasa trench CONTROL (8h)_ CAT 910 Front End Loader - - Traffic signals were set to flashing all red in the interseclions affected o&"E)iTS --_—. by operations in order to create a safer working environment EQUIP v DESCRIPTION 8K59677 - .. HOURS BH 31 -.. 310D John Deet Baddioe_ - - -- ---- L18 '544H J!D_Fnmt End Pipe Loader ------- - -- • -- 487189 _ 3 EX13 235 CAT Excavator - 8 - -_ - -_- 544E John -Deer Front End Loader-- - 8 TOW 1/22/2008:11:39 AM 93 CLASSIFICATION uben Mendoza - HOURS mus Lopez Forernan/operator e - umeAecericlo -- Laborer ; 0 Valdez Laborer La8 Pachew------- Laborer, morn Nuhez 8K59677 Crew Cab Pick ----- -- -- 1 - -4Z09112 - - - Flatbed Se(vice Pickup - - --- - - -- ---- 6X53434 Uti61y Pickup • -- 487189 • _.— InRand Rand L'ghting Ptant -•- - - 1 WT706- Lam 8 - -_ - -_- 544E John -Deer Front End Loader-- - 8 _ 919884 -- -10 Wheeler Dump Tnrck 0 EX 12 - _ .. _ 235 CAT --�-- .. Excavator/Compacior -- 0 CorrEraG —yy-=T RYS U D�--�- �w► — '. Extre YIRNtk Do" TOW 1/22/2008:11:39 AM 93 CLASSIFICATION uben Mendoza - HOURS mus Lopez Forernan/operator e - umeAecericlo -- Laborer ; 0 Valdez Laborer La8 Pachew------- Laborer, morn Nuhez Wel----- Pucheco Labor 0- on Brisseno �borer e -_ xio R - Aerator - s Rodriquez Laborer e Luis Vasquez --- Lam 8 - Laborer 8 Rema" Days Jam 15 through Jan.16.xis CITY OF RIVERSIDE DAILY P;r9e tot 1 CONSTRUCTION REPORT 1/16/2008 Wensda Pro ectContractor Hrs.: Start 0:00 # 6522 SEWER PIPELINE CAPACITY IMPROVEMENTS - SLOP o:oo Contractor Garcia Juarez Construction Traffic Normal Location Spring _Part Garden St. Weather __._ly cloudy Subcontractor Inspector Art Hernandez Day Shift. (1 hr) Humidit -- P_Low_ CONIROWNG ITEM _Temp AM NUMBER 44F-ITempPM 70F -—L . .. WORK PERFORMED L_ spring Gardens St. Contractor did not work today, No activities observed - NOTES: - - - -- --- - - 1._ Field conditions remain as before --k2 evised correspondence and forwarded e-mails - - ----------- TRAFFIC CONTROL COMMENTS: ARH_Diary 01-16-W CITY OF RIVERSIDE DAILY Page 1 of 1 CONSTRUCTION REPORT Project #6522 SEWER PIPELINE CAPACITY IMPROVEMENTS Contractor Garcia Juarez Construction Location La Cadenza Dr., Spring Garden SL, Columbia Ave. and Palma Rita Ave. Subcontractor Inspector Anthony B. Allen (On duty 19h50 to 05h00) cONTRaLNG ITEM NUMBER q WORK PERFORMED The Contractor set out traffic control. The Contractor removed the top loot of materials and placed base materials from Station 15+11.06 on Columbia Ave. back towards E. La Cadena Ave. The Contractor compacted the trench and placed temporary AC. Significant Conversation: Additional Equip: J/D Broom Tractor (0h). J/Deer 51 OC Back Hoe Compactor (Oh)_ 10 Wheeler Dump Truck # 41 (71<98 :157) (0h). Trench whacker (5h). TRAFFIC CONTROL CONME W - - - Traffic signals were set to flashing all red in the intersections attested by operations in order to create a safer working environment. EQUIP # 01114/2008 through 0111512008 HOURS Monday and Tuesday Start 20h00 Stop 03h00 AM Trams Light PM Traffic Light Weather Clear Cloudy Rain Wind Still Moderate High Humidity Low Moderate' High AM Temp 42 QPM Temp 45 The Contractor removed the top loot of materials and placed base materials from Station 15+11.06 on Columbia Ave. back towards E. La Cadena Ave. The Contractor compacted the trench and placed temporary AC. Significant Conversation: Additional Equip: J/D Broom Tractor (0h). J/Deer 51 OC Back Hoe Compactor (Oh)_ 10 Wheeler Dump Truck # 41 (71<98 :157) (0h). Trench whacker (5h). TRAFFIC CONTROL CONME W - - - Traffic signals were set to flashing all red in the intersections attested by operations in order to create a safer working environment. EQUIP # ----- - DESCRIPTION93 — HOURS BH 31 --------- - 310D John Deer Backhoe — - ti _ - PERSONNEL - -- ---- ------ — CLASSIFICATION HOURS Ruben Mendoza L18 544H J/D FroM End Pie Loader 0 -1 — EJesus Lopez Foremanloperator 7 EX13 235 CAT Fxrava�r - - : - - -- -- - - -- Laborer jJa—Ascencio 9817417-10 - - --• - - WtrMWmDu p Truth--- ---- ------ ----- - --- -----taboret----_-- 7 --- • - 2 Flores --- - 8K59677 —Crew Cab Pickup �€David 1 Laborer 7 _ 4Z09112 .----- Flatbed Service Pickup -- -- -- Laborer 0 6(53434 _-IVa !1W Pick 1 Adolfo Pacheco Operator-- - 487189 ---pig Rand Lighting Plant 1 _ _._Alejundro Nuhez — - - - Laborer - 0 WT -06 Ford Water Trudc 7 ------ FSamuel - — Laborer -- _ 0 `Ramon Brisseno --- =544�John DeerFiortt End Loader ' E— 5J19884 '10 Wheeler DumpTrodc Honor►o R �— i Labxxw -- — 2 `Jesus Roxfrique ---- EX72 _235 CAT Fxcavator/Compactor 0 _ ------ Eduardo R Contract -f — - •••--•-- - n— i Days used _ -TO�. Total 1/22/2008 : 11:39 AM Extra Work Days RemaMV Deva -- Laborer 0 Jan- 14 through Jan.15.)ds TRAFFIC TRAFFIC CONTROL- COMMENTS: - EQUIP Ann Diary 01-15-08 CITY OF RIVERSIDE DAILY F':ache 1 of f CONSTRUCTION REPORT 1/15/2008 Tuesda Protect Contractor Hrs.: K 5522 SEWER PIPELINE CAPACITY Start — 0:00 Stop 0;00 Contractor IMPROVEMENTS Traffic Garcia Juarez Construction -- ---- ---Normal Locabon Spring Garden St. Weather - Part) cloud --- - Y --_ Y_- Subcontractor Inspector Art Hernandez Day Shift: (I hr) Humid! Low_ CONTROtuNOITEM Temp AM 44F Temp NUMBER WORK PERFORMED PM 70F Spring Gardens St. Contractor did not work today. No activities observed. -- - — - -- 1. NOTES: 1-_ Drove around the job site, "Steel Plates Ahead" signs were in - — place 2- Revised correspondence and forwarded — e-mails �------- --- TRAFFIC TRAFFIC CONTROL- COMMENTS: - EQUIP Ann Diary 01-15-08 CITY OF RIVERSIDE DAILY Page 1 of t CONSTRUCTION REPORT Project NGS22 SEWER PIPELINE CAPACITY IMPROVEMENTS Contractor Garcia Juarez Construction Location La Cadenza Dr_, Spring Garden SL, Columbia Ave_ and Palma Rita Ave. Subcontractor Inspector Anthony B. Allen (On duty 20h50 to 05ho0) coNmoWNG trot NUMBER WORK PERFORMED The Contractor set out traffic control. 01/1312008 through 0111412008 Monday and Tuesday Start 20h00 Slop 03h00 AM TrafflC Light PM TrBf is Light t Weather Clear Cloudy Rain Wind Still Moderate High Humidity Low Moderate High AM Temp 40 �PM Temp 43 The Contractor continued with the road crossing at Station 15+11.06 on Columbia Ave. by placing three six foot and two two foot Joints up tc the manhole joining the steel encased section_ The Contractor backfilled and compacted the trench and placed temporary AC. 1 - significant Conversation: - Additional Equip. J/D Broom Tractor (0h). J/Deer 510C Back Hoe Compactor (2h). 10 Wheeler .157) (0h). Trench whacker (0h). Dump Truck # 41 (7K98 _ -_ -- - , • Traffic signals were set to flashing all red in theTRAFFIC intersections affected CONTROL COMMENTS: by operations in order to create a safer working environmenL ---- - -------- EQUIP # DESCRIPTION � - --------- HOURS -- L16 544H J/D Front End Pipe Loader — T D IX13 235 CAT Excavator ; — ____._-_Wheelerm—Tr�cc>< — — — ----- - -- 0 ---- RK5967-7 Crew Cab Pickup -- --- 4Z09112 --- Flatbed Service pickup - - 6X59,34 Jbl' Picku - - ---- 487189 - IngersoLRand t fighting Plant 8 YVT-06 — Fkxd Water Tnxik- -_ - - Laborer 0 esus Rodriquez 'S44EJohnq—Froit loader 5J 19884 _10 Wheeler Dump Truck 0-- duardo R -- -- CAT Eavator/Compactor - 2 — --- -235 0 Tont 1/1412008: 11:24 AM Days Used i W -a i Extra Work Days 93 PERSONNEL -�� CLASSIFICA --- ---- - =N- - J (OURS-._ Ruben Mendoza — --- Jesus Lopez --- -- --- F2TTaNOperator B " lake Asceno - - - -- -- - 0 ci �vra mores -- - . --� Sorge Valdez 8..---- tdafo.PacJteco .. ---- - — ,- - -- T- 0 Uejundro Nuhez -- - >amuel Pt checa _.. ------ ---- Laborer ------ 0 - ---- Laborer tamon Brisseno - - - - — -- bnorio R - - -Operator - -0 -- - -- - - - Laborer g esus Rodriquez Laborer--- 0-- duardo R -- . — --- .,-- Laborer, p. Remaining Days I' Jan -13 through Jan. 14 -As CITY OF RIVERSIDE DAILY Poge 1 of 1 CONSTRUCTION REPORT 1/14/2008 Monde Project Contractor Hrs : Start 0:00 I # 6522 SEWER PIPELINE CAPACITY IMPROVEMENTS 1 Stop 0:00 Contractor Traffic Normal Garcia Juarez Construction ----------- Location Weather Partl cloud Spring Garden St. ---- ---y Subcontractor _ Inspector Art Hernandez Day Shift: (1 hr) Humldi -- _Low coNTR°tLING ITEM I Temp AM 44F Tramp PM 66F NUMBER WORK PERFORMED (Spring Gardens St. ;Contractor did not work today, No activities observed. :NOTES: — (1_ I revised corresEgndence and forwarded e-mails 2-1 made a_call _to_GJC, talk to Jim Jackson, Jim said that He has send some paper work for approval on how to make his _ lateral connections, and soon as He get some answers they will to back to work He said He'll let me know. Just to make sure nom was out there 1 called the field for and He said He was in Anaheim -.. r-- -... ----.-- TRAFFIC CONTROL COMMENTS: ...y..o..a o ArtH_Diary 01-14-08 X a v U) 0 0 J 0 U W IL U) Z n O N W Q Q U Q a a a a a a a a O N O O O O m O m 0 m O m O F- ri Ul Ul O J 2 O O O O O O O O O O O O O O O O O O O O O O O O O O O O Z ro Z K 0 0 N 0 N 0 N no O 0 O 0 O 0 N 1 Z J a' O O O O O O O O O O O O O O O O O O O O O O O O O O O O Z 0 0 rn 0 0 0 0 0 0 U mI C z no 0 0 0 0 0 0 0 Z J - J K 0 0 O O O O O O O •- '- �- O N Z N N O O N N O O O � Z J J a' 0 0 Z a r r o n o N m n o in rn or � Q p oo N n o0 S a n N Q m 0 t7 m 0 O 0 N 0 N 0 � N m N N m N N F- U d .- � - N � � C 1 O �e - Z J 0 0 0 o o o 0 0 0 0 0 o o. - Z a r r r r O r O m X U ? K 0 ry N N r N 0 O N m N O O m C N N Q m N > U n N Z' p '- N n O m O r _ J > O J cc � � o o � � � .- ;' o o .- � � �n O o 0 0 o N J Z D� O m O O N m O O p O N N O O O O F- U 1 Z� — Q) n J 0 0 0 0 0 O O O O -N M 0 0 0 0 � Z � r n n r O 10 7 zJ U F -Z n a y Z 0 aZ n0•- m0K�- 0eN (Q7 o OwmFo 0 a 0� 0 o O of N O o� 0 0 0 O O O 0 .- W UZ0 0O W a Q Q W K W F- o W a' 1- W K W F- W a' W F- W a' W H W K W i- W K w 0 F- W m 0 5 m `3 0 0 5 0 m 3 0 0 5 0 m 3 0 5 m 3 2 0 5 0 m 3 0 0 5 0 3' o 05ED 0 3 N f - O m W N N N p N N N p N 0 3 J K O O O O O O O O O O O O O O O O O O O O O O O O O O O p O z r Z C�zz 0 N 0 N 0 N 0 p 0 p W N 7 1 » O o- o o o Z J J K O O O O O O O O O O O O O O O O O O O O O O O O O O O O O Z 0 0 m o r N O r O 0 0 O 0 O 0 O 0 O 0 N U O m m N N N N z J Z n r O N m O O rl m 0. O O O O O N_ .- Z J Z r 0 0 r o m m p n O N N N N O p ry N N � •- n m m c� m <n r Q m •- o 0 Z OJ 0 J Cl r N Q O O O O O N Z n y N r 00 N r O t7 n O O O O O X W OI m N N O N OI O p O d ? � a Z J 0 0 0 Q. Z p0 N m O (7 m n O O O N n - O O O r J O O O O � N `� N O O O O O N n z r 0 no- 0 0 0 0 o m 0 N cc 0 0 0 0 0 0 f U N N N C Q 1 z J U cr < O K r 4 0 m > r 0 0 t 0 0 m 0 F 00 r t a w r o K O Z o K 0 m 0 ¢: O �n O K O n U K O W U rn 0 N Z g K m H W W' W m F W K W m 1-- W W m (-- W R' m F W "' m F W K �1 pUp F W o g° `3 0 5 3 o g 3 0 3 3 0 3 3 0 g 3 0 5 3 X U U) 0 O J O U W a U) z rn rn r 0 N w Q Q U Q N X a U E0 V O J O U w a U) z m _rn O N w Q _Q U Q O J J D O 0 O 0 3 0 N 3 cn cc 3 3 p 0 co3 J of O O O 0 0 0 0 O O O O Z pN Z Z 2 O D a O C O w v N N ? } Z J p o Z Z o O Z Q Q VJ J C Z m m F- w QC po cQc G p G H K N O O W w m w 0F g - LL 0 n 0 0 O O O Zo 0 w w w w J O O O z a- d d O Z w w w J $ o Z z z Q N Q m m N m m N O O O O LL U O J J J F - p Z J m m O O O F- F- F Z m 0 m 00 = d N N n C N m m O Z J J O O O O Z o � m 0 m 00 U _ m N i Z J Z m O m W w N 1 Z J J O O O O Z m Z p t4 N v m N Q Q N 1 � Z J z a Z a Z O a U rn 00w Z o w 0 U Z K aw O J O m� m Fa- w w m Fa- w a m ~O 0���05� �0E- 3 3 N X a U E0 V O J O U w a U) z m _rn O N w Q _Q U Q O tlJ/UQ/Z008 11:27 9516P"-410 BCTC 11 1 PAGE 06/07 f A RlilWWRaj Rl%-TR.WJV Q .. - -1 CONTUCX. BY WT tAi 10ADI 4 AV -t I.AlM.-RU N. .6 7 11 12 IS ,t4 16 TI 22- 23 RPSOLT,-MISN.a OF -TI-W, . - CITY - or TIE :CITY OF Oq A-U--Pst 14,.2007,- CAYUMUCA awarded -BUNo_6-V2 to GDxC!jjumez ram for lbp maxtso�#04 Qt*z .j --A � .13 , .rt Q4Unibfa er p6jDAD,.0 4ptilylibm Olid tn -ro 207, the 124 •aud Gjr_ entered into, that GuyL tfb r Fist AgFeen= w $e yet pipelipe _apa-c4 Impruwmept t.od hlWvx#a-Avquue-Yipellne Capacity hW.DVMLmt cmd Ila.W"UA3mW0mpj-ov4=ws WnaaNO, GICfAitp-dto tt=bUi3d W ivalts W V%qjc( * good 4�otWAtocl r�moft- bytho Ilubrm WeAs materialitsUs Po0PTm=ma pipe 000traut 93 W. laoPA'Aft Omnv goc ok-the flomm. u oa�,4 matl-Qz And V,AS„ c6ropleboli -ethe jed in.a. iknefy iftWofk c'-Ug:41 to mWlo.bij* pobliq ag- Pi'vflb.vdjes;t& iu lhoaegipftand Etre czdst6gv sewermay.ex=d. hgAW 4qtet3r. W e acid OTI&L (q4ma whrse.-;tlm *'COO COW= atw W Ap"i 6rlpfimfiou of ,ftd 23--a-4 03/04/2008 11:27 951E 410 BCTC PAGE 07/07 .2 {aii£�1L9y ag:follev�ss: - ' 1; Kin #>a'isn s" ££# tin r� i a1s. rind gi Eiauat ty kc farf# it the eitY . i�Ltt�il $Irl ibizi co�C ti bg C h-Watttt . itis htAY hued and deP ed tintmin Joure2 ' az�sir�icticorir ; r pater-uAQs id-lbe AgremwA foij ttie•EastLa Cadanu Drive, Spring Ga do 5 3neet, olumbis i errnm $aureC 1?ipE mr 4C�pot¢ityImpm-y�mmeut, and paint 4venUe Ei�lin� 21C�jy t4ve��t ���ppluay.�riu �vemie �eti>�(iC ��� �•�� te�t� A)DQ? by-thv-Ql;y C`gUiii rich Y�; XVI 16 17 zi 22 'p.- -24 25 26• r.- 230-52 .Ildaivi�; 03/04/2008 11:27 9516' 410 BCTC PAGE 03/07 Casty- Council Memotandum.' p••�•• ry..q�in.nMNM4�hr+�a..w.oArrl+�w�A.r..:/wnwrwwuu 7C. IC�IMUF�&BLE 1fA{IC�.F ANS OtTlf CO(J�1IL bAi E; Maxair 4, 2Cio8 Mom: O*u-.JC'.G ':I I~3�P�RT.MEN t` i7��i.IJ4t 23a V,yJ�D.:• 1 t%UB-JFM-. CI1`ti URFti?. ► i'1+M `fEFtMit A7 EaAkm aamez— `R� t Tl fit PERFORlUii!kTRACT'. -BlOr ND S LAST- LL11]EA}�1 DRIVE! V*A.Cya-C,Am.—�VS7M1 FM-.CZ']Lu�JE3�Ai+��E��i�� �.€�#P1�+Gl 'IM`MOVOMOhir, Attb PM AitYRi A #VENU15- �t_t CPA lTY )Ov M:� ANS# 'ALIyTM`i'�l iGEV17LP�R7`Oit±EN7P#a.;`cT PU3SANT�Dt�[ ON ISSUE ' Tf1e �iie fcrr Citi CotJnesfoolFisideratron isvutie`t#terfo teri�i�ate S3a�ia :JtiarQ� Cnii�t�sn'�' ��JC} erfgltr?artr of" sx�nfi;t:Wdrsunt art rt iAijgu5t :f-; 2 7 [ILrYitie'iy C.burici iwa1ded �(si.6s�ta,e1Ct0: 0 strULlU1- .East La: tUdenaOr"ke.,'$piir,qe."ard ie-siiea: -(�i�trtb�al•1ve�;te',.�.a1m�LArp�li�e:•iGapa�iiy 1t�csY�[rt�ent;�nd �Img►•�it�;�vEn�a Pi�ine rvagaUfil Irnprdi-a it aim fayhylot'a Me►1�',i�rou�rp�iri� P�j�ct RMMODATlirti� 'fat, thy. Ci�r �auncr'f: AN��Ei�tjtetet�ii�a>i��ir►.oiG.IG'$Perf$rtriaaFe.o�.t�'G�t}t��t �3i�IJ�r:$�`�,j�:at>�f�� �m+7th•�reeribook S�ebap €�.4;:a�i�#. ' ' 2.AdD if a l e�rcirl3vn a�itftoriz?rr� a r►jhativ of i�JE's'pel or tt Ee o�TContmo---sid :.6W.2� li as4.w CA404 Drive, $009 C_am-ah ei: CONIMN4 AVW4 $e*O :PiOR1.6 C40ach IM.pi6vgMent:, and Pai><ny0ta AvenUo Pipeline Cdpacity Imfrrt mb tion tarid Palrriyrita Avenue "Pipv6wnts:proie pursuanfto qro"b.Quk teatTah &A AA6MD t71ti .k1�ie 22, s"tile: eriteie�i irtfri•• aft a�r'esttient �NiEh •tile. •Coilrrkji �� RiueY�ida. tt� jarYiir(d�•. i��te"fer:treutttteit s� 6'm- ft#Iia-tigm-- Ve idmc! 3i�jr_'.,�t0u gNft. AgW.ew,". Itto pump. •tre'atr r i .•the.:.6-o lia4tedf o fat Qft ieV;W ���r *h i>�i mged otr "rrr4. klaa Rivlkirsfde'yvArotwitY pprifii�l IksAiRsukPOrT&%r) - DepPlt n eoti' I eifC it o a. stu 1 4;if 's a t te>stii in l [star jsj€i sa f� at mine the need f4 Y saPa Y impkgeiaeii-�vii- eNdfingdjiTFuhk-Sew� 3lUdT(SfU8Yj The SWyideilffied4ne-ed4raddif'rdpai catxa�ity •- . 03/64/2008 11:27 9516' -410 BCTC PAGE 04/87 0ii"AuqUg 9•:412007; th,6.City awarded .Bid No.. -652.2 J¢..Gj.0 this, prbjecL The m.en6 Term ft-llbn orw.* b!s-pommanbe of the u5nimid pursuaritto ierrdhata. wrift" wfi ;S(�Q)a on Illowrety, UnclQr-,tho q 'the a7, �he.qp�cp t . b.as, _m�'MptrqaM Perform the w6rk 5ho4lo the Wrpty not ass M... pl A u e.cohtr vKh.th,gy.e... 4 H to -yrr pr lip l iiom The OMM gmunds f6r. d4fatilt-terMi ..nalion,of ■ IMPrRPOf OTTION izatIPTI and abamdgoeiRt or" Woykjjpr.oDe!mq U r Filum to remoRze ted, re-qRthq prOJ6!M 'Irt. gool.."foif . agerea te 0 ft�p., requests icy.the rid Rib w6w-SM a P Alp Tha fbilowl.mg t1mollm-INwof Gis.4tit>tir failure or W to -aid 4*4?%)b 'phita aw. rip sqbwdtMqomWem peegspaW.or Kgoe d. on thgpraj t; ■ F aiMj*tp PMVi09 gersAruie) game end t?Iasif_rtic9rt for Gei#ift>rdyrciQ hig"MW MOM W lt*.p4wb, W400 DPPqft,*fi IM -We �",mf OOM-ed- PayWl op6jq% ftem from l f fn t4ytnoll of a haseft5 cetnsirgction zc je; repeiAedj(e.gt�qj t6 proizre :an updated onr>tmct]Qn sthedule weLiWas reqiAWI W the r,-OrffP ict; and Ju0bah4 custs for- Sewer redosign isaimes anti refusal to a,rja.TnaWaj*toM% v, P.eftm Vork'o-I a lifte !O.Pro wa !or o v req 0 q Praymftn Plan (,15WMP.) Ar - BJWP-s:- ID ■ -FolumIq maintaln mquireAfrg") may; ■ FQUrsio pr",.qwM mq= rieAq o pp.oved mo.t0al wbMON14. Unq js cq4Tjo Ica t4 use Tmptbp er t wqcceptiabte Matefof hOt 4 VecMed M the -(gbjed; E-rror*ousTt.,que0B* TOO- ef.ddWonal rOattrials fbf Woa dod ftmfeflMev-w.6rk k Aeu of prtivious, pe-Mlm. ".rk Wth the Nppl f.opre*�W:aiWes pye&e:nt 0 lv'lhmiJ under !he the rego is -,Aqudmffq riiUT Irb n by 8 16.teas 016 *&joO& in m- part 23ii�`2 03/04/2008 11:27 951( A113 BCTC eywe -I PAGE 05/07 re,Wfted ih riumet64delayt3ileopardL,-in,g other *. PyGjiects-sndpraduoingrelated fta§aNa ihipacts. Efflorl of the prajoct:by a1w mean$ is crib sl. Pates McL MeWe se -r 1p,ezed 'I -e ba-rtdj& •-�be 'S BE (19B )AM.:;bp1�6 -0i on - mpg* tlf:.thp, e4s0rjg:..PWmy*a Av e wei* malt Va Ith F U. M.' fAtYissues assaclated-Wttt aI) - elbzintbhd rbnsMfbrfah SItA Ohd, Ofier; eqMipffient i4nd mRtbjomy jdt Mill calft axcm5a" Rs, a*[Va, Prqj�cls of il k in. the grAp inotu#0 fb� joLwa ;Street 0 Ila d .Nt� bTnr .0ol. m r4 M. lKa Is pr* _p M.4 IR ct prm- bou -2 is 64 -pt rid * wofte m avid pff ramp. OWIRLIM.S, Crowimfiod twboUft.- Wg LW gn.d jA pjaMed-to CQimq e d _v.ygh.qpjp1Tww. .ay Thff oifRIFF0, praipa wt_.OSflrmt q* W93 $30JU5 0 , In4iding pn$jhqtrihg, (?Rn*.U!gjq.n, apat causlruoon majiRgemant. Gj(;V not-WL-exqe Wiltm mAqnitpn p! 5r4lqp NyE j§$2,p37,3 .0. AROr ltlftiftallor� GJC IA onfitl6d by -paymenl for -apprrbwd 41jawlis ijf *Qi k IrIstalwilt legEi- ddiwjge,s .ca4w_dby'C;J-C, fth3gal' M"ct OA0fftki0hu the, thee cines Mriporpse Of QV9-p)Wcma noe boW. sqrety-, -ptdpwd of Npd-4,: PaIJF .4NT RpRtQ VIII -P, 'eJ J, pt Oy mj : AApwv,,0A �§ tkx- )ft, -Pve9oYy.A P6 moo. 0 0 Atto4v_-V 211a--:3- 03/04/2008 11:27 951E 410 BCTC PAGE 02/07 DATE: 214-08 ITEM NO.: 7a W—WRANDUM FROM THS CATV ATTORNEY CONCERNING A GL08ED :SE$SION DEt=ORE• THE -CITY COUNCIL OF THE CITY OF PJVEW$IDE TO:.- Honorable Nlaypr arra Members of-the-City.Couricil FROM: Greggry P. Priamps, Ciiy Attorney SLIBJEGi losad a ion�/� cipated'Ltigatioi� C verr�nresntCode 54)56gfb}MM Name of-Claimant(a): Garda JuarAz COnstructron., lne. v Clty-6f Riverside Claim No.: 0"2-21 A closed session will be held on March 4, 2008, for the purpose of conferring With mgl1pr receiving advice from your I�1 counsel concemirig anficipsted litigation. Besedupon•the i�eceipEb a cleini pursuant tq the Tort Clat"sms:AQt. anri the WOW of. its.legal coun_-eti the City Council believes ihecg is significant exposure to litfgetim [Gouemtropj Code §5490.9(b)(Q If the City Council sulllgri s the City Attorney to ¢sfenr#, or seek tyr refrain frpm sQsic[n� 00611 411a review or retfet,: this determirt�rtlein sh$tibe rcPorted in ppan session at the pupl'�c mestir: d4ring witioh.tf'te; Cls��ert sesslotl is held. tf the City Cs�ungl auih9rizas initiatrr�n or intewen idn; such ei.ithorjzatSc5t1.heli also !�e r pottiJd artd thb putttic dviSed mat �et�on, d of ►d rjfs:®fid Esther pa. cglar may ba. inclosed upon regUe�t.efferthe tlbn is forfie.ElY cornmei7c0d. '(Cao rnrrteni Cpde Bb7,1aX2�I If the.City Council acceptt a set#Iomwt offersigned by the opposing payty, the zub stanoe of the settlement shall bo reported at -the public rrleeting during which the clod sesslan Is -held. [Gaverrnrrtertt Corp W-W.1(a)(3)(A)% - AW shall inc[Lkge the vote orabstentlon of each member_ Dated: 'February 29, 2008. Frepar&d b"y.; • Gr oc y P,'Pd6jMos . City Attome}t •. .. -. '.. - cl:lrycomlVJPCloos�}p�9�p90.81�DttA40Dl?,doo : . . 7a 1 2 3 4 �5 6 7 8 9 12 .13 14 7 15 16 17 _, t8 19 20 21. 22 -23 2d 25. 26 27 LEGRAND H. CLEGG II, CITY ATTORNEY CRAIG J. CORN -WELL. CHIEF DEPUTY CITY ATTORNEY (SBN 173327) EDWARD M. CHAVEZ, DEPUTY CITY ATTORNEY (SBN 146I33) FILE -D ANITA 0. AVILES, DEPUTY CITY ATTORNEY (SBN 167173) t-oS ANGELlyS sl,r�lil�rz cuURr 205 S. Willowbrook Avenue Compton, California 90220 Telephone: (310) 605-5582 FEB 13 Z007 / Facsimile: (310) 763-0895 JOHN A. CLnriKE, CLERK Attorneys for Defendant, E' -I ONVVELL. CITY OF COMPTON EIBYF. DEPU7v x'.10G SUPERIOR COURT OF THE STATE OF CALIFORNIA -- FOR THE COUNTY OF LOS ANGELES —SOUTH CENTRAL DISTRICT GARCIA JUAREZ CONSTRUCTION, INC.,) ��/� Plaintiff, ) Case No.: TC 020649 f-�V 7 5p 0 } Assigned to Hon. Josh M. Fredricks, Dept_ .A CITY OF COMPTON and DOES 1 through [Exempt from Filing Fees; Govt. Code-§. 6103] 100; inclusive, CROSS-COMPLAINT ION :BE_ HALF- OF Defendants_ CITY OF COMPTON FOR, - .. ) (-I)-Breach of Written Contract; (2)_Breach of Implied Covenant of .Good Faith and Fair.Dealing . CITY OF COMPTON, a municipal ) corporation; } Cross -Complainant, V. GARCIA JUAREZ CONSTRUCTION, :INC.; and ROES I through 20, Inclusive, ) Cioss-Defendants. ) , ) Cross -Complainant, City of Compton, a Municipal Corporation, alleges -as.follows: 211111 CROSS-COMPLAINT OF THE CITY OF COMPTON 11 2 3 4 I 5 6 8, 9 .12 13 14 Is 16 17 18 19 20 -21 22 23 -24 25 26 27 28 GENERAL ALLEGATIONS 1. Cross -Complainant, the City of Compton, (hereinafter referred to as "Cross - Complainant' or "City") is now, and at all times mentioned in this Cross -Complaint was, a municipal corporation, organized and existing under the laws of the State of California, with its principal place of business in Los Angeles County, California. 2. Cross -Defendant, Garcia Juarez Construction, tnc. (hereinafter referred to as "Cross - Defendant' or "Garcia Juarez"), is now, and at all times mentioned in this Cross -Complaint was, a corporation,.organized and existing under the laws of the State. of California, with its principal place of business in Orange County, California. 3. Cross -Complainant does not know the true names of Cross -Defendant$ ROES 1 through 20, inclusive, and therefore sues -these Cross -Defendants by their fictitious names. Each of the, fictitiously named Cross -Defendants is in some manner responsible, either in contract or tort, for the claims alleged herein and damages and injuries suffered by Cross -Complainant as alleged herein. Cross-Cornplainant will allege by amendment the true names, capacities and relationships of ROES -l. through 20 when ascertained by Cross -Complainant. 4. Cross -Complainant is informed and believes, and on the.basis of that information and belief alleges, that at all times mentioned in the Cross -Complaint, the named Cross -Defendants, unnamed persons and entities and ROES 1 through 20 were the agents; employees, representatives and co-conspirators of their co -cross-defendants, and in doing the things alleged in this Cross -Complaint were acting within the course and scope of that agency, employment, representation and - conspiracy - 2 CROSS-COMPLAINT OF THE CITY OF COMPTON i 2 3 4� I 5 I, 6 I 7 I 8 9 10 II 13 14 15 16 IT 18 19 20. 21 22 23 24 25 26 27 28 5. Wherever appearing in this Cross -Complaint, each and every reference to Cross - Defendants and to any of them, is intended to be and shall be a reference to all Cross -Defendants hereto, and to each of them, named and unnamed, including all fictitiously named Cross - Defendants, unless said reference is otherwise specifically qualified. INTRODUCTION 6. The City was incorporated in 1888 and operates under state constitutional plenary powers of its Charter. The City of Compton covers roughly ten square miles. A population of approximately 95,835 inhabits the City. Water service is provided to the City's residents through a distribution system made up of 160 miles of pipe. 7. The.City is within the service area of the Metropolitan Water District of.Southern California C'MWD"). In or about October of 2000, the MWD received. a $45 million grant from the California Department of Water Resources to be used for groundwater storage projects within its, service area $. Some of the City's water system has been in place -for over 80 years. Given the age 'of Portions of its water distribution system and thepotential of funding assistance from. the MWD; the City began to Consider, upgrading portions of its system in a manner that would coincide with the MWD's grant requirements. 9. After developing a general proposal, the City submitted it proposal to the MWD for consideration. The MWD selected the City's proposal and agreed to fund the proposal. In, early January of 2005, the City entered into a Groundwater Storage Program Funding Agreement with the MWD (hereinafter referred to as the "Grant"). 3 CROSS-COMPLAINT OF THE CITY OF COMPTON 10. Under the terms of the Grant, the MWD agreed to reimburse the City and pay for the proposed facilities in an amount not to exceed $2,428,900. Various condition, however, were set 3 forth in the Grant. Specifically, the Grant requires that the City must assure that "Completion of 4 the Facilities occurs not later than September 30, 2008." The Grant also states that "under no s condition may the Completion Date exceed September 30, 2008, or the total budget exceeds the 6 7 specified amount allocated as Program Funds unless such overages. shall be the responsibility of s the Program Agency." The Grant money in this case will serve as a reimbursement. 9 11. The City will, pay the upfront costs associated with the work done on the project. If the 14 City is able to meet the conditions set forth in the Grant, then the MWD will reimburse the City. 12 12. In order to implement its Grant proposal, the City retained the services of Willdan. 13 Willdan is an engineering services firm with vast experience in the design of public construction ` 14 projects. Willdan proceeded to design the project specifications: 15 13. The overall plan that Willdan developed for the project consisted of a phased construction 16 project. The first and most critical phase was and is the Tucker Street water distribution pipeline - 17 - . I8-- and well discharge main project. 19 14.. In or about June of 2006 Willdan finalized the plans for the. project and assisted Kambiz 211 Shoghi, the City of Compton's Water Department General Manager in. preparing the bid 21 _. documents. Soon thereafter the project was put out.for competitive bid. 22 23 15. The bid documents included the construction drawings (plans) and specifications for the 24. project. On June 29, 2006, the bids were opened and another contractor was the lowest bidder. 25 26 27 4 28 CROSS-COMPLAINT OF THE CITY OF COMPTON 2 3 4 s 6 7 8 9 10 1► 12 13 14 15 16 1.7 18 I,y 20 21 22 23 24 25 26 27 28 This contractor was unable to provide the required bonding, so the contract was awarded to the next lowest bidder, Garcia Juarez. 16. On or about September 19, 2006, an "Agreement between the City of Compton and Garcia Juaez Construction Company" was entered (hereinafter referred to as the "Agreement"). A true and correct copy of the Agreement is attached hereto as Exhibit A. 17. Under the express terms of the contract, the Contractor was top erform, in a professional manner, all the required tasks. necessary for the: "CONSTRUCTION OF TUCKER STREET WATER DISTRIBUTION PIPELINE AND WELL DISCHARGE MAIN" as more fully outlined in the CITY's Contract Documents and Specifications for Construction of Tucker Street Water Distribution Pipeline and Well Discharge Main package, dated June 2006, attached hereto and incorporated hereby. (Agreement, Para. 1) The contract documents and specifications were also incorporated by reference by Agreement, Paragraph 20. In addition, the Contractor ageed :to "perform all the said work and furnish all the saidlahor and materials at its own cost and. expense as are necessary to complete in a good worker -like and substantial manner and to the satisfaction of the CITY, the work herein set forth." (Agreement, Para. 1) Moreover; Garcia Juarez agreed as follows: CONTRACTOR agrees to be responsible for furnishing all saidlabor, materials, equipment, tools and services; furnishing and removing, tools and equipment, and doing everything required by the Agreement; and for completing the work in accordance with the requirements of this Agreement. (Agreement, Para. 1) Fi CROSS-COMPLAINT OF THE CITY OF COMPTON 1 3 4 5 6 7 .. R 9 10 12 13 14- 1.5 16 17 18 -19 20 21 22 23 24 25 26 27 29 18. Under the terms of the Agreement, the Contractor was to be paid on a lump sum basis. ghat lump sum amount was 5745,244.00; the low -bid amount submitted by the Contractor. Agreement, Para. 2) The Agreement provided the following: The total lump sum price paid the CONTRACTOR will include compensation for all work, including travel and equipment. No additional compe4sation will be paid to the CONTRACTOR, unless there is a change in the scope of the work or the scope of the project. In the instance of a - change in the scope of work or the scope of the project, adjustment to the total lump sum compensation will, be negotiated between the CONTRACTOR'and the CITY. Adjustment in the total lump sum compensation will not be effective until authorized and approved by the CITY. (Agreement, Para. 2)' 19. The Contractor'sservices were to commence within ten, calendar, days after receipt of the Notice-to-Procced from the .CITY'. (See, Agreement, Para. 3) All work included in the contract was to be completed within sixty (60) days of the Notice -to -Proceed, unless the Agreement was terminated sooner. See A Bement- Para 3 The_Agreement contans_language. that_` -`time -is -of-- - -- - gr __ ). the essence," which states, in pertinent part: Time is of the essence of this Contract.and it is agreed that it would be impracticable or extremely difficult to ascertain the extent of actual loss or damage, which the CITY will sustain by reason of any delay in the performance of this Agreement. Itis therefore agreed that the 6 CROSS-COMPLAINT OF TIIE CITY OF COMPTON I CONTRACTOR will pay as liquidated damages to the CITY the following 2 sum: Seven Hundred Fifty Dollars ($750.00) for each days delay beyond 3 the time therein prescribed for finishing the work. If liquidated damages are a" not paid, as designated by the CITY, the CITY may deduct the amount s from any money due or that may become due the CONTRACTOR under 7 this Agreement in addition to any other remedy available to the CITY. s (See, Agreement, Para. 5) 9 20. Plaintiffwas aware from the outset that the work being undertaken in this contract -was of TO critical importance to the City.. Section 1-4.2.2.of the specifications stated: 1T 12 The construction schedule shall be in the form of a tabulation, Gantt chart, 13 or graph and shall be in sufficient detail to show the chronological 14 relationship.of all activities of.the.project including, but no:(sic) limited to, _ 15 estimated starting and;comple.tion dates of.various activities; -submittal of .kb shop drawings. to the Engineer for approval-,procureme 17 nt of materials, and Ts scheduling of equipment: The construction schedule shall reflect i9 -completion of all work -under the Contract within -the specified time and in 20 accordance with these specifications. The water distributionp�P i eline will 21 transfer the existing water supply, service connections from -the existing 22 23 Midland Trust company to. the :City of Compton Water Department. Timely 24 completion is therefore of a critical nature_ If the Contractor is behind his 25 26 27 - 7 2s CROSS-COMPLAINT OF THE CITY OF COMPTON I schedule, he must work additional hours at no additional cost to the City to 2 meet the schedule. (Emphasis added.) 3 (Agreement, Section 1-4.2.2) The term "Engineer" was defined in Section 1-2(b) to mean 4 the General Manager of the Municipal Water Department or his authorized representatives. 5 (Agreement, Section 1-2(b)) 6 21. In addition, the main body of the Agreement contains a termination provision which 8 reads: 9 Notwithstanding any other. provisions of this. Agreement, this Agreement to may be terminated. if- 12 12 A. If the. CONTRACTOR . persistently disregards laws ordinances, 73 rules, regulations-or orders of any public authority having 14 jurisdiction, or otherwise if guilty of a substantial violation of any 15 proylsion.ofthis Agreement, the 16 n, the CITY may, without prejudice to any right or remedy and after r glv ing;the CONTRACTOR and his surety, if any, seven (7) days written notice, terminate the _.Iv_. employment of the-CONTRACTOR. 20 B. If CONTRACTOR or the CITY fails to perform any material 21 obligation under this Agreement, then-in addition to any other �2 23 remedies, the.CITY or CONTRACTOR. may terminate. this . 24 Agreement immediately upon written notice. (Emphasis.added.) 25 (Agreement, Para. 14) 26 27 28 8 CROSS-COMPLAINT OF THE CITY OF COMPTON 3 4 5 6 22. On September 21, 2006, a Pre -Construction Meeting took place_ Those in attendance were Kambiz Shoghi (City of Compton Water Department General Manager), Martin Murquhart (City of Compton Water Department), Vince Damasse (Willdan), Mike Bustos (Willdan), Jack Perieh (Willdan) and Jim Jackson (Garcia Juarez Construction). At the Pre -Construction meeting, it was made clear to Garcia Juarez that Willdan was acting as the City's Engineer on the 7 project. Garcia Juarez was also instructed by the City to. mail all contractually required material s submittals to Vince Damasse, Willdan's Project Manager,- for review and approval. Moreover, v Garcia Juarez was directed to submit questions in writing to Willdan: to 23: Garcia Juarez was given a Notice -to -Proceed on October 10, 2006. Under the terms of it 12 the Agreement, Garcia Juarez had sixty days from that date in which to complete the project. 13 24. From the outset; Garcia Juarez. began to tender requests for information and other 14 submittals regarding the project. By the end of October ten submittals had been sent to Willdan 15 for review and.comment. Material submittals and schedules were submitted by Garcia Juarez 16 that did not meet the contract requirements, were incomplete, untimely, or oroDosed then-,(- of 18 non=complying materials. 19 25. GarciaJuarez's failure to provide complete and accurate submittals in accordance with 20 contract requirements. began to put the project behind schedule. In addition, other actions by 21 Garcia Juarez. created further delay. For example, Willdanrejected the non -complying submittals 22 23. and directed Garcia Juarez to make corrections and resubmit. Despite Willdan and City staff's 24 notification that the materials proposed for use by .Garcia Juarez; specifically, the pipe fittings, 25. bolts, gaskets, valves,. pipe bedding- sand and road repair materials, did not meet the contract 26 27 28 9 CROSS-COMPLAINT OF THE CITY OF COMPTON 1 z 3 a 5 6 requirements, Garcia Juarez argued that the City and Willdan must authorize and accept the non- complying materials. 26. Willdan also prodded Garcia Juarez to submit critical plans necessary for the safe and `efficient execution of the work, including an accurate and acceptable progress schedule in Iaccordance with the contract requirements, a traffic control plan, a pipeline disinfection plan and 7 a temporary water service plan (known in the industry as a "high lining" plan). Willdan's 8 direction as it related to the critical plans either went uncorrected or were not submitted in an 9 acceptable, form until weeks after such.documents. are normally prepared and submitted: 10 . 27. Willdan's prodding.of Garcia Juarez to submit other critical documents, needed prior to the start of the work.was unavailing. The documents were not submitted until nearly six weeks 12 13 late, were submitted only when the work was suspended (after ,extraord. i:nary efforts by the City 14 and Willdan to get Garcia Juarez to comply) and when submitted were not:in an acceptable form, 15 but a instead a parroting of the contract language.. -. 16 28. On October 20, 2006; Willdan sent a Notice of Cure `Deficiency.letter 17 to Garcia Juarez. 1R The deficiency identified in the letter outlined Garcia Juarez's continued failure to forward all 19correspondence to Willdan, the City's Engineer on this project. In response to this letter, Garcia 20- Juarez chose to deny it was directed to send correspondence and submittals to Willdan.. 2t Thereafter, Garcia Juarez continued to tender submittals reg 22 arding the project that raised . 23.. concerns with Willdan about the completion time. 24 29. On November 15., 2006, Daniel M. Bleskey of Willdan, received a copy of a preliminary . notice and additional documentation from HD- Supply Waterworks, Inc. (hereinafter referred to 26 27 28 . 1L CROSS-COMPLAINT OF THE CITY OF COMPTON t 2 3 4 5 6 7 Is 16 { 47 I as "HD") indicating that Garcia Juarez had ordered non -approved and non -complying materials, specifically 18" and 24" ADS "soil tight" pipe. This material had been ordered by Garcia Juarez for delivery to the City for the Tucker Street project. These materials were not in accordance with the contract requirements in that the project specified materials that were to conform to the requirements of the Los Angeles County Flood Control District permit which specified 8 -inch and 12 -inch 'water tight" pipe. 30. Receipt of the preliminary notice alarmed Mr. Bleskey because Garcia Juarez had not been given the green light to proceed due -to its failure to comply with various material specifications and its failure to submit a construction schedule. Moreover, as mentioned above, the type of pipe identified on the documentation from HD wasnot called.for in the contract documents, was the wrong size and type and Garcia Juarez had not arranged for the use of the City's yard as:a delivery site. In response to receipt of thepreliminary notice and material invoice; Wil.ldan sent Garcia Juarez a letter titled "Suspension. of Work:" 31. At this same time, Garcia Juarez had been trying to obtain permission to substitute some 1A of -the materials set oui in the specifications: When Willdan repeatedly denied Garcia Juarez's i9 demand for substitution; in its zeal, Garcia Juarez went directly to associates at .another of 20 Willdan's offices and to City on-site personnel to try to obtain permission to make specification 21 changes and;circumvent the Project Manager's direction. None of these individuals had authority ii 23 to approve specification changes. On November 20, 2006, the City sent Garcia Juarez a letter 24_. titled "Notification of Potential Termination`for Default: City of Compton,Tucker. Street Water 25 Distribution Pipeline and Well Discharge Main; Show Cause." Despite receipt of this letter, 26 27 28 11 CROSS-COMPLAINT OF.THE CITY OF COMPTON I Garcia Juarez continued its lack of cooperation and its failure to comply with the contract 2 specifications and the Engineer and City's directions all of which resulted in further project 3 delays. 4 - 32.On November 28, 2006, the City sent Garcia Juarez a letter titled "Notification of 5 Potential Termination for Default." This letter detailed Garcia Juarez's violations of various 6 .7 contract_ terms. This letter was faxed and mailed. Garcia Juarez was given seven days after 8 receipt of the notice to correct the non -complying work and respond in writing. On December 5, 9 2006, Willdan had not received a response to the letter. On December 6a', the City sent Garcia io Juarez a notice of ternunation of contract.12 - FIRST CAUSE OF ACTION' 13 .(Breach of Contract, -Against All Defendants and ROES 1 through 20) 14 33: -Cross-Complainant incorporates by reference paragraphs I through 32, inclusive, 15 of this Cross-Compfaint (including all paragraphs of the General -Allegations and all paragraphs 16 of all preceding causes of action, if any) as if the same were full 17 y set forth herein: - i s _ 34. Cross -Complainant Lias at all times performed the terms of the contract in the i9 manner specified by the contract, or was excused from having to do those things, 20 35. Cross' -Defendants, and each of them, have failed and refused to tender their 21 performance as required by the contract. This includes that Cross -Defendants breached the 22 23 contract beginning on or about October of 2006, causing harm to the City. .24 36:: Cross -Defendant's failure and refusal to per its obligations under the.contract u have directly damaged Cross -Complainant through the delay in the performance of the 27 12 28 CROSS-COMPLAINT OF THE CITY OF COMPTON 2 3 4 s 6 7 ..8 9 l0 tl 12 13, 14 15. IV i7 l z3 1:9 20 21 23 24 2s 26 27 28 Agreement and the failure to complete the project within 60 days of the Notice -or -Proceed. Each day of delay has damaged the City in the amount of $750.00 per day. The City has also sustained the loss of revenues from the water usage at the Tucker Street location in an amount of approximately $6,000 per month. Moreover, the City has had to expend sums of money for its engineers and project managers to put the project out to bid again and in defending against Garcia-Juarez's Complaint; said amount to be proven at the time of trial. SECOND CAUSE OF ACTION (Breach of Covenant of Good Faith and: Fair Dealings, Against All Defendants and ROES T through 20) 37. Cross -Complainant incorporates. by reference paragraphs I through 36, :inclusive, of this Cross -Complaint (including all paragraphs of the General Allegations and.all paragraphs of all -.preceding causes of action; if any) as if the sarine were fully set forthherein. 38. In every contractor agreement there. is -an implied covenant of good faith and fair dealing. This means that each party will, not do; anything to unfairly interfere with the right of any other party to receive the benefits of the contract. 39. The City and.Garcia Juarez eniered:into a contract, referred to herein as the Agreement. 40. The City did all, or substantially all of the significant things that it was required to do under.theAgreement or was excused from:having to do those things. 41. Garcia Juarez unfairly interfered with the City's right to receive. the benefits of Agreement and/or failed to cooperate with the City in the performance of the Agreement. CROSS-COMPLAINT OF THE CITY OF COMPTON t 42. As a result of the actions of Cross -Defendants, and each of them; set forth 2 hereinabove, said Cross -Defendants have violated the implied covenant of.good faith and fair 3 dealing contained in the Agreement. 4 43. The actions of said Cross -Defendants, as hereinbefore described in violation of 5 said covenant of good faith and fair dealing have caused the Cross -Complainant harm and caused b it to suffer damages according to proof -at the -time of trial. s PRAYER FOR RELIEF 9 WHEREFORE, Cross -Complainant demands judgment against Cross -Defendants as. 10 follows: 1, AS TO ALL CAUSES OF ACTION 13 1..:.; For general and specific damages ,according to -proof at,the time :of trial, but in an 14 amount of not less than $60,250,00; is For attorneys' fees and costs according to proof;- 16 3. For interest as allowed by law; 17 IR 4. For cost of suit herein; and 19 5. Any other and further relief the Court may deem just, equitable and proper. zo Dated: February 13,:2007 Respectfully_ submitted, 21 By c=----�L` 22 Legrand H. Clegg Ili: City Attorney Craig J. Cornwell, Chief Deputy.. 23 Edward M. Chavez,.Deputy City Attorney 24 Anita O. Aviles, Deputy. City Attorney 25 26 27 2 14 8 CROSS-COMPLAINT OF THE CITY OF COMPTON